Form S-1/A - General form for registration of securities under the Securities Act of 1933: [Amend]

As filed with the Securities and Exchange Commission on February 24, 2025.

Registration No. 333-282941

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

WASHINGTON, D.C. 20549

AMENDMENT NO.3

FORM S-1

REGISTRATION STATEMENT

UNDER

THE SECURITIES ACT OF 1933

Alpha One Inc.

(Exact name of registrant as specified in its charter)

Wyoming

4899

27-1310226

(State or other jurisdiction of

incorporation or organization)

(Primary Standard Industrial

Classification Code Number)

(I.R.S. Employer

Identification Number)

No. 203, F2.62A, 2F, Tianzhan Building

No. 4 Tanran 5^th Road, Tian’an Community

Shatou Street, Futian District, Shenzhen, Guangdong Province

People’s Republic of China 518000

+86 755 82794624

(Address, including zip code, and telephone number, including area code, of registrant’s principal executive offices)

Cyndy Jackson

1507 Lampman Ct

Cheyenne, WY 82007

(Name, address, including zip code, and telephone number, including area code, of agent for service)

Copies of all communications to:

Rockville Law Group, LLC

Li Weng, Esq.

3635 Old Court Road, #208, Baltimore MD 21208

Telephone: US +1 (410) 243 5500

China: +86 1818 622 4565

Email: wenglidk@foxmail.com

(Name, address, including zip code, and telephone number, including area code, of agent for service)

Approximate date of commencement of proposed sale to the public: From time to time after the effective date of this registration statement, as determined by the selling shareholders.

If any of the securities being registered on this Form are to be offered on a delayed or continuous basis pursuant to Rule 415 under the Securities Act of 1933 check the following box. ☒

If this Form is filed to register additional securities for an offering pursuant to Rule 462(b) under the Securities Act, please check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering. ☐

If this Form is a post-effective amendment filed pursuant to Rule 462(c) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering. ☐

If this Form is a post-effective amendment filed pursuant to Rule 462(d) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering. ☐

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company or an emerging growth company. See the definitions of “large accelerated filer,” “accelerated filer”, “smaller reporting company” and “emerging growth company” in Rule 12b-2 of the Exchange Act. (Check one):

Large accelerated filer	☐	Accelerated filer	☐
Non-accelerated filer	☒	Smaller reporting company	☒
		Emerging growth company	☐

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act ☐.

CALCULATION OF REGISTRATION FEE

Title of Each Class of Securities to be Registered	Amount to be Registered		Proposed Maximum Offering Price Per Share (1)		Proposed Maximum Aggregate Offering Price		Amount of Registration Fee (2)

Common Stock, $0.001 par value		10,000,000	$	2.38		23,800,000		3,643.78

(1)	Estimated solely for purposes of calculating the registration fee in accordance with Rule 457(a) of the Securities Act of 1933 based upon the closing sale price of our shares of common stock of 2.38 on October 29, 2024.

(2)	The fee is calculated by multiplying the aggregate offering amount by 0.0001531, pursuant to Section 6(b) of the Securities Act of 1933.

(3)	Includes 2,493,514 shares of common stock that were issued to Sun Horn Limited sold from Zhuo Wang

(4)	Includes 2,558,200 shares of common stock that were issued to Lin Jianhui sold from Zhongyun Global International Group Limited

(5)	Includes 2,227,337 shares of common stock that were issued to Yu Xiaocai sold from Zhongyun Global International Group Limited

(6)	Includes 406,706 shares of common stock that were issued to Zhang Jinlin sold from Zhongyun Global International Group Limited

(7)	Includes 874,081 shares of common stock that were issued to Cao Yong sold from Zhongyun Global International Group Limited

(8)	Includes 1,440,162 shares of common stock that were issued to Lin Jiayao sold from Zhongyun Global International Group Limited

THE REGISTRANT HEREBY AMENDS THIS REGISTRATION STATEMENT ON SUCH DATE OR DATES AS MAY BE NECESSARY TO DELAY OUR EFFECTIVE DATE UNTIL THE REGISTRANT SHALL FILE A FURTHER AMENDMENT WHICH SPECIFICALLY STATES THAT THIS REGISTRATION STATEMENT SHALL THEREAFTER BECOME EFFECTIVE IN ACCORDANCE WITH SECTION 8(A) OF THE SECURITIES ACT OF 1933 OR UNTIL THE REGISTRATION STATEMENT SHALL BECOME EFFECTIVE ON SUCH DATE AS THE COMMISSION, ACTING PURSUANT TO SAID SECTION 8(A), MAY DETERMINE.

THE INFORMATION IN THIS PROSPECTUS IS NOT COMPLETE AND MAY BE CHANGED. WE MAY NOT SELL THESE SECURITIES UNTIL THE REGISTRATION STATEMENT FILED WITH THE SECURITIES AND EXCHANGE COMMISSION IS EFFECTIVE. THIS PROSPECTUS IS NOT AN OFFER TO SELL THESE SECURITIES AND IT IS NOT SOLICITING AN OFFER TO BUY THESE SECURITIES IN ANY STATE WHERE THE OFFER OR SALE IS NOT PERMITTED. THERE IS NO MINIMUM PURCHASE REQUIREMENT FOR THE OFFERING TO PROCEED.

PRELIMINARY PROSPECTUS

Alpha One Inc.

10,000,000 SHARES OF COMMON STOCK

$0.001 PAR VALUE PER SHARE

This prospectus relates to shares of common stock of Alpha One Inc. which may be offered by the selling shareholders for their own account.

The shares of common stock being offered by the selling shareholders pursuant to this prospectus are “restricted securities” under the Securities Act of 1933, as amended (the “Securities Act”), before their sale under this prospectus. This prospectus has been prepared for the purpose of registering these shares of common stock under the Securities Act to allow for a sale by the selling shareholders to the public without restriction. Each of the selling shareholders and the participating brokers or dealers may be deemed to be an “underwriter” within the meaning of the Securities Act, in which event any profit on the sale of shares by such selling shareholder, and any commissions or discounts received by the brokers or dealers, may be deemed to be underwriting compensation under the Securities Act. The selling shareholders must offer and sell their shares for the fixed price of $1.000 for the duration of the offering.

The registration of the shares of our common stock covered by this prospectus does not necessarily mean that any shares of our common stock will be sold by any of the selling shareholders, and we cannot predict when or in what amounts any of the selling shareholders may sell any of our shares of common stock offered by this prospectus.

Our common stock is quoted on the OTC Pink Marketplace under the symbol “AOAO.” On October 29, 2024, the closing price of our common stock was $2.38.

We are not selling any shares of our common stock under this prospectus and will not receive any proceeds from any sale or disposition by the selling shareholders of the shares of our common stock covered by this prospectus. We are paying the expenses incurred in registering the shares.

Alpha One Inc. (“AOAO”) is not an operating company but a holding company incorporated in the State of Wyoming. Substantially all of the business operations are conducted in the People’s Republic of China (“PRC” or “China”) by our PRC subsidiary. Shares of common stock registered in this prospectus are shares of a U.S. holding company, which does not conduct operations. As used in this prospectus, “we,” “us,” “our” or “the Company” refers to Alpha One Inc. Or the U.S. holding company.

We face various legal and operational risks and uncertainties relating to our subsidiary’s operations in China. Because substantially all of our operations are conducted in China through our PRC subsidiary, the Chinese government may intervene or influence the operation of our PRC subsidiary and exercise significant oversight and discretion over the conduct of their business and may intervene in or influence their operations at any time, or may exert more control over securities offerings conducted overseas and/or foreign investment in China-based issuers, which could result in a material change in operations of our PRC subsidiary and/or the value of our common stock. Further, any actions by the Chinese government to exert more oversight and control over offerings that are conducted overseas and/or foreign investment in China-based issuers could significantly limit or completely hinder our ability to offer or continue to offer securities to investors and cause the value of such securities to significantly decline or be worthless. See “Risk Factors - Risks Related to Doing Business in China -Any actions by the Chinese government to exert more oversight and control over offerings that are conducted overseas and/or foreign investment in China-based issuers could significantly limit or completely hinder our ability to offer or continue to offer securities to investors and cause the value of such securities to significantly decline or be worthless” on page 18.

In recent years, the PRC government initiated a series of regulatory actions and made a number of public statements on the regulation of business operations in China, including cracking down on illegal activities in the securities market, enhancing supervision over China-based companies listed overseas, adopting new measures to extend the scope of cybersecurity reviews, and expanding efforts in anti-monopoly enforcement. As of the date of this prospectus, we have not engaged in any monopolistic behavior and our business does not control more than one million users’ personal information as of the date of this prospectus, implicate cybersecurity, or involve any other type of restricted industry. However, we cannot affirm that PRC regulators share the same interpretation. Because these statements and regulatory actions are new and subject to change, it is difficult for us to predict how quickly the legislative or administrative regulation making bodies in China will respond to companies, or what existing or new laws or regulations will be amended or promulgated, if any, or the potential impact such amended or new legislation will have on our daily business operations or our ability to accept foreign investments and list on a U.S. stock exchange. See “Prospectus Summary — Recent PRC Regulatory Developments” beginning on page 4 of this prospectus.

On February 17, 2023, the CSRC released the New Overseas Listing Rules, which came into effect on March 31, 2023. The New Overseas Listing Rules apply to overseas securities offerings and/or listings conducted by (i) companies incorporated in the PRC, or PRC domestic companies, directly and (ii) companies incorporated overseas with operations primarily in the PRC and valued on the basis of interests in PRC domestic companies, or indirect offerings. The New Overseas Listing Rules requires (1) the filings of the overseas offering and listing plan by the PRC domestic companies with the CSRC under certain conditions, and (2) the filing of their underwriters with the CSRC under certain conditions and the submission of an annual report to of such filed underwriters the CSRC within the required timeline. The required filing scope is not limited to the initial public offering, but also includes subsequent overseas securities offerings, single or multiple acquisition(s), share swap, transfer of shares or other means to seek an overseas direct or indirect listing, a secondary listing or dual listing. On the same day, the CSRC also held a press conference for the release of the New Overseas Listing Rules and issued the Overseas Listing Notice. Under the Overseas Listing Notice, a company that (i) has already completed overseas listing or (ii) has already obtained the approval for the offering or listing from overseas securities regulators or exchanges but has not completed such offering or listing before effective date of the New Overseas Listing Rules and also completes the offering or listing before September 30, 2023 will be considered as an existing listed company and is not required to make any filing until it conducts a new offering in the future. For the company that has already submitted offering and listing applications but not yet obtained the approvals from overseas securities regulators or exchanges shall choose to make its filing with the CSRC at a reasonable time but before the completion of the offering/listing. For the company that has already obtained CSRC approval, which was substituted by the filing requirements upon the effectiveness of the Trial Measures, for overseas listing or offering can continue its process during the valid term of the CSRC approval without additional filing and it shall make the CSRC filing pursuant to the New Overseas Listing Rules if it does not complete the offering or listing before the expiration of the original approval from CSRC.

On May 7, 2024, the CSRC released of the guidelines “Overseas Offering and Listing No. 7 Regulatory Requirements for Domestic Companies Transferring Offering and Listing from overseas OTC Market to Overseas Stock Exchange”, rules are, (i) According to Article 1 and Article 2 of new regulations, overseas offering and listing refers to offering and listing activities in overseas stock exchanges, and listing of domestic companies in overseas OTC market is out of scope for the filing requirement; (ii) According to Article 16 of new regulations, domestic companies that seek initial public offering or listing in overseas market shall file with CSRC within 3 working days after the relevant application is submitted overseas, and offering and listing in other overseas market than where it has offered and listed shall be filed with CSRC within 3 working days after the relevant application is submitted overseas; and (iii) According to Notice of Filing Management Arrangements for Domestic Companies Seeking Offering and Listing in Overseas Market, since new regulations came into effect (which is 31^st March, 2023), domestic companies that have submitted application to overseas market other than where it has offered and listed, but do not get approval from overseas regulator or stock exchanges yet, shall file with CSRC before offering and listing procedures are completed. We are listing in overseas OTC market and not transferring Offering and Listing from Overseas OTC Market to Overseas Stock Exchange currently. According to the CSRC Guidelines of Regulatory Rules, we are not subjected to the Trial Administrative Measures of Overseas Securities Offering and Listing by Domestic Companies, or the Trial Measures, which became effective on March 31, 2023.

The Holding Foreign Companies Accountable Act, or the HFCAA, was enacted on December 18, 2020, and was amended by the Consolidated Appropriations Act, 2023 enacted on December 29, 2022. The amended HFCAA states if the SEC determines that we have filed audit reports issued by a registered public accounting firm that has not been subject to inspection by the PCAOB for two consecutive years, the SEC shall prohibit our Common stock from being traded on a national securities exchange or in the over-the-counter trading market in the United States. The Consolidated Appropriations Act, 2023 reduced the number of consecutive non-inspection years required for triggering the prohibitions under the HFCAA from three years to two years. The PCAOB issued a Determination Report on December 16, 2021 (the “Determination Report”) which found that the PCAOB was unable to inspect or investigate completely registered public accounting firms headquartered in mainland China and Hong Kong because of a position taken by one or more authorities in those jurisdictions. Furthermore, the Determination Report identified the specific registered public accounting firms which are subject to these determinations (“PCAOB Identified Firms”). Our auditor, Bush & Associates CPA LLC, the independent registered public accounting firm that issues the audit report included elsewhere in this prospectus, as an auditor of companies that are traded publicly in the United States and a firm registered with the PCAOB, is subject to laws in the U.S. pursuant to which the PCAOB conducts regular inspections to assess its compliance with the applicable professional standards. Bush & Associates CPA LLC is headquartered in Nevada, and, as of the date of this prospectus, was not included in the list of PCAOB Identified Firms in the Determination Report. On December 15, 2022, the PCAOB issued a report that vacated its December 16, 2021, determination and removed mainland China and Hong Kong from the list of jurisdictions where it is unable to inspect or investigate completely registered public accounting firms.

Each year, the PCAOB will determine whether it can inspect and investigate audit firms in mainland China and Hong Kong, among other jurisdictions. If the PCAOB determines in the future that it no longer has full access to inspect and investigate accounting firms in mainland China and Hong Kong and we use an accounting firm headquartered in one of these jurisdictions to issue an audit report on our financial statements filed with the SEC, we would be identified as a “Commission-Identified Issuer” following the filing of the annual report on Form 10-K for the relevant fiscal year. There can be no assurance that we would not be identified as a “Commission-Identified Issuer” for any future fiscal year, and if we were so identified for two consecutive years, we would become subject to the prohibition on trading under the HFCAA. The delisting of our Common stock, or the threat of their being delisted, may materially and adversely affect the value of your investment. These risks could result in a material adverse change in our operations and the value of our Common stock, significantly limit or completely hinder our ability to offer or continue to offer securities to investors or cause the value of such securities to significantly decline or become worthless.

Cash may be transferred within our organization in the following manners: (i) we may transfer funds to our PRC subsidiary by way of capital contributions or loans, through intermediate holding companies, such as our Hong Kong subsidiary; (ii) we or our intermediate holding company may provide loans to our PRC operating subsidiary directly and vice versa; and (iii) our PRC subsidiary may make dividends or other distributions to us through our intermediate holding subsidiaries.

As of the date of this prospectus, we have not made dividend or other distributions to our shareholders. We may pay dividends to our shareholders subject to our ability to service our debts as they become due and provided that our assets will exceed our liabilities after the payment of such dividends. As a holding company, we may rely on dividends and other distributions on equity paid by our subsidiaries for our cash and liquidity requirements, including payment of any debt we may incur outside of China and our expenses. If any of our subsidiaries incurs debt on its own behalf in the future, the instruments governing such debt may restrict their ability to pay dividends to us. To the extent cash or assets in the business is in the PRC or a PRC subsidiary, the cash or assets may not be available to fund operations or for other use outside of the PRC due to interventions in or the imposition of restrictions and limitations on our or our subsidiaries’ ability by the PRC government to transfer cash or assets. PRC laws and regulations applicable to our PRC subsidiaries permit payments of dividends only out of their retained earnings, if any, determined in accordance with applicable accounting standards and regulations. Our PRC subsidiaries may pay dividends only out of their respective accumulated after-tax profits as determined in accordance with PRC accounting standards and regulations. In addition, our subsidiaries are required to set aside at least 10% of its accumulated after-tax profits each year, if any, to fund certain statutory reserve funds, until the aggregate amount of such funds reaches 50% of its registered capital. At its discretion, a wholly foreign-owned enterprise may allocate a portion of its after-tax profits to discretionary funds. These reserve funds and discretionary funds are not distributable as cash dividends. Furthermore, dividends paid by our WFOE subsidiaries to their parent companies will be subject to a 10% withholding tax, which can be reduced to 5% if certain requirements are met. The PRC government also imposes restrictions on the conversion of RMB into foreign currencies and the remittance of currencies out of the PRC. As such, we may experience difficulties in completing the administrative procedures necessary to obtain and remit foreign currency for the payment of dividends from our profits, if any. As of the date of this prospectus, none of our subsidiaries has made any dividends or other distributions to us.

Investing in our securities involves a high degree of risk. Before making any investment decision, you should carefully review and consider all the information in this prospectus and the documents incorporated by reference herein, including the risks and uncertainties described under “Risk Factors” beginning on page 10.

NEITHER THE SECURITIES AND EXCHANGE COMMISSION NOR ANY STATE SECURITIES COMMISSION HAS APPROVED OR DISAPPROVED OF THESE SECURITIES OR DETERMINED IF THIS PROSPECTUS IS TRUTHFUL OR COMPLETE. ANY REPRESENTATION TO THE CONTRARY IS A CRIMINAL OFFENSE.

We may amend or supplement this prospectus from time to time by filing amendments or supplements as required. You should read the entire prospectus and any amendments or supplements carefully before you make your investment decision.

The date of this prospectus is February 24, 2025.

Alpha One Inc.

TABLE OF CONTENTS

	Page
Prospectus Summary	2
Risk Factors	10
Use of Proceeds	23
Determination of Offering Price	23
Description of Business	23
Legal Proceedings	28
Management’s Discussion and Analysis of Financial Condition and Results of Operations	28
Market Price of and Dividends on Registrant’s Common Equity and Related Stockholder Matters	33
Management – Directors and Executive Officers	33
Executive Compensation	35
Security Ownership of Certain Beneficial Owners and Management	36
Certain Relationships and Related Transactions, and Corporate Governance	37
Selling Shareholders	37
Plan of Distribution	38
Description of Securities	40
Interests of Named Experts and Counsel	41
Additional Information	41
Legal Matters	41
Experts	41
Financial Statements	F-1

You should rely only on the information contained in this prospectus or a supplement to this prospectus. We have not authorized anyone to provide you with different information. This prospectus is not an offer to sell securities, and it is not soliciting an offer to buy securities, in any jurisdiction where the offer or sale is not permitted. You should not assume that the information contained in this prospectus or any supplement to this prospectus is accurate as of any date other than the date on the front cover of those documents.

CAUTIONARY NOTE REGARDING FORWARD-LOOKING STATEMENTS

This prospectus contains “forward-looking statements”. Forward-looking statements reflect the current view about future events. When used in this prospectus, the words “anticipate,” “believe,” “estimate,” “expect,” “future,” “intend,” “plan,” or the negative of these terms and similar expressions, as they relate to us or our management, identify forward-looking statements. Such statements include, but are not limited to, statements contained in this prospectus relating to our business strategy, our future operating results and liquidity and capital resources outlook. Forward-looking statements are based on our current expectations and assumptions regarding our business, the economy and other future conditions. Because forward–looking statements relate to the future, they are subject to inherent uncertainties, risks and changes in circumstances that are difficult to predict. Our actual results may differ materially from those contemplated by the forward-looking statements. They are neither statements of historical fact nor guarantees of assurance of future performance. We caution you therefore against relying on any of these forward-looking statements. Important factors that could cause actual results to differ materially from those in the forward-looking statements include, without limitation, a continued decline in general economic conditions nationally and internationally; decreased demand for our products and services; market acceptance of our products and services; the impact of any infringement actions or other litigation brought against us; competition from other providers and products; our ability to develop and commercialize new and improved products and services; our ability to raise capital to fund continuing operations; changes in government regulation that relate to our business, and more specifically, how we market and sell products; our ability to complete customer transactions and capital raising transactions; and other factors (including the risks contained in the section of this prospectus entitled “Risk Factors”) relating to our industry, our operations and results of operations and any businesses that may be acquired by us. Should one or more of these risks or uncertainties materialize, or should the underlying assumptions prove incorrect, actual results may differ significantly from those anticipated, believed, estimated, expected, intended or planned.

Factors or events that could cause our actual results to differ may emerge from time to time, and it is not possible for us to predict all of them. We cannot guarantee future results, levels of activity, performance or achievements. Except as required by applicable law we do not intend to update any of the forward-looking statements to conform these statements to actual results.

PROSPECTUS SUMMARY

This summary only highlights the more detailed information appearing elsewhere in this prospectus. As this is a summary, it does not contain all of the information that you should consider in making an investment decision. You should read this entire prospectus carefully, including the information under “Risk Factors” and our financial statements and the related notes included elsewhere in this prospectus, before investing.

In this Prospectus, the “Company,’’ ‘‘we,’’ ‘‘us,’’ and ‘‘our,’’ refer to Alpha One Inc. Or U.S. Holding Company, unless the context otherwise requires. Unless otherwise indicated, the term ‘‘fiscal year’’ refers to our fiscal year ending March 31st. Unless otherwise indicated, the term ‘‘common stock’’ refers to shares of the Company’s common stock.

Corporate History

Alpha One Inc. (“we”, “us”, the “Company” or “AOAO”) was originally incorporated in State of Nevada on May 5, 2006 under the name Microscints, Inc. On October 26, 2009 the Company filed the Certificate of Amendment to change the name from Microscints, Inc. to World Mobile Holdings, Inc. On March 19, 2020, the Company redomiciled from the State of Nevada to the State of Wyoming. On September 10, 2021, the Company’s name was changed from World Mobile Holdings, Inc. to Alpha One Inc, The Company had been engaged in the various business since its incorporation. The Company was not successful and discontinued the majority of its operation by December 31, 2016. Beginning from January 2017, the Company plans on providing business services and financing to emerging growth entities.

On October 8, 2019, Haining Zhang, filed a petition with the District Court, Clark County, Nevada, and the Court ordered that Mr. Zhang was appointed as receiver for the Company. Consequently, Mr. Zhang is granted the authority to conduct business of the Company pursuant to N.R.S. 78.630. Haining Zhang was appointed the sole officer and director at that time.

On October 15, 2019, the Company issued 100,000,000 shares of common stock, with a par value of $0.001, to Mr. Zhang, our CEO, for $100,000, $99,950 of which was subsequently expensed in its operation by December 31, 2019, and the balance was expensed in its operation in 2020.

On February 8, 2021, the previously issued 100,000,000 shares of common stock were canceled in connection with changes in the Company’s strategic direction.

On March 30, 2021, 100,000,000 shares of common stock, under the control of Haining Zhang, were transferred to Zhuo Wang. As a result, Haining Zhang resigned as the sole officer and director, and Shuhua Liu was appointed as the sole director and CEO of the Company.

On May 1, 2021 the Company amended its article of incorporation to change its authorized capital as following: 50,000,000 shares of preferred stock, par value $0.001 per share; 450,000,000 shares of common stock, par value $0.001 per share. 500,000 shares of Preferred Stock are designated Series A Preferred Stock. On June 17, 2021, the Company issued 245,000 shares of preferred stock to Zhuo Wang, 198,900 shares of preferred stock to Shuhua Liu, and 56,100 shares of preferred stock to Goldcrown International (HK) Limited, controlled by Wei Chen, as compensation for services provided.

On September 10, 2021, the Company effectuated a 100-for-1 reverse stock split, which resulted in a new total of 1,359,447 shares of common stock.

On February 8, 2022, the Company convert 500,000 of its Series A Preferred Stock into common stock with a ratio of 100 for 1.

On March 23, 2023, Alpha One Inc. (“AOAO,” or the “Company”) completed its merger with Zhongyun (BVI). (“Zhongyun BVI”) and Zhongyun BVI’s wholly-owned subsidiary, Shenzhen Zhongyun Communication Technology Co., Ltd” (“Shenzhen Zhongyun”), pursuant to the terms of a definitive share exchange agreement dated March 23, 2023.

Upon completion of the merger, all of the outstanding shares of Zhongyun BVI’s common stock were exchanged for 25,450,086 shares of common stock of AOAO. Prior to the merger, Shuhua Liu and her spouse directly and indirectly obtained the total 49.65% controlled of AOAO, and 50% indirectly controlled of Zhongyun BVI by Zhongyun Global International Group Limited. Shuhua Liu is the sole director of AOAO and Zhongyun BVI. As AOAO and Zhongyun BV were under common control at the time of the share exchange, the transaction is accounted for as a combination of entities under common control in a manner similar to the pooling-of-interests method of accounting. Following the Merger, Shuhua Liu and her spouse directly and indirectly obtained the 49.77% controlled of AOAO. Immediately after completion of such share exchange, the Company has a total of 76,809,533 issued and outstanding shares of common stock, with authorized common shares of 450,000,000.

Consequently, the Company has ceased to fall under the definition of shell company as define in Rule 12b-2 under the Exchange Act of 1934, as amended (the “Exchange Act”) and Zhongyun BVI is now a wholly owned subsidiary.

On November 16, 2023, the former director and CEO Zhuo Wang transferred 19,890,000 shares to Sun Horn Limited, 4,239,742 shares to Shuhua Liu and 1,370,258 shares Xinli Chen for free.

On May 28, 2024, 25,450,086 shares of common stock of AOAO transferred from Zhongyun Global International Group Limited to seventy-one individuals (including Shuhua Liu 1,561,033 shares) and two corporates, after the transferred, Shuhua Liu and her spouse directly and indirectly held total 56,800,775 shares, or 66.646% of outstanding shares.

Our Company structure is shown in the below chart. The percentages denote ownership.

Zhongyun (BVI) Limited (“Zhongyun BVI”) was incorporated in the British Virgin Islands on December 6, 2022 with limited liability.

Zhongyun Investment Hong Kong Limited (“Zhongyun HK”) which is 100% owned by Zhongyun BVI, was incorported in the HongKong on December 23, 2022, Zhongyun HK is an investment holding company with no operations. On March 2, 2023, Zhongyun HK acquired Shenzhen Zhongyun Communication Technology Co., Ltd.

Shenzhen Zhongyun Communication Technology Co., Ltd, a Chinese company, a wholly foreign owned enterprise (WFOE), also referred to herein as “Shenzhen Zhongyun”, which was incorporated on August 25, 2020 by the controlling shareholder, Shuhua Liu. Shenzhen Zhongyun is principally engaged in the electronic products trading and telecommunication engineering servicess in the People’s Republic of China (“PRC”).

Shenzhen Zhongyun is the company through which we operate, and which shares our business plan with the goal of developing and providing modern electronic products trading and telecommunication engineering services to our future clients.

The Company’s mailing address is No. 203, F2.62A, 2F, Tianzhan Building, No. 4 Tanran 5th Road, Tian’an Community, Shatou Street, Futian District, Shenzhen, Guangdong Province, China. The telephone number is +86 755 82794624.

Status of “Smaller Reporting Company”

We are a “smaller reporting company” as defined in Item 10(f)(1) of Regulation S-K. Smaller reporting companies may take advantage of certain reduced disclosure obligations. We have elected to comply with the scaled disclosure requirements applicable to “smaller reporting companies,” including providing two years of audited financial statements. We will remain a smaller reporting company until the last day of the fiscal year in which (1) the market value of our Common Stock held by non-affiliates is equal to or exceeds $250 million and (2) our annual revenues were equal to or exceeded $100 million during such completed fiscal year and the market value of our Common Stock held by non-affiliates is equal to or exceeds $700 million.

Recent PRC Regulatory Developments

Among other things, the Regulations on Mergers and Acquisitions of Domestic Enterprises by Foreign Investors (the “M&A Rules”) and the Anti-Monopoly Law of the People’s Republic of China promulgated by the SCNPC which became effective in 2008 (“Anti-Monopoly Law”), established additional procedures and requirements that could make merger and acquisition activities by foreign investors more time-consuming and complex. Such regulation requires, among other things, that the Ministry of Commerce of the People’s Republic of China (the “MOFCOM”) be notified in advance of any change-of-control transaction in which a foreign investor acquires control of a PRC domestic enterprise or a foreign company with substantial PRC operations, if certain thresholds under the Provisions of the State Council on the Standard for Declaration of Concentration of Business Operators, issued by the State Council in 2008, are triggered. Moreover, the Anti-Monopoly Law requires that transactions which involve the national security, the examination on the national security shall also be conducted according to the relevant provisions of the Measures for the Safety Examination of Foreign Investment. In addition, the PRC Measures for the Security Review of Foreign Investment which became effective in January 2021 require acquisitions by foreign investors of PRC companies engaged in military-related or certain other industries that are crucial to national security be subject to security review before consummation of any such acquisition.

On July 6, 2021, the relevant PRC government authorities made public the Opinions on Strictly Cracking Down on Illegal Securities Activities in Accordance with the Law (the “Opinions”). These opinions emphasized the need to strengthen the administration over illegal securities activities and the supervision on overseas listings by China-based companies and proposed to take effective measures, such as promoting the construction of relevant regulatory systems to deal with the risks and incidents faced by China-based overseas-listed companies. Pursuant to the Opinions, Chinese regulators are required to accelerate rulemaking related to the overseas issuance and listing of securities, and update the existing laws and regulations related to data security, cross-border data flow, and management of confidential information. Numerous regulations, guidelines and other measures are expected to be adopted under the umbrella of or in addition to the Cybersecurity Law of the PRC (the “Cybersecurity Law”) and the Data Security Law. As of the date of this prospectus, no official guidance or related implementation rules have been issued yet and the interpretation of these opinions remains unclear at this stage. See “Risk Factors — Risks Related to Doing Business in China on page 15 to page 20, Any failure to comply with applicable laws and requirements could have a material and adverse effect on our business.

On December 28, 2021, the Cybersecurity Review Measures (2021 version), which were promulgated and became effective on February 15, 2022, provide that any “online platform operators” possessing personal information of more than one million users which seeks to list in a foreign stock exchange should be subject to cybersecurity review. The Cybersecurity Review Measures (2021 version), further list the factors to be considered when assessing the national security risks of the relevant activities, including, among others, (i) the risk of core data, important data or a large amount of personal information being stolen, leaked, destroyed, and illegally used or exited the country; and (ii) the risk of critical information infrastructure, core data, important data or a large amount of personal information being affected, controlled, or maliciously used by foreign governments after listing abroad. The CAC requires that under the new rules, companies possessing personal information of more than one million users must now apply for cybersecurity approval when seeking listings in other nations because of the risk that such data and personal information could be “affected, controlled, and maliciously exploited by foreign governments.” Any failure to comply with applicable laws and requirements could have a material and adverse effect on our business.

As of the date of this prospectus, we have not engaged in any monopolistic behavior and our business does not control more than one million users’ personal information, implicate cybersecurity, or involve any other type of restricted industry. As advised by our PRC legal counsel, Inner Mongolia Shuoda Law Firm, as of the date of this prospectus, we are not required to declare a cybersecurity review with the CAC, according to the Measures for Cybersecurity Review, since we are not an online platform operator carrying out data processing activities that affect or may affect national security, and currently do not have over one million users’ personal information and do not anticipate that we will be collecting over one million users’ personal information in the foreseeable future, which we understand might otherwise subject us to the Measures for Cybersecurity Review. As of the date of this prospectus, we have not received any notice from any authorities identifying us as CIIOs or requiring us to undergo a cybersecurity review or network data security review by the CAC. However, we cannot affirm that PRC regulators share the same interpretation. Because these statements and regulatory actions are new and subject to change, it is difficult for us to predict how quickly the legislative or administrative regulation making bodies in China will respond to companies, or what existing or new laws or regulations will be amended or promulgated, if any, or the potential impact such amended or new legislation will have on our daily business operations or our ability to accept foreign investments and list on a U.S. stock exchange.

On the same day, the CSRC also held a press conference for the release of the New Overseas Listing Rules and issued the Overseas Listing Notice. Under the Overseas Listing Notice, a company that (i) has already completed overseas listing or (ii) has already obtained the approval for the offering or listing from overseas securities regulators or exchanges but has not completed such offering or listing before effective date of the New Overseas Listing Rules and also completes the offering or listing before September 30, 2023 will be considered as an existing listed company and is not required to make any filing until it conducts a new offering in the future. For the company that has already submitted offering and listing applications but not yet obtained the approvals from overseas securities regulators or exchanges shall choose to make its filing with the CSRC at a reasonable time but before the completion of the offering/listing. For the company that has already obtained CSRC approval, which was substituted by the filing requirements upon the effectiveness of the Trial Measures, for overseas listing or offering can continue its process during the valid term of the CSRC approval without additional filing and it shall make the CSRC filing pursuant to the New Overseas Listing Rules if it does not complete the offering or listing before the expiration of the original approval from CSRC.

We have been closely monitoring regulatory developments in China regarding any necessary approvals from the CSRC, the CAC or other PRC regulatory authorities required for our operations and overseas listings. However, there remains significant uncertainty as to the enactment, interpretation and implementation of regulatory requirements related to overseas securities offerings and other capital markets activities. The PRC government may take actions to exert more oversight and control over offerings by China-based issuers conducted overseas and/or foreign investment in such companies, which could significantly limit or completely hinder our ability to offer or continue to offer securities to investors outside China and cause the value of our securities to significantly decline or become worthless. If it is determined in the future that the approval or permissions of the CSRC, the CAC or any other regulatory authority is required for our operations through our PRC Subsidiaries and this offering and we or our PRC Subsidiaries do not receive or maintain the approvals or permissions, or we or our PRC Subsidiaries inadvertently conclude that such approvals or permissions are not required, or applicable laws, regulations, or interpretations change such that we or our PRC Subsidiaries are required to obtain approvals or permissions in the future, we and our PRC Subsidiaries may be subject to investigations by competent regulators, fines or penalties, ordered to suspend our PRC Subsidiaries’ relevant operations and rectify any non-compliance, limit our ability to pay dividends outside of mainland China, delay or restrict the repatriation of the proceeds from this offering into mainland China or take other actions prohibited from engaging in relevant business or conducting any offering, and these risks could result in a material adverse change in our operations, significantly limit or completely hinder our ability to offer or continue to offer securities to investors, or cause such securities to significantly decline in value or become worthless. See “Risk Factors — Risks Related to Doing Business in China — Chinese government may intervene or influence our operations in accordance with laws and regulations, or may exert more control over offerings conducted overseas and/or foreign investment in China-based issuers, which could result in a material change in our operations and/or the value of our shares” and “Risk Factors — Risks Related to Doing Business in China —Any actions by the Chinese government to exert more oversight and control over offerings that are conducted overseas and/or foreign investment in China-based issuers could significantly limit or completely hinder our ability to offer or continue to offer securities to investors and cause the value of such securities to significantly decline or be worthless” on page 18, of this prospectus.

Cash Transfers and Dividend Distributions

We currently have not maintained any cash management policies that dictate the purpose, amount and procedures for cash transfers between the Company, our subsidiaries, or investors. Rather, the funds can be transferred in accordance with the applicable PRC laws and regulations. To the extent cash or assets in the business is in the PRC or a PRC entity, the funds or assets may not be available to fund operations or for other use outside of the PRC due to the imposition of restrictions and limitations on the ability of us or our subsidiaries by the PRC regulatory authority to transfer cash or assets. As of March 31, 2024 and 2023, our PRC operating subsidiary’s cash held in RBM were $383,682 (equivalent to RMB2,770,310) and $329,994 (equivalent to RMB 2,266,269) respectively. As of September 30, 2024, our PRC operating subsidiary’s cash held in RMB were $3,225 (equivalent to RMB22,636).

Under existing PRC foreign exchange regulations, payment of current account item, such as profit distributions and trade and service-related foreign exchange transactions, can be made in foreign currencies without prior approval from the State Administration of Foreign Exchange, or the SAFE, by complying with certain procedural requirements. Therefore, our PRC subsidiary is able to pay dividends in foreign currencies to us without prior approval from SAFE, subject to the condition that the remittance of such dividends outside of the PRC complies with certain procedures under PRC foreign exchange regulations, such as the overseas investment registrations by our shareholders or the ultimate shareholders of our corporate shareholders who are PRC residents. Approval from, or registration with, appropriate government authorities is, however, required where the RMB is to be converted into foreign currency and remitted out of China to pay capital expenses such as repayment of loans denominated in foreign currencies. The PRC regulatory authority may also at its discretion restrict access in the future to foreign currencies for current account transactions. Current PRC regulations permit our PRC subsidiary to pay dividends to the Company only out of their accumulated profits, if any, determined in accordance with Chinese accounting standards and regulations.

We are a holding company with no material operations of our own and do not generate any revenue. We currently conduct substantially all of our operations through our PRC operating subsidiary Shenzhen Zhongyun. As a holding company, we may rely on dividends and other distributions on equity paid by our subsidiaries, including those based in mainland China,for our cash and liquidity requirements. If any of our subsidiaries incurs debt on its own behalf in the future, the instruments governing such debt may restrict their ability to pay dividends to us. Under Wyoming law, we is permitted to provide funding to our subsidiaries in corporated in the British Virgin Islands and Hong Kong through loans or capital contributions as our board of directors may determine from time to time. Our subsidiary is permitted under the respective laws of the British Virgin Islands and Hong Kong to provide funding to the Company through dividend distribution without restrictions on the amount of the funds. There are no restrictions by the British Virgin Islands and Hong Kong governments on dividend distributions from Hong Kong to the British Virgin Islands and the British Virgin Islands to Wyoming.

Under the PRC laws and regulations, our PRC subsidiaries may pay dividends only out of their respective accumulated after-tax profits as determined in accordance with PRC accounting standards and regulations. The Company is a holding company and its material assets consist solely of the ownership interests held in its PRC subsidiary. The Company relies on dividends paid by its subsidiaries for its working capital and cash needs, including the funds necessary: (i) to pay dividends or cash distributions to its shareholders, (ii) to service any debt obligations and (iii) to pay operating expenses. As a result of PRC laws and regulations that require annual appropriations of 10% of after-tax income to be set aside in a general reserve fund prior to payment of dividends, the Company’s PRC subsidiary is restricted in that respect, in their ability to transfer a portion of their net assets to the Company as a dividend. As of March 31, 2024 and 2023, our PRC operating subsidiary’s net restricted assets were $2,961,361 (equivalent to RMB21,381,980) and $1,431,152 (equivalent to RMB 9,828,589) respectively. As of September 30, 2024, our PRC operating subsidiary’s net restricted assets were $2,282,708 (equivalent to RMB16,020,359).

The following table describes transfers among us and our subsidiaries made during the periods presented:

	For the years ended March 31				For the six months ended September 30
	2024		2023		2024		2023
	RMB		RMB		RMB		RMB
Capital contributions from us to our offshore subsidiaries ⁽¹⁾		-		-		-		-
Loans from us to our offshore subsidiaries		-		-		-		-
Capital contributions from our offshore subsidiaries to PRC operating subsidiary		-		-		-		-
Loans from our PRC operating subsidiaries to our offshore subsidiaries		-		-		-		-
Other amounts paid by our WFOE on our behalf of our offshore subsidiaries ⁽²⁾		-		-		-		-

	(1)	“Offshore subsidiaries” refer to all of our subsidiaries except our PRC subsidiary.
	(2)	Cash paid by our PRC operating subsidiary to our Hong Kong subsidiaries for expenses.

As of the date of this prospectus, our Wyoming holding company Alpha One Inc., has not declared or paid dividends, made distributions, or transferred assets to its subsidiaries in the past, nor have any dividends, distributions or asset transfers been made by any our PRC Subsidiaries to Zhongyun HK, Zhongyun BVI or the Wyoming holding company. For the years ended March 31, 2024 and 2023 and for the six months ended September 30, 2024 and 2023, there was no cash transfer among our Wyoming holding company, Zhongyun BVI, Zhongyun HK and our PRC Subsidiary. Wyoming holding company’s expenses paid by the solely director Shuhua Liu for the years ended March 31, 2024 and 2023 and for the six months ended September 30, 2024 and 2023. We do not have any current plan to declare or pay any cash dividends on our ordinary shares in the foreseeable future after this offering.

Permission Required from the PRC Authorities with respect to Operations and Securities Listing

As of the date of this prospectus, we and our PRC subsidiary have received all requisite permits, approvals and certificates from the PRC government authorities to conduct our business operations in China, and no permission or approval has been denied or revoked.

As an enterprise engaged in intelligent product sales and telecommunication engineering services business, our PRC subsidiary is not operating in an industry that prohibits or limits foreign investment. We and our PRC subsidiary are not required to obtain permissions from the CSRC, the CAC or any other PRC authorities to operate, other than the permits and approvals our PRC subsidiary have already received. However, if we or our subsidiary do not receive or maintain required permissions or approvals, inadvertently conclude that such permissions or approvals are not required, or applicable laws, regulations, or interpretations change such that we are required to obtain such permissions or approvals in the future, we may be subject to governmental investigations or enforcement actions, fines, penalties, suspension of operations, or be prohibited from engaging in relevant business or conducting securities offering, and these risks could result in a material adverse change in our operations, significantly limit or completely hinder our ability to offer or continue to offer securities to investors, or cause such securities to significantly decline in value or become worthless.

Our PRC subsidiaries are required to obtain certain permits and licenses from the PRC government agencies to operate our business in China, including: (a) business licenses, (b) Construction Enterprise Qualification Certificate, and (c) Safety Production License. We have received such licenses or certificates pursuant to PRC Law.

On February 17, 2023, the CSRC promulgated Trial Administrative Measures of the Overseas Securities Offering and Listing by Domestic Companies, or the Overseas Listing Trial Measures, and relevant five supporting guidelines, together as the New Overseas Listing Rules, which became effective on March 31, 2023. According to the New Overseas Listing Rules, PRC domestic companies that seek to offer and list securities in overseas markets, either in direct or indirect means, are required to complete the filing procedure with the CSRC and report relevant information. The New Overseas Listing Rules provide that if the issuer meets the following criteria at the same time, the overseas securities offering and listing conducted by such issuer will be deemed as an indirect overseas offering subject to the filing procedures as set forth under the New Overseas Listing Rules: (i) 50% or more of any of the issuer’s operating revenue, total profit, total assets or net assets as documented in its audited consolidated financial statements for the most recent fiscal year is accounted for by domestic companies; and (ii) the issuer’s business activities are substantially conducted in mainland China, or its principal place(s) of business are located in mainland China, or the majority of senior managers in charge of its business operations and management are PRC citizens or domiciled in mainland China. According to the New Overseas Listing Rules, we shall file with the CSRC within three (3) business days after our first submission of listing application documents overseas, and if we apply for the CSRC to postpone to publicize our filing information, we shall report to the CSRC within three (3) business days since our first public filing day. Furthermore, we shall also report to the CSRC with the offering after the overseas offering finished. The New Overseas Listing Rules also require subsequent overseas securities offering in the same overseas market to be filed within three (3) business days after the completion of such subsequent offering, and subsequent reports to be filed with the CSRC on material events within three (3) business days after the occurrence and public disclosure of such material events, such as change of control, investigations or sanctions imposed by overseas securities regulatory agencies or other competent authorities, change of listing status or transfer of listing segment or voluntary or forced delisting of the issuer who have completed overseas offerings and listings.

On the same day, the CSRC also held a press conference for the release of the New Overseas Listing Rules and issued the Notice on Administration for the Filing of Overseas Offering and Listing by Domestic Companies (the “Overseas Listing Notice). Under the Overseas Listing Notice, if company (i) has already completed overseas listing; or (ii) has already obtained the approval for the offering or listing from overseas securities regulators or exchanges but has not completed such offering or listing before effective date of the New Overseas Listing Rules and also completes the offering or listing before September 30, 2023, such company will be considered as an “existing listed company” and is not required to make any filing until it conducts a new offering in the future. If a company has already submitted offering and listing applications but has not obtained the approvals from overseas securities regulators or exchanges, such company shall choose to make its filing with the CSRC at a reasonable time but before the completion of the offering/listing. Companies that have already obtained CSRC approval for overseas listing or offering can continue its process during the valid term of the CSRC approval without additional filing, and shall make the filing pursuant to the New Overseas Listing Rules if they do not complete the offering or listing before the expiration of the original approval from CSRC.

We are listing in overseas OTC market and not transferring Offering and Listing from Overseas OTC Market to Overseas Stock Exchange currently. According to the CSRC Guidelines of Regulatory Rules, we are not subjected to the Trial Administrative Measures of Overseas Securities Offering and Listing by Domestic Companies, or the Trial Measures, which became effective on March 31, 2023.

SUMMARY OF THE OFFERING

The following is a summary of the shares being offered by the selling shareholders:

Common stock offered by selling shareholders	Up to 10,000,000 shares of common stock. This represents an aggregate of 13% of our outstanding common stock. (1)

Common stock outstanding prior to the offering	76,809,533 shares

Common stock outstanding after the offering	76,809,533 shares

Terms of the Offering	The Selling Shareholders will determine when and how they will sell the common stock offered in this prospectus. as more fully provided in the Plan of Distribution section. of this prospectus commencing Page 38

Use of proceeds	We are not selling any shares of the common stock covered by this prospectus. As such, we will not receive any of the offering proceeds from the registration of the. shares of Common Stock covered by this prospectus.

Risk factors	The Common Stock offered hereby involves a high degree of risk and should not be purchased by investors who cannot afford the loss of their entire investment. See “Risk Factors” beginning on page 10.

OTC Pink Trading Symbol	“AOAO”

(1) Based on 76,809,533 shares of common stock outstanding as of September 30, 2024

RISK FACTORS

Investing in our common stock involves a high degree of risk. You should carefully consider the following risks, together with all of the other information contained in this Registration Statement, including our consolidated financial statements and related notes, before making a decision to invest in our common stock. Any of the following risks could have an adverse effect on our business, operating results, financial condition and prospects, and could cause the trading price of our common stock to decline, which would cause you to lose all or part of your investment. Our business, operating results, financial condition and prospects could also be harmed by risks and uncertainties not currently known to us or that we currently do not believe are material.

We consider the following to be the material risks for an investor regarding our common stock. Our Company should be viewed as a high-risk investment and speculative in nature. An investment in our common stock may result in a complete loss of the invested amount. An investment in our common stock is highly speculative, and should only be made by persons who can afford to lose their entire investment in us. You should carefully consider the following risk factors and other information in this Registration Statement before deciding to become a holder of our common stock. If any of the following risks actually occur, our business and financial results could be negatively affected to a significant extent.

Risks Related to Our Business and Industry

The Company’s projects are concentrated in the South of China, in particular Guangdong Province, and any material change pertaining to Guangdong Province may materially and adversely affect the Company’s business, results of operations and profitability

The Company was founded and is based in Shenzhen City Guangdong Province, there were thirteen contracts under construction, all the projects located at Guangdong Province (that including twenty-one cities) during the year ended March 31,2023 and a new project located at Guangxi Province during the year ended March 31,2024 The revenue derived from projects located in Guangdong Province during the year ended March 31,2023. and the majority of the revenue derived from projects located in Guangdong Province and minority from Guangxi Province for the year ended March 31, 2024. Given the Company’s concentration in revenue from Guangdong Province, the Company’s business is highly subject to the economic conditions and government policies which affect the Company’s business, results of operations and profitability.

The Company’s business operates on a non-recurring and project by project basis, failure to obtain new projects, and uncertainties in achieving objective of annual output, could materially affect the Company’s business and results of operations

The Company’s business operates on a project-by-project basis, as such they are non-recurring in nature. The Company has planned the annual output (represents the value of completed telecommunication engineering services, including accepted and pending acceptance work, for the fiscal year. It does not represent expected revenues.) and profits according to the projects under construction and coming projects (refer to the projects that the Company anticipates opportunities to participate in bidding or tending in the future), in order for the Company to undertake new projects, the Company must either participate in open tendering to compete for project made available by potential customers or await customers to approach the Company to solicit its services. As such, given the non-recurring nature of the Company’s projects, the Director believe that the Company’s future growth and success will depend on the Company’s ability to continue to secure projects. The Company cannot assure you that it will be able to secure projects from the Company’s existing or potential customers. In the event that there is a significant decrease in the number of projects or scale in terms of contract value of the projects awarded by the Company’s customers, the Company’s business and results of operations may be materially and adversely affected. The Company’s current revenue, which is on a non-recurring project basis and sales of third party product, is substantially less than our objective, and that substantial doubt exists regarding our ability to continue as a going concern.

We are heavily dependent on one supplier on the supply of our intelligent products, the loss of which could adversely affect our business, financial condition and results of operations

We are heavily dependent on one supplier “Shenzhen JingMeiJing Technology Co., Ltd” for the supply of our intelligent products. For the fiscal years ended March 31, 2024 and 2023, the supplier accounted for approximately 81% and nil of our total purchases respectively. For the six months ended September 30, 2024 and 2023, the supplier accounted for nil of our total purchases.

We have purchased, and expect to continue to purchase products from the supplier under our purchase agreements with it. Our agreement with the supplier is valid for two years after the products acceptance is qualified. These agreements may be terminated or rescinded earlier by mutual agreements to terminate, or occurrence of force majeure. In the event that we are unable to purchase products upon early termination or expiration of our agreement with the supplier, our business would be harmed.

The unavailability of certain products, delays in the delivery of certain products or the delivery of products that does not meet our specifications could impair our ability to meet customers’ orders. We are also subject to credit risk with respect to our suppliers. If any such suppliers become insolvent, an appointed trustee could potentially ignore the contracts we have in place with such party, resulting in increased charges or the termination of the supply contracts. We may not be able to replace a supplier within a reasonable period of time, on as favorable terms or without disruption to our operations. Any adverse changes to our relationships with suppliers could have a material adverse effect on our image, brand and reputation, as well as on our business, financial condition and results of operations.

We are highly dependent on the service of Ms. Shuhua Liu of the Company and our President, Secretary, Treasurer and Chairman of the Board of Directors

We are highly dependent on the services of Ms. Shuhua Liu, Alpha One Inc. and our Chief Executive Officer. Although Ms. Shuhua Liu spends significant time (seven hours per working day) with the Company and is highly active in our management, she does not devote her full time and attention to the Company. For example: Ms. Shuhua Liu also currently holds management positions at Alpha One Holdings Co., Ltd, she reviewed the management report quarterly and yearly, which took her about half a day monthly to handle the matter.

The Company had operating cash outflows for the years ended March 31, 2024 and 2023, and the Company’s cash flows may deteriorate due to potential mismatches in the time between receipt of payments from the Company’s customers, and payments to the Company’s suppliers, failure to appropriately evaluate the credit profile of our customers and/or delay in settlement of accounts receivable from our customers which may impact its operating cash flow position

The Company relies on its suppliers to provide the necessary labour and materials for its projects, and relies upon the cash inflow from its customers to meet the payment obligations towards its suppliers. The Company’s cash inflows are dependent upon a variety of factors including certification by its customers and the prompt settlement of its invoices. If such payment is delayed, the Company may be required to fund the cost of works for a lengthy period of time until the Company’s payment application is approved and paid for. As at March 31, 2024 and 2023, the Company’s accounts payable, accrued and other payables amounted to $5.66 million and $2.80 million respectively. Whereas for the corresponding dates, the Company’s account receivables amount to $9.75 million and $5.72 million respectively. As at September 30, 2024, the Company’s accounts payable, accrued and other payables amounted to $5.63 million and the net accounts receivable amount to $9.63 million. Nevertheless, even if the Company’s customers settle such payments on time and in full, there can be no assurance that the Company would not experience any significant cash flow mismatch which would affect the Company’s operating cash flow position as the Company may be required to provide prepayments pursuant to the arrangement with its suppliers. For the years ended March 31, 2023 and 2024 and for the six months ended September 30, 2024, the Company would in certain circumstances, depending on the scale of works required, provide its material suppliers with an advance payment of approximately 30% of the contract value as stipulated in the work order. Hence, if the Company undertakes a large number of projects, it would pose significant pressure on its cash flow and the Company may record net operating cash outflow.

Due to uncertainty of the timing of collection, we established an allowance for doubtful accounts based on account analysis and historical collection trends. We established a provision for doubtful receivables when there is objective evidence that the Company may not be able to collect due amounts. The allowance is based on management’s best estimates of specific losses on the exposures and a provision on historical trends of collections. Based on the management of customers’ credit and ongoing relationship, management determines whether any balances outstanding at the end of the period will be deemed uncollectible, both on customer basis and through an aging analysis basis. Delinquent account balances are written-off against the allowance for doubtful accounts after management has determined that the likelihood of collection is not probable. We have $6.25 million and $3.52 million overdues one year (aging over 360 days) as at September 30, 2024 and March 31, 2024 respectively.

We have implemented policies and measures to enhance our credit risk management and improve the collection of overdue or long-outstanding accounts receivable. However, given the nature of our business, we cannot guarantee that our substantial accounts receivable position will not persist.

Any deterioration in the credit profile of our customers or delays in their payments could impact our cash flow. If we are required to rely on bank or other borrowings to meet our liabilities, it could place significant pressure on our operating cash flow. This may lead to adverse effects on our business operations, financial performance, and potential liquidity risks in the future.

Failure to properly estimate the risks, time and cost involved in a project or delays in completion may lead to cost overruns and affect the Company’s financial conditions and profitability

When determining the offer price for its projects, the Company generally adopts a cost-plus pricing model after taking into account factors including, the nature, scale, complexity and location of the relevant project, as well as the estimated material, labour and equipment cost. As such, whether the Company is able to achieve its target profitability in any project is significantly dependent on its ability to accurately estimate and control these costs. The actual time taken and cost involved in implementing the Company’s project may be adversely affected by a number of factors, such as shortage or cost escalation of materials and labor, adverse weather conditions, accidents, and any other unforeseen problems and circumstances. As of the aforesaid factors may give rise to delays in completion of works or cost overruns, which in turn result in a lower profit margin or even a loss for a project, thereby materially and adversely affecting the Company’s financial condition, profitability or liquidity.

The Company’s performance depends on prevailing market conditions and trends in the Telecommunications Infrastructure Services industry, and Infrastructure Digitalisation Solution Services industry and in the overall state of economy in PRC

All of the Company’s operations are based in, and all of the Company’s revenue was derived from the PRC for the years ended March 31, 2023 and 2024, and the Directors expect the Company’s business will continue to be based in the PRC. Accordingly, the Company’s future performance depends on the prevailing market conditions and trends in the telecommunications industry in the PRC. The future growth and level of profitability is likely to depend primarily upon the continued availability of large-scale projects, which will be determined by the interplay of various factors. These factors include, in particular, the PRC government’s policies and initiatives, the spending budgets and patterns of the Company’s customers, and the general conditions and prospects of the PRC economy. If the government authorities adopt regulations that place additional restrictions or burdens on the telecommunications industry, the Company’s customers may be more conservative in their spending budgets, and the demand for Telecommunications Infrastructure Services and Infrastructure Digitalisation Solution Services in the PRC may deteriorate, which in turn materially and adversely affect the Company’s operations and profitability. In addition, the Company’s performance and financial condition also depend on the state of the economy in the PRC. If there is a downturn in the economy of the PRC, the Company’s results of operations and financial position may be adversely affected. In addition to economic factors, social unrest or civil movements may also affect the state of the economy in the PRC, and in such cases, the Company’s operations and financial position may also be adversely affected.

The Company is exposed to claims arising from latent defects that may be caused by itself or its suppliers in the past, the discovery of which may have material negative impact on the Company’s reputation, business and results of operations

The Company may face claims arising from latent defects that might be existing but not yet discovered or developed. Such possible latent defects may be caused by the Company itself or its suppliers in the past. If there are claims against the Company for such latent defects when they are discovered, the Company may be held primarily liable even if the defects are caused by its suppliers without the Company’s fault. Further, due to the passage of time, the Company may be unable to locate the relevant suppliers to hold them accountable, or to procure them to rectify the defect (if it is rectifiable at all), or obtain compensation for any loss or damages caused by such defects. Latent defects may include use of materials not meeting the specifications as stipulated in the relevant contracts, which may not be discovered despite the inspection and acceptance by the customers of the works prior to completion, and remain undiscovered for years after the completion of the relevant project.

In the event that there are any significant claims against the Company by its customers or other party for any latent defects, the Company’s results of operations and financial position may be materially and adversely affected. Even if such latent defects do not involve any non-compliance with laws or regulations, or breach of any contractual obligations on the Company’s part, it may be required to rectify such defects or take preventive or remedial measures, such as conducting reviews, tests or examinations on the works in the past, because of the negative publicity or to prevent the reputation of the Company from being negatively affected. As a result, the Company’s operation, business and results of operations may be materially and adversely affected.

Legal and arbitration proceedings may arise and affect the Company’s business, operations and financial results

The Company may be subject to claims in respect of various matters from its customers, suppliers, workers and other parties concerned with the Company’s projects from time to time. Such claims may include claims for compensation for late completion of works and delivery of substandard works or, claims in respect of personal injuries and labour compensation in relation to the works, for which the Company may have to incur costs to defend itself in legal and arbitration proceedings. If the Company is not successful in defending itself in any proceedings, it may be liable to pay damages. Such payments may be significant, and if fall outside the scope and/or limit of the Company’s insurance coverage or monies retained from its labour suppliers, the Company’s business operations and financial position may be adversely affected.

Legal proceedings can be time-consuming, expensive, and may divert the Company’s management’s attention away from the operation of the Company’s business. Any claims or legal proceedings to which the Company may become a party in the future may have a material and adverse impact on the Company’s business. The Company also need to divert resources and incur extra costs to handle the aforementioned outstanding and potential claims, which could affect the Company’s corporate image and reputation in the telecommunications industry if they were published by the press. If the aforementioned claims were successfully made against the Company, it would result in legal costs and damages to be paid to the claimants, which in turn could materially and adversely affect the Company’s revenue, results of operations and financial position.

Our independent registered public accounting firm has expressed doubt about our ability to continue as a going concern, which may hinder our ability to obtain future financing.

Our audited consolidated financial statements as of March 31, 2024 and 2023 have been prepared under the assumption that we will continue as a going concern. For the six months ended September 30, 2024, we have incurred a net loss of $860,310 and net cash used in operating activities of $1,333,237. Our independent registered public accounting firm has issued a report that included an explanatory paragraph referring to our recurring losses from operations and net capital deficiency and expressing substantial doubt in our ability to continue as a going concern without additional capital becoming available. Our ability to continue as a going concern is dependent upon our ability to obtain additional equity or debt financing, attain further operating efficiencies, collect the accounts receivable, reduce expenditures, and, ultimately, to generate revenue. The financial statements do not include any adjustments that might result from the outcome of this uncertainty.

We rely entirely on the operations of Shenzhen Zhongyun. Any successes or failures of Shenzhen Zhongyun will directly impact our financial condition and may cause your investment to be either positively or negatively impacted.

At present, we share the same business plan as, and rely entirely upon, Shenzhen Zhongyun. Any successes or failures of Shenzhen Zhongyun will directly impact our financial condition and may cause your investment to be either positively or negatively impacted. As such, in the event that the business of operations of Shenzhen Zhongyun were to fail, then our own business would, in turn, fail as well. We would be forced to either drastically alter our business strategy, or we would likely cease operations entirely, which could result in the whole or partial loss of any investments made in the company.

Competition from both large, established industry participants and new market entrants may negatively affect our current and future results of operations.

The domestic competition in the electronic products trading and telecommunication engineering services is quite fierce. We may face the competition challenges in the industry, including price competition, advertising campaign, product introduction and increasing customer service business. If our competitive action has a significant impact on our competitors, it may provoke them against or respond to the action, including the information on price, volume, competitive pattern and outsourcing cost, etc.

There may be potential entrants in our industry, either a new enterprise or an enterprise originally engaged in other industries with a diversified business strategy. Potential entrants will bring new production capacity and require a certain market share. The threat to the industry posed by potential entrants depends on the barriers to entry in the industry and the strong reaction of existing enterprises after entering the new industry. If the enterprises entering the industry are mature in size and technology, they may negatively affect our current and future results of operations.

We face increasingly intense competition in markets in which we operate.

Some of our competitors may have greater financial, sales and marketing, research and development, manpower, or other resources than we do. Some new market entrants may acquire market share by leveraging existing business relationships and acquiring new technologies from third parties. Our competitors may also be more responsive to changes in technologies or customer requirements, or offer similar products or services at lower prices. All of the foregoing factors may intensify market competition, and we may face pressure in product and service pricing and competition for orders. Any adverse or unforeseeable change in our competitive environment may have a material and adverse effect on our business, prospects, results of operation and financial position.

There are uncertainties regarding the interpretation and enforcement of PRC laws and regulations

The Company’s operating subsidiary is principally based in the PRC and is subject to the laws and regulations of the PRC. The PRC legal system is based on statutory laws. Under this system, prior court decisions may be cited for reference but do not have binding precedential effect. Since 1979, the PRC government has been developing a comprehensive legal system and considerable progress has been made in the promulgation of laws and regulations dealing with economic matters, such as corporate organization and governance, property title, foreign investment, commerce, taxation and trade. As these laws and regulation are relatively new and evolving, and because of the limited volume of published cases and judicial interpretations, and the non-binding nature of prior court decisions, the interpretation and enforcement of these laws and regulations involves some uncertainties. Such uncertainties may lead to difficulties in enforcing the Company’s rights and in resolving disputes with any persons and could result in unanticipated costs and liabilities.

The success of our business relies heavily on brand image, reputation, and product quality.

It is important that we maintain and improve the image and reputation of our existing brands and products. Concerns about product quality, even when unsubstantiated, could be harmful to our image and reputation of our brands and products. While we have quality control programs in place, in the event we experienced an issue with product quality, we may experience recalls or liability in addition to business disruption which could further negatively impact brand image and reputation and negatively affect our sales. Our brand image and reputation may also be more difficult to protect due to less oversight and control as a result of the outsourcing of some of our operations. We also could be exposed to lawsuits relating to product liability or marketing or sales practices. Deterioration to our brand equity may be difficult to combat or reverse and could have a material effect on our business and financial results.

Uncertainty about future market prices (interest rates, exchange rates, stock prices and commodity prices) can adversely affect our business.

Market risks can be divided into interest rate risks, exchange rate risks, stock price risks and commodity price risks. These market factors may directly affect our production, or competitors, suppliers or consumers may indirectly affect our business. Our business model may be suppressed if substitutes emerge in the market for our products, which are other products that can achieve the same function. The threat of alternatives is threefold:

1. The competitiveness of substitutes in price;

2. Satisfaction with the quality and performance of substitutes;

3. How easy it is for customers to switch to substitutes.

At present, there is no substitute for the product itself, unless it is an industry substitute or a new technology emerges. For example, the emergence of new energy vehicles or disruptive products. This will have a destructive effect on our sales

We have historically relied, and expect to continue to rely, a large portion of our revenue was generated from our two major customers, and we do not have long-term contract with them. The loss of any of two major customers could significantly harm our business, financial condition and results of operations.

For the years ended March 31, 2023 and 2024, we have four customers and three customers accounted for more than 10% of the Company’s total revenues respectively. For the six months ended September 30, 2023 and 2024, we have three customers and two customers accounted for more than 10% of the Company’s total revenues respectively. Our two major customers accounted for 57% and 56% for the years ended March 31, 2023 and 2024 respectively. Our two major customers accounted for 67% and 92% for the six months ended September 30, 2023 and 2024 respectively. There is no assurance that we would be able to increase the number of customers to reduce our reliance on our two major customers. We do not have long-term sales agreements or other contractual assurances as to future sales of our two major customers except for sales contract related to intelligent products and construction contract for telecommunication projects. The sales are generally concluded on an order -by -order basis under business purchase order. The projects are generally concluded on the winning project.

There is no assurance that our customers will continue to place orders to us; or their future orders will be at a comparative level or on similar terms as in prior years. It is uncertain that we would be able to retain our two major customers or solicit new customers to offset the impact from any loss of such customers. Any reduction in revenue from our existing customers and/or any loss of our two major customers could have a material adverse effect on our profitability and financial performance. As a result, if we fail to successfully attract or retain new or existing two major customers or if existing two major customers run fewer products or services purchase with us, defer or cancel their insertion orders, or terminate their relationship with us altogether, whether through the actions of their agency representatives or otherwise, our business, financial condition and results of operations would be harmed.

An increase in the cost of energy or the cost of environmental regulatory compliance could affect our profitability.

The energy costs could continue to rise, which would result in higher transportation, freight and other operating costs. We may experience significant future increases in the costs associated with environmental regulatory compliance, including fees, licenses and the cost of capital improvements to our operating facilities in order to meet environmental regulatory requirements. Future operating expenses and margins will be dependent on the ability to manage the impact of cost increases. We cannot guarantee that it will be able to pass along increased energy costs or increased costs associated with environmental regulatory compliance to our customers through increased prices.

The requirements of being a public company may strain our resources, divert our management’s attention and affect our ability to attract and retain qualified board members.

As a public company, we are subject to the reporting requirements of the Exchange Act and are required to comply with the applicable requirements of the Sarbanes-Oxley Act, and other applicable securities rules and regulations. Compliance with these rules and regulations have increased our legal and financial compliance costs, made some activities more difficult, time-consuming or costly and increased demand on our systems and resources. Among other things, the Exchange Act requires that we file annual, quarterly and current reports with respect to our business and results of operations and maintain effective disclosure controls and procedures and internal controls over financial reporting. In order to maintain and, if required, improve our disclosure controls and procedures and internal controls over financial reporting to meet this standard, significant resources and management oversight may be required. As a result, management’s attention may be diverted from other business concerns, which could harm our business and results of operations. We may need to hire more employees to comply with these requirements in the future, which will increase our costs and expenses.

We may engage in acquisitions, investments or strategic alliances in the future, which could require significant management attention and materially and adversely affect our business and results of operations.

We may identify strategic partners to form strategic alliances, invest in or acquire additional assets, technologies or businesses that are complementary to our existing business. These investments may involve minority stakes in other companies, acquisitions of entire companies or acquisitions of selected assets.

Any future strategic alliances, investments or acquisitions and the subsequent integration of the new assets and businesses obtained or developed from such transactions into our own may divert management from their primary responsibilities and subject us to additional liabilities. In addition, the costs of identifying and consummating investments and acquisitions may be significant. We may also incur costs and experience uncertainties in completing necessary registrations and obtaining necessary approvals from relevant government authorities in China and elsewhere in the world. The costs and duration of integrating newly acquired assets and businesses could also materially exceed our expectations. Any such negative developments could have a material adverse effect on our business, financial condition, results of operations and cash flow.

We have identified material weaknesses in our disclosure controls and procedures and internal control over financial reporting.

We identified material weaknesses in our internal controls over financial reporting. A material weakness is a deficiency, or a combination of deficiencies, in internal control over financial reporting such that there is a reasonable possibility that a material misstatement of our financial statements will not be prevented or detected on a timely basis.

The material weaknesses identified include (i) the Company did not maintain a functioning independent audit committee and did not maintain an independent board; (ii) the Company had inadequate segregation of duties; and (iii) the Company had an insufficient number of personnel with an appropriate level of U.S. GAAP knowledge and experience and ongoing training in the application of U.S. GAAP and SEC disclosure requirements commensurate with the Company’s financial reporting requirements.

As of this prospectus, we have engaged a finance consulting firm with U.S. GAAP expertise to train our finance team and enhance their understanding of accounting standards and reporting practices. To address segregation of duties and improve oversight, we have increased staffing in our finance department.

We are also planning to establish an independent audit committee and are actively identifying qualified candidates with relevant expertise to oversee financial reporting and internal controls. Additionally, we intend to recruit a financial controller experienced in U.S. GAAP to strengthen financial management and ensure compliance with regulatory requirements.

These initiatives will involve additional costs, including increased salaries and consulting fees. We anticipate fully addressing the identified material weaknesses within approximately one and a half years, contingent on the successful implementation of these measures and the recruitment of qualified personnel.

If not remediated, our failure to establish and maintain effective disclosure controls and procedures and internal control over financial reporting could result in material misstatements in our financial statements and a failure to meet our reporting and financial obligations, each of which could have a material adverse effect on our financial condition and the trading price of our common stock.

An occurrence of a natural disaster, widespread health epidemic or other outbreaks, such as COVID-19, could have a material adverse effect on the Company’s business, financial condition and results of operations.

The Company’s business could be materially and adversely affected by natural disasters or the outbreak of a widespread health epidemic, such as swine flu, avian influenza, severe acute respiratory syndrome (SARS) or COVID-19. The occurrence of a natural disaster or a prolonged outbreak of an epidemic illness, or other adverse public health developments in the PRC could materially disrupt the Company’s business and operations. In particular, the outbreak of COVID-19 which was first reported in late 2019 and spread within the PRC and globally, has caused significant disruption in the economic activities. As the Company’s operations, customers and suppliers are located in the PRC, the outbreak of COVID-19 in the PRC may affect the telecommunications industry, and cause temporary suspension of projects and shortage of labour, materials and equipment and other services, which would severely disrupt the Company’s operations and have a material adverse effect on the Company’s business, financial condition and results of operations. The Company’s operations could also be disrupted if any of its employees or employees of the Company’s labour suppliers were suspected of contacting, or contacted an epidemic disease, since this could require the Company and its labour suppliers to quarantine some, or all of these employees, and disinfect the works sites and facilities used for the Company’s operations. In addition, the Company’s revenue and profitability could also be reduced to the extent if any natural disaster, health epidemic or other virus outbreak harms the overall economy in the PRC. These adverse impacts, if materialize and persist for a substantial period, may significantly and adversely affect the Company’s business operation and financial performance.

Risks Related to Doing Business in China

Certain judgments obtained against us by our officers and directors may not be enforceable

We are a Wyoming corporation but most of our assets are and will be located outside of the United States. Almost all our operations are conducted in the PRC. In addition, all our officers and directors are the nationals and residents of a country other than the United States. Almost all of their assets are located outside the United States. As a result, it may be difficult for you to effect service of process within the United States upon them. It may also be difficult for you to enforce in U.S. courts judgments on the civil liability provisions of the U.S. federal securities laws against us and our officers and directors, since he or she is not a resident in the United States. In addition, there is uncertainty as to whether the courts of the PRC or other jurisdictions would recognize or enforce judgments of U.S. courts.

Introduction of new laws or changes to existing laws by the PRC government may adversely affect our business.

The PRC legal system is a codified legal system made up of written laws, regulations, circulars, administrative directives and internal guidelines. Unlike common law jurisdictions like the U.S., decided cases (which may be taken as reference) do not form part of the legal structure of the PRC and thus have no binding effect on subsequent cases with similar issues and fact patterns. Furthermore, in line with its transformation from a centrally planned economy to a freer market-oriented economy, the PRC government is still in the process of developing a comprehensive set of laws and regulations. As the legal system in the PRC is still evolving, laws and regulations or the interpretation of the same may be subject to further changes. Such changes, if implemented, may adversely affect our business operations and may reduce our profitability.

Uncertainties in the interpretation and enforcement of PRC laws and regulations could limit the legal protections available to you and us.

The PRC legal system is a civil law system based on written statutes. Unlike the common law system, prior court decisions may be cited for reference but have limited precedential value.

Our PRC subsidiaries are foreign-invested enterprises and are subject to laws and regulations applicable to foreign-invested enterprises as well as various Chinese laws and regulations generally applicable to companies incorporated in China. However, since these laws and regulations are relatively new and the PRC legal system continues to rapidly evolve, the interpretations of many laws, regulations and rules are not always uniform and enforcement of these laws, regulations and rules involves uncertainties.

From time to time, we may have to resort to administrative and court proceedings to enforce our legal rights. However, since PRC administrative and court authorities have significant discretion in interpreting and implementing statutory and contractual terms, it may be more difficult to evaluate the outcome of administrative and court proceedings and the level of protection we enjoy than in more developed legal systems. Furthermore, the PRC legal system is based in part on government policies and internal rules, some of which are not published on a timely basis or at all, and which may have a retroactive effect. As a result, we may not be aware of our violation of any of these policies and rules until sometime after the violation. Such uncertainties, including uncertainty over the scope and effect of our contractual, property (including intellectual property) and procedural rights, and any failure to respond to changes in the regulatory environment in China could materially and adversely affect our business and impede our ability to continue our operations.

Uncertainties exist with respect to the interpretation and implementation of the newly enacted PRC Foreign Investment Law and its implementing rules and how they may impact our business, financial condition and results of operations.

The MOFCOM published a discussion draft of the proposed PRC Foreign Investment Law in January 2015, or the 2015 Draft FIL, according to which, variable interest entities that are controlled via contractual arrangements would also be deemed as foreign-invested entities, if they are ultimately “controlled” by foreign investors. In March 2019, the PRC National People’s Congress promulgated the PRC Foreign Investment Law, and in December 2019, the State Council promulgated the Implementing Rules of PRC Foreign Investment Law, or the Implementing Rules, to further clarify and elaborate the relevant provisions of the PRC Foreign Investment Law. The PRC Foreign Investment Law and the Implementing Rules both became effective from January 1, 2020 and replaced the major previous laws and regulations governing foreign investments in the PRC. Pursuant to the PRC Foreign Investment Law, “foreign investments” refer to investment activities conducted by foreign investors (including foreign natural persons, foreign enterprises or other foreign organizations) directly or indirectly in the PRC, which include any of the following circumstances: (i) foreign investors setting up foreign-invested enterprises in the PRC solely or jointly with other investors, (ii) foreign investors obtaining shares, equity interests, property portions or other similar rights and interests of enterprises within the PRC, (iii) foreign investors investing in new projects in the PRC solely or jointly with other investors, and (iv) investment in other methods as specified in laws, administrative regulations, or as stipulated by the State Council. The PRC Foreign Investment Law and the Implementing Rules do not introduce the concept of “control” in determining whether a company would be considered as a foreign-invested enterprise, nor do they explicitly provide whether the VIE structure would be deemed as a method of foreign investment. However, the PRC Foreign Investment Law has a catch-all provision that includes into the definition of “foreign investments” made by foreign investors in China in other methods as specified in laws, administrative regulations, or as stipulated by the State Council, and as the PRC Foreign Investment Law and the Implementing Rules are newly adopted and relevant government authorities may promulgate more laws, regulations or rules on the interpretation and implementation of the PRC Foreign Investment Law, the possibility cannot be ruled out that the concept of “control” as stated in the 2015 Draft FIL may be embodied in, or the VIE structure may be deemed as a method of foreign investment by, any of such future laws, regulations and rules. Our current corporate structure does not contain any VIE structures in the PRC and neither we nor any of our subsidiaries have any current intention establishing any VIEs in the PRC in the future. As of the date of this prospectus, substantially all of our business is conducted by our PRC Subsidiaries, primarily including Shenzhen Zhongyun Communication Technology Co., Ltd.

Pursuant to the FIL, the State Council shall promulgate or approve a list of special administrative measures for access of foreign investments, which is referred to as “the Negative List.” The FIL grants treatment to foreign investors and their investments at the market access stage which is no less favorable than that given to domestic investors and their investments, except for the investments of foreign investors in industries deemed to be either “restricted” or “prohibited” on the Negative List. The FIL provides that foreign investors shall not invest in the “prohibited” industries on the Negative List and shall meet such requirements as stipulated by the Negative List for making investment in “restricted” industries on the Negative List. Accordingly, the National Development and Reform Commission, or the NDRC, and the Ministry of Commerce promulgated the Negative List (2021), which took effect on January 1, 2022, and the NDRC and the Ministry of Commerce promulgated the Encouraged Industry Catalogue for Foreign Investment (2022 version), or the 2022 Encouraged Industry Catalogue, which took effect on January 1, 2023. Industries not listed on the Negative List (2021) are generally open for foreign investments unless specifically restricted by other PRC laws. We are engaged in the trading of intelligent products and the construction of telecommunication engineering services not including the restricted category “telecommunication value-added service”. Since our current business is not on the 2021 Negative List, to the best of our knowledge, it will not create any material adverse effect to our Company’s business.

On September 6, 2024, the Chinese government released the latest “Special Administrative Measures (Negative List) for Foreign Investment Access (2024 Edition)”, which will take effect on November 1, 2024. The new Negative list has been reduced from 31 items to 29 items, and some specific restrictions in the manufacturing field have been removed including the deletion of the requirement that “publication printing must be controlled by Chinese parties” and the deletion of prohibiting foreign investment in the production of traditional Chinese medicine decoction pieces processing technology and products with confidential prescriptions of proprietary Chinese medicines. This marks the complete removal of restrictions on foreign investment access in the manufacturing field. Our current and planned business is neither on the 2021 Negative List Edition nor on the 2024 Edition. Thus, to the best of our knowledge, we believe the 2024 Negative List will not create any material adverse effect to the Company’s business.

If future laws, administrative regulations or provisions mandate further actions to be taken by companies with respect to existing structure or we expand our business activities, we may face substantial uncertainties as to whether we can complete such actions in a timely manner, or at all. Failure to take timely and appropriate measures to cope with any of these or similar regulatory compliance challenges could materially and adversely affect our current corporate structure, business, financial condition and results of operations.

China’s political climate and economic conditions, as well as changes in government policies, laws and regulations which may be quick with little advance notice, could have a material adverse effect on our business, financial condition and results of operations.

Our principal executive offices are located in China and our sole executive officer and director is a resident of and is physically located in and has significant ties to China. Our business, financial condition, results of operations and prospects are subject, to a significant extent, to economic, political and legal developments in China. For example, as a result of recent proposed changes in the cybersecurity regulations in China that would require certain Chinese technology firms to undergo a cybersecurity review before being allowed to list on foreign exchanges, this may have the effect of further narrowing the list of potential businesses in China’s consumer, technology and mobility sectors that we intend to focus on for our business combination or the ability of the combined entity to list in the United States.

China’s economy differs from the economies of most developed countries in many respects, including the amount of government involvement, level of development, growth rate, control of foreign exchange and allocation of resources. While the PRC economy has experienced significant growth in the past two to three decades, growth has been uneven, both geographically and among various sectors of the economy. Demand for target services and products depends, in large part, on economic conditions in China. Any slowdown in China’s economic growth may cause our potential customers to delay or cancel their plans to purchase our services and products, which in turn could reduce our net revenues.

Although China’s economy has been transitioning from a planned economy to a more market-oriented economy since the late 1970s, the PRC government continues to play a significant role in regulating industry development by imposing industrial policies. The PRC government also exercises significant control over China’s economic growth through allocating resources, controlling the incurrence and payment of foreign currency-denominated obligations, setting monetary policy and providing preferential treatment to particular industries or companies. Changes in any of these policies, laws and regulations may be quick with little advance notice and could adversely affect the economy in China and could have a material adverse effect on our business and the value of our common stock.

The PRC government has implemented various measures to encourage foreign investment and sustainable economic growth and to guide the allocation of financial and other resources. However, we cannot assure you that the PRC government will not repeal or alter these measures or introduce new measures that will have a negative effect on us, or more specifically, we cannot assure you that the PRC government will not initiate possible governmental actions or scrutiny to us, which could substantially affect our operation and the value of our common stock may depreciate quickly. China’s social and political conditions may change and become unstable. Any sudden changes to China’s political system or the occurrence of widespread social unrest could have a material adverse effect on our business and results of operations.

American investors may have difficulty enforcing judgments against our Company and Officers.

We are a Wyoming corporation and most of our assets are and will be located outside of the United States. Almost all of our operations will be conducted in China. In addition, our officers and directors are nationals and residents of a country other than the United States. All of their assets are located outside the United States. As a result, it may be difficult for investors to effect service of process within the United States upon them. It may also be difficult to enforce court judgments on the civil liability provisions of the U.S. federal securities laws against our Company and our officer and director, since he is not a resident in the United States. In addition, there is uncertainty as to whether the courts of Hong Kong or other Asian countries would recognize or enforce judgments of U.S. courts.

Any failure or perceived failure by our PRC subsidiaries to comply with the Anti-Monopoly Guidelines for Internet Platforms Economy Sector and other PRC anti-monopoly laws and regulations may result in governmental investigations or enforcement actions, litigation or claims against us and could have an adverse effect on our business, financial condition and results of operations.

The PRC anti-monopoly enforcement agencies have strengthened enforcement under the PRC Anti-Monopoly Law in the recent years. On December 28, 2018, the SAMR issued the Notice on Anti-monopoly Enforcement Authorization, pursuant to which its province-level branches are authorized to conduct anti-monopoly enforcement within their respective jurisdictions. On September 11, 2020, the Anti-Monopoly Commission of the State Council issued Anti-monopoly Compliance Guideline for Operators, which requires operators to establish anti-monopoly compliance management systems under the PRC Anti-Monopoly Law to manage anti-monopoly compliance risks. On February 7, 2021, the Anti-Monopoly Commission of the State Council published Anti-Monopoly Guidelines for the Internet Platform Economy Sector that specified circumstances under which an activity of an internet platform will be identified as monopolistic act as well as concentration filing procedures for business operators. According to the PRC Anti-Monopoly Law, if a business operator carries out a concentration in violation of the law, the relevant authority shall order the business operator to terminate the concentration, dispose of the shares or assets or transfer the business within a specified time limit, or take other measures to restore the pre-concentration status, and impose a fine of up to RMB500,000. On March 12, 2021, the SAMR published several administrative penalty cases in connection with concentration of business operators that violated PRC Anti-Monopoly Law in the internet sector.

On October 23, 2021, the Standing Committee of the National People’s Congress issued a discussion draft of the amended Anti-Monopoly Law, which proposes to increase the fines for illegal concentration of business operators to “no more than ten percent of its last year’s sales revenue if the concentration of business operator has or may have an effect of excluding or limiting competition; or a fine of up to RMB5 million if the concentration of business operator does not have an effect of excluding or limiting competition.” The draft also proposes for the relevant authority to investigate transaction where there is evidence that the concentration has or may have the effect of eliminating or restricting competition, even if such concentration does not reach the filing threshold. On December 24, 2021, nine government agencies, including the NDRC, jointly issued the Opinions on Promoting the Healthy and Sustainable Development of Platform Economy, which provides that, among others, monopolistic agreements, abuse of dominant market position and illegal concentration of business operators in the field of platform economy will be strictly investigated and punished in accordance with the relevant laws.

At the present time, we have a relatively small-scale supply chain platform operations based on our market share in our product markets and other factors. We are not an operator with a dominant market position, and our operating activity cannot constitute an anti-monopoly behavior that abuses our dominant market position. We have not entered into monopoly agreements prohibited by the Anti-Monopoly Law with competing business operators. As of the date of the prospectus, we have not received a notification from the anti-monopoly regulatory authority requiring us to file the concentration of undertakings or received any related administrative penalties. We believe that we are in compliance with the currently effective PRC anti-monopoly laws in all material aspects. Nevertheless, if the PRC regulatory authorities identify any of our activities as monopolistic under the PRC Anti-Monopoly Law or the Anti-Monopoly Guidelines for the Internet Platform Economy Sector, we may be subject to investigations and administrative penalties, and therefore materially and adversely affect our financial conditions, operations and business prospects. If we are required to take any rectifying or remedial measures or are subject to any penalties, our reputation and business operations may be materially and adversely affected.

The Chinese government may intervene or influence our operations in accordance with laws and regulations, or may exert more control over offerings conducted overseas and/or foreign investment in China-based issuers, which could result in a material change in our operations and/or the value of our securities.

The Chinese government has significant oversight and discretion over the conduct of our business and may intervene or influence our operations as the government deems appropriate to further regulatory, political and societal goals. Recent regulatory developments in China may subject us to additional regulatory review, including the cybersecurity review, data security assessment and disclosure requirement, expose us to government interference, or otherwise restrict our ability to offer securities and raise capitals outside China, all of which could materially and adversely affect the business of us and the value of our securities. We cannot rule out the possibility that it will in the future release regulations or policies regarding our industry that could adversely affect our business, financial condition and results of operations. Furthermore, the PRC government has recently indicated an intent to exert more oversight and control over securities offerings and other capital markets activities that are conducted overseas and foreign investment in China-based companies like us. Any such intervention in or influence on our business operations or action to exert more oversight and control over securities offerings and other capital markets activities, once taken by the PRC government, could adversely affect our business, financial condition and results of operations and the value of our securities, or significantly limit or completely hinder our ability to offer or continue to offer securities to investors and cause the value of such securities to significantly decline or in extreme cases, become worthless.

Any actions by the Chinese government to exert more oversight and control over offerings that are conducted overseas and/or foreign investment in China-based issuers could significantly limit or completely hinder our ability to offer or continue to offer securities to investors and cause the value of such securities to significantly decline or be worthless

The Chinese government has exercised and continues to exercise substantial control over virtually every sector of the Chinese economy through regulation and state ownership. Our ability to operate in China may be harmed by changes in its laws and regulations. The central or local governments of these jurisdictions may impose new, stricter regulations or interpretations of existing regulations that would require additional expenditures and efforts on our part to ensure our compliance with such regulations or interpretations. Accordingly, government actions in the future, including any decision not to continue to support recent economic reforms and to return to a more centrally planned economy or regional or local variations in the implementation of economic policies, could have a significant effect on economic conditions in China or particular regions thereof.

As such, our business in China is subject to various government and regulatory interferences. The Chinese government may intervene or influence our operations in accordance with laws and regulations, or may exert more control over offerings conducted overseas and/or foreign investment in China-based issuers, which could result in a material change in our operations and/or the value of the securities we are registering for sale. Further, any actions by the Chinese government to exert more oversight and control over offerings that are conducted overseas and/or foreign investment in China-based issuers could significantly limit or completely hinder our ability to offer or continue to offer securities to investors and cause the value of such securities to significantly decline or be worthless. We could be subject to regulation by various political and regulatory entities, including various local and municipal agencies and government sub-divisions. The Company may incur increased costs necessary to comply with existing and newly adopted laws and regulations or penalties for any failure to comply. Our operations could be adversely affected, directly or indirectly, by existing or future laws and regulations relating to its business or industry, which could result in a material change in our operation and the value of our securities.

Furthermore, given recent statements by the Chinese government indicating an intent to exert more oversight and control over offerings that are conducted overseas, although we are currently not required to obtain permission from any of the PRC federal or local government and has not received any denial to list on the U.S. exchange, it is uncertain when and whether we will be required to obtain permission from the PRC government to list and trade on U.S. exchanges in the future, and even when such permission is obtained, whether it will be denied or rescinded, which could significantly limit or completely hinder our ability to offer or continue to offer our securities to investors and cause the value of our securities to significantly decline or be worthless.

Governmental control of currency conversion may affect the value of your investment.

The PRC government imposes controls on the convertibility of the RMB into foreign currencies and, in certain cases, the remittance of currency out of China. We receive substantially all of our revenues in RMB. Under our current corporate structure, our income will currently only be derived from dividend payments from our PRC subsidiaries. Shortages in the availability of foreign currency may restrict the ability of our PRC subsidiaries to remit sufficient foreign currency to pay dividends or other payments to us, or otherwise satisfy their foreign currency denominated obligations. Under existing PRC foreign exchange regulations, payments of current account items, including profit distributions, interest payments and expenditures from trade-related transactions can be made in foreign currencies without prior approval from SAFE by complying with certain procedural requirements. However, approval from appropriate government authorities is required where RMB is to be converted into foreign currency and remitted out of China to pay capital expenses such as the repayment of loans denominated in foreign currencies. The PRC government may also at its discretion restrict access in the future to foreign currencies for current account transactions. If the foreign exchange control system prevents us from obtaining sufficient foreign currency to satisfy our currency demands, we may not be able to pay dividends in foreign currencies to our security-holders.

Failure to comply with the Individual Foreign Exchange Rules relating to the overseas direct investment or the engagement in the issuance or trading of securities overseas by our PRC resident stockholders may subject such stockholders to fines or other liabilities.

Our ability to conduct foreign exchange activities in the PRC may be subject to the interpretation and enforcement of the Implementation Rules of the Administrative Measures for Individual Foreign Exchange promulgated by SAFE in January 2007 (as amended and supplemented, the “Individual Foreign Exchange Rules”). Under the Individual Foreign Exchange Rules, any PRC individual seeking to make a direct investment overseas or engage in the issuance or trading of negotiable securities or derivatives overseas must make the appropriate registrations in accordance with SAFE provisions. PRC individuals who fail to make such registrations may be subject to warnings, fines or other liabilities.

SAFE promulgated the Notice on Relevant Issues Relating to Domestic Resident’s Investment and Financing and Roundtrip Investment through Special Purpose Vehicles, or Notice 37, in July 2014 that requires PRC residents or entities to register with SAFE or its local branch in connection with their establishment or control of an offshore entity established for the purpose of overseas investment or financing. In addition, such PRC residents or entities must update their SAFE registrations when the offshore special purpose vehicle undergoes material events relating to material change of capitalization or structure of the PRC resident itself (such as capital increase, capital reduction, share transfer or exchange, merger or spin off).

We may not be fully informed of the identities of all our beneficial owners who are PRC residents. For example, because the investment in or trading of our shares will happen in an overseas public or secondary market where shares are often held with brokers in brokerage accounts, it is unlikely that we will know the identity of all of our beneficial owners who are PRC residents. Furthermore, we have no control over any of our future beneficial owners and we cannot assure you that such PRC residents will be able to complete the necessary approval and registration procedures required by the Individual Foreign Exchange Rules.

To our knowledge, our beneficial owners, who are PRC residents, have not completed the Notice 37 registration. And we cannot guarantee that all or any of the shareholders will complete the Notice 37 registration prior to the closing of this Offering. Failure by any such shareholders or beneficial owners to comply with Notice 37 could restrict our overseas or cross-border investment activities, limit our PRC subsidiaries’ ability to make distributions or pay dividends or affect our ownership structure, which could adversely affect our business and prospects. In addition, the PRC resident shareholders who fail to complete Notice 37 registration may subject to fines less than RMB50,000.

As these foreign exchange and outbound investment related regulations are relatively new and their interpretation and implementation has been constantly evolving, it is unclear how these regulations, and any future regulation concerning offshore or cross-border investments and transactions, will be interpreted, amended and implemented by the relevant government authorities.

It is uncertain how the Individual Foreign Exchange Rules will be interpreted or enforced and whether such interpretation or enforcement will affect our ability to conduct foreign exchange transactions. Because of this uncertainty, we cannot be sure whether the failure by any of our PRC resident stockholders to make the required registration will subject our PRC subsidiaries to fines or legal sanctions on their operations, delay or restriction on repatriation of proceeds of our securities offerings into the PRC, restriction on remittance of dividends or other punitive actions that would have a material adverse effect on our business, results of operations and financial condition.

Under the Enterprise Income Tax Law, we may be classified as a “Resident Enterprise” of China. Such classification will likely result in unfavorable tax consequences to us and our non-PRC stockholders.

China passed an Enterprise Income Tax Law (the “EIT Law”), as most recently amended and effective on December 29, 2018, and the related Implementation Regulations, as amended and effective on April 23 2019. Under the EIT Law, an enterprise established outside of China with “de facto management bodies” within China is considered a “resident enterprise,” meaning that it can be treated in a manner similar to a Chinese enterprise for enterprise income tax purposes. The implementing rules of the EIT Law define de facto management as “substantial and overall management and control over the production and operations, personnel, accounting, and properties” of the enterprise.

On April 22, 2009, the State Administration of Taxation of China issued the Notice Concerning Relevant Issues Regarding Cognizance of Chinese Investment Controlled Enterprises Incorporated Offshore as Resident Enterprises pursuant to Criteria of de facto Management Bodies, or the Notice, further interpreting the application of the EIT Law and its implementation to offshore entities controlled by a Chinese enterprise or Company. Pursuant to the Notice, an enterprise incorporated in an offshore jurisdiction and controlled by a Chinese enterprise or Company will be classified as a “non-domestically incorporated resident enterprise” if (i) its senior management in charge of daily operations reside or perform their duties mainly in China; (ii) its financial or personnel decisions are made or approved by bodies or persons in China; (iii) its substantial assets and properties, accounting books, corporate stamps, board and stockholder minutes are kept in China; and (iv) at least half of its directors with voting rights or senior management are often resident in China. A resident enterprise would be subject to an enterprise income tax rate of 25% on its worldwide income and must pay a withholding tax at a rate of 10% when paying dividends to its non-PRC stockholders.

Because we have limited capital, we may need to raise additional capital in the future by issuing debt or equity securities, the terms of which may dilute our current investors and/or reduce or limit their liquidation or other rights.

We may require additional capital to acquire a business. We may not be able to obtain additional capital when required. Future business development activities, as well as administrative expenses such as salaries, insurance, general overhead, legal and compliance expenses, and accounting expenses will require a substantial amount of additional capital.

The terms of securities we issue in future capital raising transactions may be more favorable to new investors, and may include liquidation preferences, superior voting rights or the issuance of other derivative securities, which could have a further dilutive effect on or subordinate the rights of our current investors. Any additional capital raised through the sale of equity securities will likely dilute the ownership percentage of our shareholders. Additionally, any debt securities we issue would likely create a liquidation preference superior that of our current investors and, if convertible into shares of Common Stock, would also pose the risk of dilution.

We may be unable to obtain necessary financing if and when required.

Our ability to obtain financing, if and when necessary, may be impaired by such factors as the capital markets (both in general and in the particular industry or industries in which we may choose to operate), our limited operating history and current lack of operations, the national and global economies, and the condition of the market for microcap securities. Further, economic downturns such as the current global depression caused by the COVID-19 pandemic may increase our requirements for capital, particularly if such economic downturn persists for an extended period of time or after we have acquired an operating entity, and may limit or hinder our ability to obtain the funding we require. If the amount of capital we are able to raise from financing activities, together with any revenues we may generate from future operations, is not sufficient to satisfy our capital needs, we may be required to discontinue our development or implementation of a business plan, cancel our search for business opportunities, cease our operations, divest our assets at unattractive prices or obtain financing on unattractive terms. If any of the foregoing should happen, our shareholders could lose some or all of their investment.

Because we are dependent upon Shuhua Liu, our Chief Executive Officer and director to manage and oversee our Company, the loss of her could adversely affect our plan and results of operations.

We currently have director and officer, Shuhua Liu, who manages the Company and is presently evaluating a viable plan for our future operations. We will rely solely on her judgment in connection with selecting a target company and the terms and structure of any resulting business combination. The loss of our Chief Executive Officer, could delay or prevent the achievement of our business objectives, which could have a material adverse effect upon our results of operations and financial position.

Further, because Mr. Shuhua Liu serves as Chief Executive Officer and sole director and also holds a controlling interest in the Company’s Common Stock, our other shareholders will have limited ability to influence the Company’s direction or management.

In addition, although not likely, the officers and directors of an acquisition candidate may resign upon completion of a combination with their business. The departure of a target’s key personnel could negatively impact the operations and prospects of our post-combination business. The role of a target’s key personnel upon the completion of the transaction cannot be ascertained at this time. Although we contemplate that certain or all members of a target’s management team may remain associated with the target following a change of control thereof, there can be no assurance that all of such target’s management team will decide to remain in place. The loss of key personnel, either before or after a business combination and including management of either us or a combined entity could negatively impact the operations and profitability of our business.

Risks Related to Our Common Stock

There is a limited market for our common stock, which may make it difficult for holders of our common stock to sell their stock.

Our common stock currently trades on the OTC Pink Markets under the symbol “AOAO”. Accordingly, there can be no assurance as to the liquidity of any markets that may develop for our common stock, the ability of holders of our common stock to sell our common stock, or the prices at which holders may be able to sell our common stock. Further, many brokerage firms will not process transactions involving low price stocks, especially those that come within the definition of a “penny stock.” If we cease to be quoted, holders of our common stock may find it more difficult to dispose of, or to obtain accurate quotations as to the market value of our common stock, and the market value of our common stock would likely decline.

The trading price of our Common Stock is likely to be volatile, which could result in substantial losses to investors.

The trading price of our common stock is likely to be volatile and could fluctuate widely due to factors beyond our control. This may happen because of broad market and industry factors, including the performance and fluctuation of the market prices of other companies with business operations located mainly in China that have listed their securities in the United States. In addition to market and industry factors, the price and trading volume for our common stock may be highly volatile for factors specific to our own operations, including the following:

	●	variations in our revenues, earnings and cash flow;
	●	announcements of new investments, acquisitions, strategic partnerships or joint ventures by us or our competitors;
	●	announcements of new offerings, solutions and expansions by us or our competitors;
	●	changes in financial estimates by securities analysts;
	●	detrimental adverse publicity about us, our brand, our services or our industry;
	●	additions or departures of key personnel;
	●	release of lock-up or other transfer restrictions on our outstanding equity securities or sales of additional equity securities; and
	●	potential litigation or regulatory investigations.

Any of these factors may result in large and sudden changes in the volume and price at which our common stock will trade.

In the past, shareholders of public companies have often brought securities class action suits against those companies following periods of instability in the market price of their securities. If we were involved in a class action suit, it could divert a significant amount of our management’s attention and other resources from our business and operations and require us to incur significant expenses to defend the suit, which could harm our results of operations. Any such class action suit, whether or not successful, could harm our reputation and restrict our ability to raise capital in the future. In addition, if a claim is successfully made against us, we may be required to pay significant damages, which could have a material adverse effect on our financial condition and results of operations.

We are subject to be the penny stock rules which will make shares of our common stock more difficult to sell.

We are subject now and may continue to be subject in the future, to the SEC’s “penny stock” rules if our shares of common stock sell below $5.00 per share. Penny stocks generally are equity securities with a price of less than $5.00. The penny stock rules require broker-dealers to deliver a standardized risk disclosure document prepared by the SEC which provides information about penny stocks and the nature and level of risks in the penny stock market. The broker-dealer must also provide the customer with current bid and offer quotations for the penny stock, the compensation of the broker-dealer and its salesperson, and monthly account statements showing the market value of each penny stock held in the customer’s account. The bid and offer quotations, and the broker-dealer and salesperson compensation information must be given to the customer orally or in writing prior to completing the transaction and must be given to the customer in writing before or with the customer’s confirmation.

In addition, the penny stock rules require that prior to a transaction, the broker dealer must make a special written determination that the penny stock is a suitable investment for the purchaser and receive the purchaser’s written agreement to the transaction. The penny stock rules are burdensome and may reduce purchases of any offerings and reduce the trading activity for shares of our common stock. As long as our shares of common stock are subject to the penny stock rules, the holders of such shares of common stock may find it more difficult to sell their securities.

If we become directly subject to the scrutiny, criticism and negative publicity involving U.S. listed Chinese companies, we may have to expend significant resources to investigate and resolve the matter which could harm our business, operations and reputations, which could result in a loss of your investment in our common stock.

U.S. public companies that have substantially all of their operations in China, have been the subject of intense scrutiny, criticism and negative publicity by investors, financial commentators and regulatory agencies, such as the SEC. Much of the scrutiny, criticism and negative publicity has centered around financial and accounting irregularities, a lack of effective internal controls over financial accounting, inadequate corporate governance policies or a lack of adherence thereto and, in some cases, allegations of fraud. As a result of the scrutiny, criticism and negative publicity, the publicly traded stock of many U.S. listed Chinese companies has sharply decreased in value and, in some cases, has become virtually worthless. Many of these companies are now subject to shareholder lawsuits and SEC enforcement actions and are conducting internal and external investigations into the allegations. It is not clear what effect this sector-wide scrutiny, criticism and negative publicity will have on our business. If we become the subject of any unfavorable allegations, whether such allegations are proven to be true or untrue, we will have to expend significant resources to investigate such allegations and/or defend the Company. This situation may be a major distraction to our management. If such allegations are not proven to be groundless, our company and business operations will be severely hampered and your investment in our shares could be rendered worthless.

We currently intend to retain most, if not all, of our available funds and any future earnings to fund the development and growth of our business. As a result, we do not expect to pay any cash dividends in the foreseeable future. Therefore, you should not rely on an investment in our common stock as a source for any future dividend income.

Our board of directors has complete discretion as to whether to distribute dividends., Even if our board of directors decides to declare and pay dividends, the timing, amount and form of future dividends, if any, will depend on our future results of operations and cash flow, our capital requirements and surplus, the amount of distributions, if any, received by us from our subsidiaries, our financial condition, contractual restrictions and other factors deemed relevant by our board of directors. Accordingly, the return on your investment in our common stock will likely depend entirely upon any future price appreciation of our common stock. There is no guarantee that our common stock will appreciate in value, or even maintain the price at which you purchased the common stock. You may not realize a return on your investment in our common stock and you may even lose your entire investment in our common stock.

If relations between the United States and China worsen, our stock price may decrease and we may have difficulty accessing the U.S. capital markets.

At various times during recent years, the United States and China have had disagreements over political and economic issues. Controversies may arise in the future between these two countries. Any political or trade conflicts between the United States and China could adversely affect the market price of our common stock and our ability to access U.S. capital markets.

You may experience difficulties in effecting service of legal process, enforcing foreign judgments or bringing actions in China against us or our management named in the prospectus based on foreign laws.

We are a company incorporated under the laws of the United States and we conduct substantially all of our operations in China. In addition, all our senior executive officers reside within China for a significant portion of the time and most are PRC nationals. As a result, it may be difficult for you to effect service of process upon us or those persons inside mainland China. It may also be difficult for you to enforce in U.S. courts judgments obtained in U.S. courts based on the civil liability provisions of the U.S. federal securities laws against us and our officers and directors as none of them currently resides in the United States or has substantial assets located in the United States. In addition, there is uncertainty as to whether the courts of the PRC would recognize or enforce judgments of U.S. courts against us or such persons predicated upon the civil liability provisions of the securities laws of the United States or any state.

The recognition and enforcement of foreign judgments are provided for under the PRC Civil Procedures Law. PRC courts may recognize and enforce foreign judgments in accordance with the requirements of the PRC Civil Procedures Law based either on treaties between China and the country where the judgment is made or on principles of reciprocity between jurisdictions. China does not have any treaties or other forms of written arrangement with the United States that provide for the reciprocal recognition and enforcement of foreign judgments. In addition, according to the PRC Civil Procedures Law, the PRC courts will not enforce a foreign judgment against us or our directors and officers if they decide that the judgment violates the basic principles of PRC laws or national sovereignty, security or public interest. As a result, it is uncertain whether and on what basis a PRC court would enforce a judgment rendered by a court in the United States.

USE OF PROCEEDS

We will not receive any proceeds from the sales of shares of our common stock by the selling shareholders.

We will pay for the expenses of this offering, except that the selling shareholders will pay any broker discounts or commissions or equivalent expenses and expenses of selling shareholder’s legal counsel applicable to any sale of the shares.

DETERMINATION OF OFFERING PRICE

The selling shareholders may sell some or all of their shares from time to time in the principal market on which the stock is traded at the fixed price of $1.000. The offering price bears no relationship to our assets, book value, earnings or any other customary investment criteria. We will not receive any proceeds from the sale of the shares by the selling shareholders. The shares may be sold directly by the selling shareholders to or through brokers or dealers, directly to purchasers or through agents designated from time to time.

DESCRIPTION OF BUSINESS

Corporate History

Alpha One Inc. (“we”, “us”, the “Company” or “AOAO”) was originally incorporated in State of Nevada on May 5, 2006 under the name Microscints, Inc. On October 26, 2009 the Company’s name was changed from Microscints, Inc. to World Mobile Holdings, Inc. On March 19, 2020, the Company redomiciled from the State of Nevada to the State of Wyoming. On September 10, 2021, the Company’s name was changed from World Mobile Holdings, Inc. to Alpha One Inc, The Company had been engaged in the various business since its incorporation. The Company was not successful and discontinued the majority of its operation by December 31, 2016. Beginning from January 2017, the Company plans on providing business services and financing to emerging growth entities.

On February 8, 2021, the previously issued 100,000,000 shares of common stock were canceled in connection with changes in the Company’s strategic direction.

On September 10, 2021, the Company effectuated a 100-for-1 reverse stock split, which resulted in a new total of 1,359,447 shares of common stock.

On February 8, 2022, the Company convert 500,000 of its Series A Preferred Stock into common stock with a ratio of 100 for 1.

On March 23, 2023, Alph One Inc. (“AOAO,” or the “Company”) completed its merger with Zhongyun (BVI). (“Zhongyun BVI”) and Zhongyun BVI’s wholly-owned subsidiary, Shenzhen Zhongyun Communication Technology Co., Ltd” (“Shenzhen Zhongyun”), pursuant to the terms of a definitive share exchange agreement dated March 23, 2023.

Upon completion of the merger, all of the outstanding shares of Zhongyun BVI’s common stock were exchanged for 25,450,086 shares of common stock of AOAO. Prior to the merger, Shuhua Liu and her spuse directly and indirectly obtained the total 49.65% controlled of AOAO, and 50% indirectly controlled of Zhongyun BVI by Zhongyun Global International Group Limited. Shuhua Liu is the sole director of AOAO and Zhongyun BVI. As AOAO and Zhongyun BV were under common control at the time of the share exchange, the transaction is accounted for as a combination of entities under common control in a manner similar to the pooling-of-interests method of accounting. Following the Merger, Shuhua Liu and her spouse directly and indirectly obtained the total 49.77% controlled of AOAO. Immediately after completion of such share exchange, the Company has a total of 76,809,533 issued and outstanding shares of common stock, with authorized common shares of 450,000,000.

On November 16, 2023, the former director and CEO Zhuo Wang transferred 19,890,000 shares to Sun Horn Limited, 4,239,742 shares to Shuhua Liu and 1,370,258 shares Xinli Chen for free.

Business Overview

We are a telecommunications infrastructure services and solutions provider, operating through our core subsidiary, Shenzhen Zhongyun Communication Technology Co., Ltd. Our operations focus on two key areas: telecommunications infrastructure services and the development of digital solutions for project management.

Through Shenzhen Zhongyun Communication, we specialize in building, installing, and maintaining complex communication networks, including base stations for 4G and 5G infrastructure, fiber-optic cable installation, and wireless network deployment. We also provide advanced solutions for transmission network development, data center (IDC) construction, and core network optimization. Our end-to-end services ensure comprehensive support across the entire telecommunications lifecycle, offering solutions from tower and antenna maintenance to network monitoring and emergency response services.

Over recent years, the business has maintained steady growth, with our Intelligent Products segment consistently being the largest contributor. This trend reflects the increasing demand for cutting-edge telecommunications solutions and our strong positioning in the market. Additionally, the diversification of our revenue streams from both product sales and construction services ensures resilience and adaptability, supporting our long-term strategic objectives and financial health.

Our customers

Our customers consist primarily of telecommunications operators and equipment manufacturers seeking infrastructure services to support their communication networks. Our customers rely on us to deliver critical solutions such as fiber-optic cable installations, wireless network deployment, data center (IDC) services, and 5G infrastructure development. These clients come from various sectors, including telecommunication, technology, and data service industries.

In addition, we serve construction and project management companies through our software solutions subsidiary. These customers use our integrated platforms to manage project workflows, financial processes, and IT infrastructure.

We ensure that our customers receive tailored and professional services that meet the rigorous demands of their industries, enhancing their operational efficiency and ensuring scalability. The expertise and quality of our services help solidify long-term relationships and attract new businesses to our growing network.

Telecommunications Infrastructure Services

Shenzhen Zhongyun specializes in providing comprehensive telecommunication infrastructure services and communication engineering solutions. We serve telecommunications operators and equipment manufacturers, offering a wide range of services that position us as a key player in the industry. Our business is divided into two main sectors: telecommunications infrastructure and related services.

●

Core Network Installation:

	○	Base Station Construction: We are crucial in building base stations that support wireless communication networks, especially 4G and 5G infrastructure.
	○	Wireless Network Deployment: We install and deploy wireless networks, ensuring high-speed connectivity in both urban and rural areas.
	○	Fiber Optic Cable Laying: We lay the foundation for high-speed, high-bandwidth communication networks through fiber optic cable installations, essential for both local and global data transmission.

●

Network Development:

	○	Data Center (IDC) Construction: We build and maintain data centers to ensure efficient data processing and storage for telecommunication providers.
	○	Core and Aggregation Layer Equipment Installation: We focus on constructing critical layers of transmission networks, vital for data routing and network scalability.

●

Maintenance and Optimization:

	○	Tower and Antenna Maintenance: We provide ongoing maintenance for communication towers, antennas, and associated systems like GPS and environmental control.
	○	Network Optimization: We offer services to optimize 5G infrastructure and other networks, enhancing efficiency and performance.

●

Specialized Telecommunication Services:

○

Broadband Installation for Enterprises and Residences: Setting up high-speed broadband for corporate and residential customers.

Telecommunication Data Center Monitoring: Offering surveillance and operational support for data centers, ensuring uptime, security, and reliability.

Intellectual Property

Protection of our intellectual property is a strategic priority for our business. We rely primarily on a combination of trademark, patent, copyright, computer software and trade secret laws to establish and protect our proprietary rights.

We currently have the following ten registered patents in China:

Patent Number	Authorization Date	Expiration Date	Patent
CN202110194040.4	2022-08-19	2041-02-21	A Security Method Based on 5G Network Communication Base Stations
CN202223408295.5	2023-03-28	2032-12-16	A Multifunctional Terminal Information Collection Device for Base Stations
CN202320173842.1	2023-05-30	2033-01-31	Antenna Performance Testing Device for Base Station Equipment
CN202320039739.8	2023-05-30	2033-01-03	Communication Base Station Transceiver Platform
CN202320149705.4	2023-08-08	2033-01-13	A Base Station Antenna Automated Testing Device
CN202310135608.4	2023-11-03	2043-02-09	Relay Protection Communication System and Method Based on 5G
CN202211626361.8	2024-02-23	2042-12-16	A 5G Accelerator Card Communication Module, Accelerator Card, and Communication Transmission Method
CN202322759712.9	2024-06-04	2033-10-16	A 5G communication mobile base station maintenance equipment
CN202323123673.X	2024-06-11	2033-11-20	A Big Data Signal Transmission Base Station
CN202323420749.5	2024-09-10	2033-12-15	A steel structure base for 5G communication base stations

We currently have the following five copyrights in China:

Copyright Number	First Issue Date	Registration Date	Copyright
2023SR0640643	2022-01-20	2023-06-13	Zhongyun Communication Network Communication Management System V1.0
2023SR0648418	2022-03-19	2023-06-13	Zhongyun Communication Base Station Metering and Control System V1.0
2023SR0654779	2022-04-20	2023-06-14	Zhongyun Communication 5G Terminal Protocol Control System V1.0
2023SR0660028	2022-05-01	2023-06-14	Zhongyun Communication Base Station Communication Positioning Monitoring System V1.0
2023SR0320415	2022-08-21	2023-03-13	Zhongyun Communication 5G Security Monitoring System V1.0

We currently have the following registered licenses in China:

License Number	Issue Date	Expiration Date	Department issued
D244429374	2023-12-13	2024-12-31	Guangdong Provincial Department of Housing and Urban Rural Development
DL34414110	2022-08-02	2027-08-02	Shenzhen Futian District Housing and Construction Bureau

We currently have the following registered Internet domain names in China:

Internet domain names		Expiration Date
zygogo.com.cn		2029-05-07
alpha-aoao.com		2026-09-16

The Company’s Revenue Model

The company’s revenue model for construction services operates primarily through structured project engagements and long-term service agreements, ensuring a balance between short-term project income and ongoing service-based revenue. The Company’s revenue model for wholesaling intelligent products is primarily through sales contracts. The Company will recognize its sales revenue upon the products received by its customers, where the ownership of the products has been transferred from the Company to the customers.

Project-Based Contracts: Revenue is generated through customized contracts for specific infrastructure projects, such as building base stations, laying fiber-optic cables, and constructing data centers. These contracts are typically milestone-driven, meaning the company is compensated at various stages of project progress—planning, installation, testing, and final delivery.

Ongoing Service Agreements: The company extends its revenue potential by offering comprehensive after-sales services and maintenance contracts. The service agreements cover essential functions like network optimization, equipment maintenance, and emergency response, ensuring continuous customer engagement.

Product Sales: A significant portion of revenue is derived from hardware and intelligent communication device sales through large-scale contracts. Payments are structured with down payments, followed by full settlement upon delivery, ensuring upfront capital and secured revenue after project completion.

Integrated Solutions: The company enhances value by packaging hardware sales with long-term service agreements, creating comprehensive client solutions that drive both immediate sales and sustained service revenue, strengthening customer loyalty.

Future Plans

The company’s strategic vision focuses on leveraging its expertise in telecommunications infrastructure to drive significant growth both domestically and internationally. By capitalizing on emerging opportunities in smart city development, AI-driven technologies, and global telecommunications, the company aims to expand its footprint and enhance its market position.

Domestically, the company will strengthen its presence in key cities within the Greater Bay Area, including Shenzhen, Guangzhou, Zhuhai, and Zhongshan. The focus will align with national initiatives, particularly in the development of 5G networks and expanding fiber-optic infrastructure to meet the increasing demands for high-speed connectivity.

On the international front, the company plans to extend its operations under China’s “Belt and Road” initiative, targeting strategic markets across Asia, Europe, and other regions. This will help position the company as a leading player in the global telecommunications and digital services industry.

The company is also committed to the growing demand for smart city infrastructure. It plans to deploy advanced telecommunications networks and contribute to the development of smarter, more connected urban environments.

In addition, the company will continue to expand its project management offerings by enhancing its platform with big data, and cloud computing capabilities to better serve the construction and project management industries. The ongoing investment in research and development will fuel innovation across telecommunications infrastructure and smart city solutions, ensuring the company remains at the forefront of industry advancements and competitive growth.

In the broader education and technology sectors, the government will increase its investment in smart technologies, supporting growth in technological products and solutions. As a result, the company plans to expand the sales of offerings, collaborate with more technological companies, and explore new business opportunities in emerging sectors.

Employees

We have a total of 25 full-time employees across key departments. Our General Manager’s Office has one individual overseeing the company, supported by four employees in the Finance Department and one in the Financing Department. The Administration Department comprises five team members, while one employee manages the Audit Department. Our R&D Department includes five specialists focusing on innovation and technology development. The largest Company, the Project Department, employs eight individuals to manage our wide-ranging projects. This team structure enables us to operate efficiently and meet our strategic goals.

LEGAL PROCEEDINGS

There are no pending legal proceedings to which we are a party or in which any director, officer or affiliate of ours, any owner of record or beneficially of more than 5% of any class of our voting securities, or security holder is a party adverse to us or has a material interest adverse to us.

MANAGEMENT’S DISCUSSION AND ANALYSIS

You should read the following discussion and analysis of our financial condition and results of operations in conjunction with the section entitled “Selected Financial Data” and our financial statements and the related notes included elsewhere in this prospectus. This discussion contains forward-looking statements that involve risks and uncertainties about our business and operations. Our actual results and the timing of selected events may differ materially from those anticipated in these forward-looking statements as a result of various factors, including those we describe under “Risk Factors” and elsewhere in this prospectus.

Business Overview

Alpha One Inc. (“AOAO” or the “Company”) is a US holding company incorporated in Nevada on May 5, 2006. On March 19, 2020, the Company redomiciled from the State of Nevada to the State of Wyoming. We conduct our business through our PRC subsidiary “Shenzhen Zhongyun Communication Technology Co., Ltd” (“Shenzhen Zhongyun”), which is telecommunications infrastructure services and solutions provider, including hardware procurement, installation and maintenance, software application, software and hardware management and other related services, Shenzhen Zhongyun Communication Technology Co., Ltd” a company incorporated and based in PRC. With the mission to become a leading domestic and world-class comprehensive solution provider for the application of AI intelligent communication systems.

Results of Operations

	Years Ended March 31,
	2024			2023			Change
Net revenues	$	23,549,144		$	6,494,640		$	17,054,504		263	%
Cost of revenues		(20,411,893	)		(5,191,960	)		15,219,933		293	%
Gross profit		3,137,251			1,302,680			1,834,571		141	%

Operating expense		(1,073,829	)		(602,751	)		471,078		78	%
Other expense		(892	)		(8,006	)		(7,114	)	(89	)%
Other income		6,658			23,296			(16,638	)	(71	)%
Interest income		91			108			(17	)	(16	)%
Interest expense		(323,528	)		(267,925	)		55,603		21	%
Income taxes		(500,201	)		(117,884	)		382,317		324	%
Net income	$	1,245,550		$	329,518		$	916,032		278	%

Net Revenues

Net revenues totaled $23,549,144 for the year ended March 31, 2024, an increase of $17,054,504, or 263%, as compared to the revenue for the year ended March 31, 2023. The increase in net revenues was mainly due to a significantly increase in sales of intelligent products $17,580,582 from the third parties, coverage of 75% of total net revenues for the year ended March 31, 2024. The sales of intelligent products were not steady and seasonal, mainly affected by the education procurement policy, which has two bidding and procurement processes with local education bureau per year. One is every March, the other is every October. Our customers will take part in the bidding and procurement processes. Additionally, there is a timing gap between when the company makes downpayments to suppliers and when it receives downpayments from customers. Therefore, there are known uncertainty whether the company could maintain such increment in revenue.

Looking ahead, our intelligent products rely on network connectivity via a dedicated app, which is supported by our 5G infrastructure project (our telecommunication project). As we continue expanding our telecommunications capabilities, we anticipate potential synergies between our intelligent product offerings and 5G infrastructure, which could create new revenue streams and business opportunities in the future.

Cost of Revenues

Cost of revenues totaled $20,411,893 for the year ended March 31, 2024, an increase of $15,219,933, or 293%, as compared to for the year ended March 31, 2023. The increase in cost of revenue was due to the increase of revenue.

Gross Profit

Gross profit was $3,137,251 and $1,302,680 for the years ended March 31, 2024 and 2023 respectively. Gross profit increased $1,834,571 for the year ended March 31, 2024 primarily due to the increase in sales of intelligent products.

Operating Expenses

Operating expenses totaled $1,073,829 for the year ended March 31, 2024, an increase of $471,078, or 78%, as compared to the year ended March 31, 2023. The increase was primarily due to the increase in directors and staffs’ salary, consulting and professional expense incurred in 2024 in connection with the business operation.

Interest Expenses

Interest expenses total $323,528 for the year ended March 31, 2024, an increase of $55,603, or 21%, as compared to the year ended March 31, 2023. The increase was primarily due to the increase in the short term and long-term loan from bank.

Income Tax

Income tax was $500,201 and $117,884 for the year ended March 31, 2024 and 2023 respectively. Income tax increased $382,317 or 324% for the year ended March 31, 2024 primarily due to the increase in income before taxation.

Net income

Net income totaled $1,245,550 for the year ended March 31, 2024, an increase of $916,032, of 278%, as compared to the net income of $329,518 for the year ended March 31, 2023. The increase was primarily due to the net revenue increase.

Liquidity and Capital Resources

Working Capital

	Years Ended March 31,
	2024		2023		Change
Total current assets	$	11,588,952	$	6,350,938	$	5,238,014
Total current liabilities		9,070,491		5,363,972		3,706,519
Working capital	$	2,518,461	$	986,966	$	1,531,495

As of March 31, 2024, we had total current assets of $11,588,952 consisting of cash on hand and at banks of $383,682, of which $383,682 held in RMB, net accounts receivable of $9,746,035, net prepayments and other receivables of $1,149,225, and due from related party of $310,010, compared to total current assets of $6,350,938 as of March 31, 2023 consisting of cash on hand and at banks of $329,994, of which $329,994 held in RMB. The increase was mainly due to the increase in accounts receivable, prepayments and other receivables in 2024. We had current liabilities of $9,070,491, mainly consisting of accounts payable of $1,513,854, accrued expenses and other payables of $4,153,740, current portion of bank and other borrowings of $1,351,345 (incurred by the PRC operating subsidiary, the aggregate outstanding principal balances was $1,489,843), current portion of operating lease liabilities of $11,066, income tax payable of $653,168 and due to related parties of $1,376,439 compared to total current liabilities of $5,363,972 as of March 31, 2023.

As a holding company with no material operations of our own, we conduct our operations primarily through our PRC subsidiaries in China. We are permitted under PRC laws and regulations to provide funding to our PRC subsidiaries in China through capital contributions or loans, subject to the approval from governmental authorities and limitation of amount, or we may make additional capital contributions to our PRC subsidiaries in China. As of March 31, 2024, current portion of bank and other borrowings of $1,351,345 out of total balances $1,489,843 incurred by our PRC operating subsidiaries. These debt agreements may restrict the ability of our PRC subsidiaries to transfer their net assets to us through cash dividends which their assets are a security to bank borrowings. We may rely on dividends paid by our PRC subsidiaries to fund cash and financing requirements. Any limitation on the ability of our PRC subsidiaries to pay dividends to us could have a material adverse effect on our ability to conduct our business and to pay dividends to shareholders of our ordinary shares. The ability of our subsidiaries in China to make dividends or other cash payments to us is subject to various restrictions under PRC laws and regulations.

Cash Flows

	Years Ended March 31,
	2024			2023			Change
Cash flows used in operating activities	$	(694,052	)	$	(2,128,379	)	$	(1,434,327	)
Cash flows used in investing activities		(30,162	)		(151,920	)		(121,758	)
Cash flows provided by financing activities		832,159			2,450,094			(1,617,935	)
Effect of exchange rate changes on cash and cash equivalents		(54,257	)		8,357			(62,614	)
Net changes in cash and cash equivalents	$	53,688		$	178,152		$	(124,464	)

Cash Flow from Operating Activities

Cash flow used in operating activities for the year ended March 31, 2024 was $694,052 as compared to the amount of $2,128,379 used in operating activities for the year ended March 31, 2023, reflecting a decrease of $1,434,327. The decrease in net cash used in operating activities was mainly due to the fact that the increase from accrued expenses and other payables impact on cash flows.

Cash Flow from Investing Activities

Cash flow used in investing activities was $30,162 and $151,920 for the years ended March 31, 2024 and 2023, respectively. The decrease in net cash flow used in investing activities was mainly due to the decrease of acquisition of Property and equipment.

Cash Flow from Financing Activities

Cash flow provided by financing activities was $832,159 and $2,450,094 for the years ended March 31, 2024 and 2023, respectively. The decrease in net cash provided by financing activities was mainly due to the decrease in net proceeds of bank borrowings and capital injection.

Results of Operations for the three and six months ended September 30, 2024

	Three months Ended September 30,
	2024			2023			Change
Net revenues	$	153,297		$	1,873,136		$	(1,719,839	)	(92	)%
Cost of revenues		(258,656	)		(1,314,050	)		1,055,394		80	%
Gross profit		(105,359	)		559,086			(664,445	)	(119	)%

Operating expense		(388,418	)		(351,297	)		(37,121	)	(11	)%
Other expense, net		(120,407	)		(231,517	)		111,110		48	%
Income taxes		23,715			26,613			(2,898	)	(11	)%
Net (loss) income	$	(590,469	)	$	2,885		$	(593,354	)	(20567	)%

	Six months Ended September 30,
	2024			2023			Change
Net revenues	$	472,142		$	3,399,276		$	(2,927,134	)	(86	)%
Cost of revenues		(575,089	)		(1,960,401	)		1,385,312		71	%
Gross profit		(102,947	)		1,438,875			(1,541,822	)	(107	)%

Operating expense		(643,599	)		(526,907	)		(116,692	)	(22	)%
Other expense, net		(158,380	)		(248,989	)		90,609		36	%
Income taxes		44,616			(150,113	)		194,729		130	%
Net income	$	(860,310	)	$	512,866		$	(1,373,176	)	(268	)%

Net Revenues

Net revenues totaled $153,297 for the three months ended September 30, 2024, reflecting a decrease of $1,719,839, or 92%, as compared to revenue of $1,873,136 for the three months ended September 30, 2023. The decrease in net revenues was mainly due to a decrease in sales of intelligent products from the third parties.

Net revenues totaled $472,142 for the six months ended September 30, 2024, reflecting a decrease of $2,927,134, or 86%, as compared to revenue of $3,399,276 for the six months ended September 30, 2023. The decrease in net revenues was mainly due to a decrease in sales of intelligent products from the third parties.

Cost of Revenues

Cost of revenues totaled $258,656 for the three months ended September 30, 2024, reflecting a decrease of $1,055,394, or 80%, as compared to cost of revenues of $1,314,050 for the three months ended September 30, 2023. The decrease in cost of revenue was due to decrease of the revenue described above.

Cost of revenues totaled $575,089 for the six months ended September 30, 2024, reflecting a decrease of $1,385,312, or 71%, as compared to cost of revenues of $1,960,401 for the six months ended September 30, 2023. The decrease in cost of revenue was due to decrease of the revenue described above.

Gross (Loss) Profit

Gross loss was $105,359 for the three months ended September 30, 2024, reflecting a decrease of $664,445, or 119%, as compared to gross profit of $559,086 for the three months ended September 30, 2023. The decreased was primarily due to the decrease of revenues described above.

Gross loss was $102,947 for the six months ended September 30, 2024, reflecting a decrease of $1,541,822, or 107%, as compared to gross profit of $1,438,875 for the six months ended September 30, 2023. The decreased was primarily due to the decrease of revenues described above.

Operating Expenses

Operating expenses totaled $388,418 for the three months ended September 30, 2024, reflecting an increase of $37,121, or 11%, as compared to operating expenses of $351,297 the three months ended September 30, 2023. The increase was primarily due to the increase in directors and staffs’ salary, software maintenance fee, consulting and professional expense incurred in 2024 in connection with the business operation.

Operating expenses totaled $643,599 for the six months ended September 30, 2024, reflecting an increase of $116,692, or 22%, as compared to operating expenses of $526,907 the six months ended September 30, 2023. The increase was primarily due to the increase in directors and staffs’ salary, software maintenance fee, consulting and professional expense incurred in 2024 in connection with the business operation.

Net (Loss) Income

Net loss totaled $590,469 for the three months ended September 30, 2024, reflecting a decrease of $593,354, or 20567%, from net income of $2,885 for the three months ended September 30, 2023. The decrease was primarily due to the decrease of revenue and the increase of operating expenses.

Net loss totaled $860,310 for the six months ended September 30, 2024, reflecting a decrease of $1,373,176, or 268%, from net income of $512,866 for the six months ended September 30, 2023. The decrease was primarily due to the decrease of revenue and the increase of operating expenses.

Liquidity and Capital Resources

Going concern.

The Company had incurred a net loss of $860,310 and the operating cash outflows of $1,333,237 for the six months ended September 30, 2024. The Company had incurred a net loss of $590,469 for the three months ended September 30, 2024. These factors raise substantial doubt about the Company’s ability to continue as a going concern within one year after the date the financial statements are issued. The Company’s financial statements do not include any adjustments that might result from the outcome of this uncertainty should we be unable to continue as a going concern.

Management estimates that the current funds on hand (means cash at bank and on hand) will be sufficient to continue operations through the next 12 months. The continuation of the Company as a going concern is dependent upon (1) there was $6.25 million overdue one year (aging over 360 days) as of September 30, 2024, the company will accelerate the collection of accounts receivable, $2.5 million will be received as of June 30, 2025, and $2.79 million to be collected in the next 12 months that based on the agreed extra payment term on the ongoing contracts. From October 2024 to January 2025, the Company has collected $1.15 million out of the $2.5 million, and regards of well-known reputation of customers, we assume that we will be able to successfully collect such amounts within the extra payment term; (2) the continued financial support from its stockholders or its ability to obtain external financing, the company has only obtained verbal funding commitments from stockholders, which are non-binding and may not be fulfilled; (3) further to make the cost controlling; and (4) implement management’s business plan to extend its operations and generate sufficient revenues to meet its obligations. While the Company believes in the viability of its strategy to increase sales volume and in its ability to raise additional funds, there can be neither any assurances to that effect, nor any assurance that the Company will be successful in securing sufficient funds to sustain the operations. In long-term, the continuation of the Company as a going concern is dependent upon (i) further implement management’s business plan to extend its operations and generate sufficient revenues to meet its obligations; (ii) Shorten customer payment terms and extend supplier payment terms; and (iii) maintain to obtain the revolving credit lines and loans with lower interest from the bank, the company has obtained the revolving credit lines amounting to $1,648,076 (equivalent to RMB11,807,142.84), which bears interest rate from 3% to 16.7% for 12 months. The Company will obtain more lower revolving credit lines to replace the higher interest rate bank loan and the collection of accounts receivable to settle the revolving credit lines and loans in the future.

Management believes that the actions presently being taken to obtain additional funding and implement its strategic plan provides the opportunity for the Company to continue as a going concern.

Based on our current operating plan, we believe that the revolving loans, together with our existing cash at bank and on hand and anticipated cash flow from operations, will be sufficient to meet our anticipated working capital requirements and capital expenditures for at least the next 12 months following the date of September 30, 2024.

Working Capital

	September 30, 2024		March 31, 2024		Change
Total current assets	$	11,492,802	$	11,588,952	$	(96,150	)
Total current liabilities		9,834,282		9,070,491		763,791
Working capital	$	1,658,520	$	2,518,461	$	(859,941	)

As of September 30, 2024, we had total current assets of $11,492,802 consisting of cash on hand and at bank of $3,225, of which $3,225 held in RMB, net accounts receivable of $9,632,028, net prepayments and other receivables of $1,706,841 and due from related party of $150,708, as compared to total current assets of $11,588,952 as of March 31, 2024. The decrease was mainly reflected in lesser cash and cash equivalents. As of September 30, 2024, we had current liabilities of $9,834,282 consisting of current portion of operating lease liabilities of $1,647, accounts payable of $1,208,325, accrued expenses and other payables of $4,426,149, current portion of bank borrowings of $1,433,657 and due to related parties of $2,084,224, as compared to total current liabilities of $9,070,491 as of March 31, 2024. The increase was mainly reflected in higher amounts due to related parties.

The Company’s net loss of $860,310 for the six months ended September 30, 2024, compared to the net income of $512,866 for the six months ended September 30, 2023.

As a holding company with no material operations of our own, we conduct our operations primarily through our PRC subsidiaries in China. We are permitted under PRC laws and regulations to provide funding to our PRC subsidiaries in China through capital contributions or loans, subject to the approval from governmental authorities and limitation of amount, or we may make additional capital contributions to our PRC subsidiaries in China. As of September 30, 2024, current portion of bank and other borrowings of $1,433,657 out of total balances $1,522,445 incurred by our PRC operating subsidiaries. These debt agreements may restrict the ability of our PRC subsidiaries to transfer their net assets to us through cash dividends which their assets are a security to bank borrowings. We may rely on dividends paid by our PRC subsidiaries to fund cash and financing requirements. Any limitation on the ability of our PRC subsidiaries to pay dividends to us could have a material adverse effect on our ability to conduct our business and to pay dividends to shareholders of our ordinary shares. The ability of our subsidiaries in China to make dividends or other cash payments to us is subject to various restrictions under PRC laws and regulations.

Cash Flows

	Six months ended September 30,
	2024			2023			Change
Cash flows used in operating activities	$	(1,333,237	)	$	(516,978	)	$	(816,259	)
Cash flows used in investing activities		-			(28,959	)		(28,959	)
Cash flows provided by financing activities		856,768			360,839			495,929
Effect of exchange rate changes on cash and cash equivalents		96,012			(107,020	)		203,032
Net changes in cash and cash equivalents	$	(380,457	)	$	(292,118	)	$	(88,339	)

Cash Flow from Operating Activities

Cash flow used in operating activities for the six months ended September 30, 2024 was $1,333,237 as compared to the amount of $516,978 used in operating activities for the six months ended September 30, 2023, reflecting an increment of $816,259. The increase in net cash used in operating activities was mainly reflected on the net loss in 2024.

Cash Flow from Investing Activities

Cash flow used in investing activities was nil and $28,959 for the six months ended September 30, 2024 and 2023, respectively. The decrease in net cash flow used in investing activities was mainly reflected on no purchase of property and equipment in 2024.

Cash Flow from Financing Activities

Cash flow provided by financing activities was $856,768 and $360,839 for the six months ended September 30, 2024 and 2023, respectively. The increase in net cash used in financing activities was mainly reflected on higher advanced from related parties in 2024.

INDUSTRY OVERVIEW

This section includes market and industry data that we have developed from publicly available information; various industry publications and other published industry sources and our internal data and estimates. Although we believe the publications and reports are reliable, we have not independently verified the data. Our internal data, estimates and forecasts are based upon information obtained from trade and business organizations and other contacts in the market in which we operate and our management’s understanding of industry conditions.

As of the date of the preparation of this section, these and other independent government and trade publications cited herein are publicly available on the Internet without charge. Upon request, the Company will also provide copies of such sources cited herein.

Telecom Infrastructure Engineering in China

China’s telecommunications infrastructure sector is one of the most dynamic and rapidly expanding industries in the world, fueled primarily by the accelerated deployment of 5G networks, broadband expansion, and increasing investments in digital infrastructure. As China pushes towards digital transformation, telecom infrastructure engineering plays a critical role in the construction and maintenance of the systems that support high-speed internet, mobile communications, and data services across the country.

The telecommunications infrastructure market in China was valued at approximately $31.62 billion in 2024 (https://www.linkedin.com/pulse/china-telecom-network-infrastructure-market-evaluation-ioxnf/), reflecting its vast scale and robust growth trajectory. This figure is expected to grow significantly, to a projected strong compound annual growth rate (CAGR) of 14.49% over the period from 2024 to 2031 driven by China’s ambitious plans to expand its 5G network and fiber-optic infrastructure.

The telecommunications infrastructure market in the world has experienced substantial growth in recent years. It is projected to increase from $94.1 billion in 2023 to $100.52 billion in 2024, achieving a CAGR of 6.8%. In 2028, it is expected to continue its strong growth trajectory, reaching $130.72 billion with the same CAGR. (https://www.thebusinessresearchcompany.com/report/telecom-network-infrastructure-global-market-report). The anticipated growth during this forecast period is driven by the deployment and expansion of 5G networks, the rise of edge computing, increased Internet of Things connectivity, growing concerns over network security, further cloud and data center expansion, advancements in artificial intelligence, and ongoing network optimization efforts.

The deployment of 5G networks has been particularly transformative, with China leading globally in both the number of 5G connections and base stations. By 2025, China is projected to have more than 3 million 5G base stations, reflecting its commitment to creating a globally competitive digital ecosystem. (https://techblog.comsoc.org/2021/11/17/china-plans-to-triple-the-number-of-5g-base-stations-by-end-of-2025/#:~:text=China%20aims%20to%20have%20about%203.64%20million,5G%20base%20stations%20for%20every%2010%2C000%20people). This expansion, which also includes a strong focus on fiber-optic networks, is essential to support the country’s digital infrastructure and the growing demand for high-speed connectivity across all sectors.

Key Growth Drivers

●	5G Deployment

The telecom infrastructure market in China is experiencing robust growth, primarily driven by the rapid deployment of 5G technology. The Chinese government has prioritized this rollout as part of its national strategy to enhance digital infrastructure, leading to significant investments in building millions of 5G base stations. The substantial investments made by major telecom operators such as China Mobile, China Telecom, and China Unicom have been pivotal in this transformation, facilitating the rapid adoption of 5G services and creating a competitive landscape that encourages further infrastructure development.

●	Broadband and Fiber-Optic Network Expansion

In addition to 5G, China continues to expand its fiber-optic broadband networks to provide high-speed internet access to more remote and rural areas. This push aligns with the government’s digital inclusion initiatives, which are key to improving regional economic opportunities and enhancing public services such as education, healthcare, and governance. The fiber-optic network requires extensive engineering expertise for laying cables, building data centers, and ensuring seamless connectivity across vast distances.

●	Data Centers

With the rise of cloud computing and increasing internet usage, there is growing demand for data centers across China. The surge in mobile data traffic due to the proliferation of smartphones and connected devices is another significant market driver. As of early 2021, there were approximately 1.61 billion mobile connections in China, indicating a penetration rate exceeding the country’s population (https://www.worlddata.info/asia/china/telecommunication.php). This massive increase in mobile connectivity has led to a corresponding rise in data consumption, with mobile data traffic reportedly increasing by 40% during the COVID-19 pandemic. The emphasis on improving network capacity and reliability is essential for meeting consumer expectations and supporting the growing number of Internet of Things.

Telecom infrastructure engineering is critical to designing, constructing, and maintaining these data centers, which house servers that support everything from consumer internet applications to large-scale enterprise systems. As companies such as Huawei, Alibaba, and Tencent continue to expand their cloud services, the demand for infrastructure engineering related to cooling, power, network security, and server management increases.

●	Digital Transformation and Smart Cities

The push toward digital China, including the development of smart cities, serves as another critical factor propelling the telecom infrastructure market within China. The Chinese government aims to integrate advanced technologies like cloud computing, artificial intelligence, and big data into everyday business operations and public services. This digital transformation necessitates robust telecom infrastructure to support new digital services and applications. The smart cities require robust telecom networks that can support the Internet of Things, autonomous transportation systems, and smart energy grids, which presents a growing need for engineering services that specialize in the integration of telecommunications technologies with urban infrastructure.

Recently Issued Accounting Pronouncements

In February 2016, the Financial Accounting Standards Board (“FASB”) issued ASU No. 2016-02, Leases (Topic 842) (“ASU 2016-02”), as amended, which generally requires lessees to recognize operating and financing lease liabilities and corresponding right-of-use assets on the balance sheet and to provide enhanced disclosures surrounding the amount, timing and uncertainty of cash flows arising from leasing arrangements. The Company adopted the new standard effective January 1, 2019 and elected the package of practical expedients permitted under the transition guidance, which allows to carry forward our historical lease classification, and initial direct costs for any leases that exist prior to adoption of the new standard. The Company will also keep leases with an initial term of 12 months or less off the balance sheet and recognize the associated lease payments in the consolidated statements of income on a straight-line basis over the lease term. The Company estimates approximately $247,369 would be recognized as total right-of-use assets and total lease liabilities on its consolidated balance sheet as of June 1, 2019. Other than additional disclosure, the Company does not expect the new standard to have a material impact on its consolidated financial statements.

Off Balance Sheet Commitments and Arrangements

We have not entered into any financial guarantees or other commitments to guarantee the payment obligations of any third parties. In addition, we have not entered into any derivative contracts that are indexed to our shares and classified as shareholder’s equity or that are not reflected in our consolidated financial statements. Furthermore, we do not have any retained or contingent interest in assets transferred to an unconsolidated entity that serves as credit, liquidity or market risk support to such entity. We do not have any variable interest in any unconsolidated entity that provides financing, liquidity, market risk or credit support to us or engages in leasing, hedging or product development services with us.

MARKET PRICE FOR OUR COMMON EQUITY AND RELATED STOCKHOLDER MATTERS

Market Information

Our common stock is quoted on the OTC Pink Sheets under the symbol “AOAO.”

The table below sets forth the high and low closing prices of the Company’s Common Stock during the periods indicated. The quotations reflect inter-dealer prices without retail mark-up, markdown or commission and may not reflect actual transactions.

	2024 Price Range				2023 Price Range
	High		Low		High		Low

First Quarter	$	2.38	$	2.00	$	2.00	$	1.00
Second Quarter	$	2.38	$	2.38	$	1.74	$	0.14
Third Quarter	$	2.38	$	2.38	$	2.00	$	1.48
Fourth Quarter	$	2.38	$	1.51	$	2.35	$	2.00

(1)

There was no trading during this time.

The closing sales price of the Company’s common stock as reported on February 21, 2025, was $1.54 per share.

Shareholders

As of February 21, 2025, there were approximately 430 shareholders of record of our common stock.

Dividend Policy

We have never paid any cash dividends on our capital stock and do not anticipate paying any cash dividends on our common stock in the foreseeable future. We intend to retain future earnings to fund ongoing operations and future capital requirements. Any future determination to pay cash dividends will be at the discretion of our board of directors and will be dependent upon financial condition, results of operations, capital requirements and such other factors as the board of directors deems relevant.

Sale of Restricted Shares

All, but 76,745,587 of the shares of our common stock outstanding are “restricted securities” as such term is defined in Rule 144. These restricted securities were issued and sold by us, or will be issued and sold by us, in private transactions and are eligible for public sale only if registered under the Securities Act or if they qualify for an exemption from registration under the Securities Act, including the exemption provided by Rule 144.

Equity Compensation Plan Information

Currently, there is no equity compensation plans in place.

DIRECTORS AND EXECUTIVE OFFICERS AND CORPORATE GOVERNANCE

Biographical information regarding the officers and directors of the Company, who will continue to serve as officers and Directors of the Company are provided below:

Officer Biographies

NAME		AGE		DATES OF APPOINTMENT		POSITION
Shuhua Liu		43		March 30, 2023		Chief Executive Officer and Director

23D, Building 4, Yujing Oriental Garden, 168 Baishi Road, Nanshan District, Shenzhen, Guangdong Province, China

NAME		AGE		DATES OF APPOINTMENT		POSITION
Hongyan Li		49		October 27, 2024		Chief Financial Officer

No. 203, F2.62A, 2F, Tianzhan Building, No. 4 Tanran 5th Road, Tian’an Community, Shatou Street, Futian District, Shenzhen, Guangdong Province, China.

The term of office for each director is one (1) year.

Shuhua Liu - Chief Executive Officer

Ms. Liu has served as the Executive Officer of Alpha One Inc. since 2023. Ms. Liu brings over 20 years of experience in financial management, business investment, and leadership. Ms. Liu received her doctor degree of EU Business School in April 2024, In June 2008, she received an Executive Master of Business Administration Program in Auckland Institute of Studies. In 2014, Ms. Liu found Alpha One Holdings Limited and Alpha Culture Education Consulting (Shenzhen) Co., Ltd, Ms. Liu has resigned the president and director of Alpha Culture Education Consulting (Shenzhen) Co., Ltd. On February 7, 2025.

Due to Ms. Shuhua Liu’s over 20 years of experience in top management of various businesses, in March of 2023, the Board of Directors elected to appoint her to the positions of President, Secretary, Treasurer and Chairman of Board of Directors of the Company.

Hongyan Li - Chief Financial Officer

Ms. Li brings over 26 years of finance and accounting expertise, specializing in corporate finance, credit risk, and financial structuring. She holds an International Finance degree from Xinjiang University of Finance and Economics and an MBA from Shenzhen University. Ms. Li’s career includes senior roles at the Agricultural Bank of China and Xinjiang Construction Group, where she managed financial restructuring and regulatory compliance for Hong Kong market entry. Most recently, she served as Deputy General Manager at Shenzhen Li Jia Jia Cheng Group, overseeing financing for large-scale infrastructure projects. As CFO, she provides strategic financial leadership, focusing on growth and capital efficiency.

Corporate Governance

Director Independence

None of our directors qualified as an “independent director” under the rules of NASDAQ, Marketplace Rule 4200(a).

Nominating Committee

We do not presently have a nominating committee. Our Board of Directors currently acts as our nominating committee.

Audit Committee

We do not presently have an audit committee. Our Board of Directors currently acts as our nominating committee.

Involvement in certain legal proceedings

Our Directors and our Executive officers have not been involved in any of the following events during the past ten years:

	1.	Bankruptcy petition filed by or against any business of which such person was a general partner or executive officer either at the time of the bankruptcy or within two years prior to that time;
	2.	Any conviction in a criminal proceeding or being subject to a pending criminal proceeding (excluding traffic violations and other minor offenses);
	3.	Being subject to any order, judgment, or decree, not subsequently reversed, suspended or vacated, of any court of competent jurisdiction, permanently or temporarily enjoining, barring, suspending or otherwise limiting his/her involvement in any type of business, securities or banking activities; or
	4.	Being found by a court of competent jurisdiction (in a civil action), the Commission or the Commodity Futures Trading Commission to have violated a federal or state securities or commodities law, and the judgment has not been reversed, suspended, or vacated.
	5.	Such person was found by a court of competent jurisdiction in a civil action or by the Commission to have violated any Federal or State securities law, and the judgment in such civil action or finding by the Commission has not been subsequently reversed, suspended, or vacated;
	6.	Such person was found by a court of competent jurisdiction in a civil action or by the Commodity Futures Trading Commission to have violated any Federal commodities law, and the judgment in such civil action or finding by the Commodity Futures Trading Commission has not been subsequently reversed, suspended or vacated;
	7.	Such person was the subject of, or a party to, any Federal or State judicial or administrative order, judgment, decree, or finding, not subsequently reversed, suspended or vacated, relating to an alleged violation of:(i) Any Federal or State securities or commodities law or regulation; or(ii) Any law or regulation respecting financial institutions or insurance companies including, but not limited to, a temporary or permanent injunction, order of disgorgement or restitution, civil money penalty or temporary or permanent cease-and-desist order, or removal or prohibition order; or(iii) Any law or regulation prohibiting mail or wire fraud or fraud in connection with any business entity; or
	8.	Such person was the subject of, or a party to, any sanction or order, not subsequently reversed, suspended or vacated, of any self-regulatory organization (as defined in Section 3(a)(26) of the Exchange Act (15 U.S.C. 78c(a)(26))), any registered entity (as defined in Section 1(a)(29) of the Commodity Exchange Act (7 U.S.C. 1(a)(29))), or any equivalent exchange, association, entity or organization that has disciplinary authority over its members or persons associated with a member.

Code of Ethics

We have not adopted a formal Code of Ethics. The Board of Directors evaluated the business of the Company and the number of employees and determined that since the business is operated by a small number of persons, general rules of fiduciary duty and federal and state criminal, business conduct and securities laws are adequate ethical guidelines. In the event our operations, employees and/or Directors expand in the future, we may take actions to adopt a formal Code of Ethics.

Shareholder Proposals

Our Company does not have any defined policy or procedural requirements for shareholders to submit recommendations or nominations for Directors. The Board of Directors believes that, given the stage of our development, a specific nominating policy would be premature and of little assistance until our business operations develop to a more advanced level. Our Company does not currently have any specific or minimum criteria for the election of nominees to the Board of Directors and we do not have any specific process or procedure for evaluating such nominees. The Board of Directors will assess all candidates, whether submitted by management or shareholders, and make recommendations for election or appointment.

A shareholder who wishes to communicate with our Board of Directors may do so by directing a written request addressed to our President, at the address appearing on the first page of this Information Statement.

EXECUTIVE COMPENSATION

Pre-Transaction - Alpha One Inc.

The following table sets forth the compensation earned during the past two fiscal years by the person who served as our principal executive officer for the year ended of March 31, 2024 and March 31,2023.

Summary Compensation Table

Name and Principal Position	Year	Salary		Bonus		Stock Awards		Option Awards		Non- Equity Incentive Plan Compen- Sation		Change in Pension Value and Nonqualified Deferred Compensation		All Other Compensation		Total
Shuhua Liu, CEO	2024		-		-		-		-		-		-		-		-
	2023		-		-		-				-		-		-		-
Hongyan Li, CFO	2024		16,572		-		-		-		-		-		-		16,572
	2023		1,428		-		-		-		-		-		-		1,428

Narrative Disclosure to Summary Compensation Table

There are no employment contracts, compensatory plans or arrangements, including payments to be received from the Company with respect to any executive officer, that would result in payments to such person because of his or her resignation, retirement or other termination of employment with the Company, or its subsidiaries, any change in control, or a change in the person’s responsibilities following a change in control of the Company.

Outstanding Equity Awards at Fiscal Year-End

There are no current outstanding equity awards to our executive officers as of March 31, 2024.

Long-Term Incentive Plans

There are no arrangements or plans in which we provide pension, retirement or similar benefits for directors or executive officers.

Compensation Committee

We currently do not have a compensation committee of the Board of Directors. The Board of Directors as a whole determines executive compensation.

Compensation of Directors

The directors of the Company receive no extra compensation for their services on our Board of Directors.

Executive Compensation Philosophy

Our Board of Directors determines the compensation given to our executive officers in their sole determination. Our Board of Directors reserves the right to pay our executive or any future executives a salary, and/or issue them shares of common stock in consideration for services rendered and/or to award incentive bonuses which are linked to our performance, as well as to the individual executive officer’s performance. This package may also include long-term stock-based compensation to certain executives, which is intended to align the performance of our executives with our long-term business strategies. Additionally, while our Board of Directors has not granted any performance base stock options to date, the Board of Directors reserves the right to grant such options in the future, if the Board in its sole determination believes such grants would be in the best interests of the Company.

Incentive Bonus

The Board of Directors may grant incentive bonuses to our executive officer and/or future executive officers in its sole discretion, if the Board of Directors believes such bonuses are in the Company’s best interest, after analyzing our current business objectives and growth, if any, and the amount of revenue we are able to generate each month, which revenue is a direct result of the actions and ability of such executives.

Long-term, Stock Based Compensation

In order to attract, retain and motivate executive talent necessary to support the Company’s long-term business strategy we may award our executive and any future executives with long-term, stock-based compensation in the future, at the sole discretion of our Board of Directors, which we do not currently have any immediate plans to award.

SECURITY OWNERSHIP OF CERTAIN BENEFICIAL OWNERS AND MANAGEMENT

The following table sets forth certain information concerning the number of shares of our common stock owned beneficially as of the date of this Report by: (i) each of our directors; (ii) each of our executive officers; (iii) all of our current executive officers and directors as a Company, unless otherwise indicated, the shareholders listed below possess sole voting and investment power with respect to the shares they own.

Based on 76,809,533 shares of common stock issued and outstanding as of the date of this Registration Statement. The number and percentage of shares beneficially owned is determined under rules promulgated by the SEC and the information is not necessarily indicative of beneficial ownership for any other purpose. Under such rules, beneficial ownership includes any shares as to which the individual has sole or shared voting power or investment power and also any shares which the individual has the right to acquire within 60 days through the exercise of any stock option or other right. The persons named in the table have sole voting and investment power with respect to all shares of common stock shown that are beneficially owned by them, subject to community property laws where applicable and the information contained in the footnotes to this table.

Number of Shares Total Beneficially Held

Name and Address of Beneficial Owner	Beneficially Held		Percent
Directors and Officers
Shuhua Liu (Chief Executive Officer and Director)		25,690,775		33.447	%
Hongyan Li (Chief Financial Officer)		422,002		0.549	%
All director and officer		26,112,777		33,997	%

5% shareholders
Sun Horn Limited^※		19,890,000		25.895	%
Shuhua Liu		25,690,775		33.447	%
Goldcrown International (HK) Limited^※		5,610,000		7.304	%
		56,800,775		66.646	%

※ Wei Chen is the beneficial owner, who is the spouse of the director Shuhua Liu, is the sole director and shareholder of Sun Horn Limited and Goldcrown International (HK) Limited.

CERTAIN RELATIONSHIPS AND RELATED TRANSACTIONS, AND CORPORATE GOVERNANCE

On September 10, 2021, the Company effectuated a 100-for-1 reverse stock split, which resulted in a new total of 1,359,447 shares of common stock.

On February 8, 2022, the Company convert 500,000 of its Series A Preferred Stock into common stock with a ratio of 100 for 1.

Upon completion of the merger, all of the outstanding shares of Zhongyun BVI’s common stock were exchanged for 25,450,086 shares of common stock of AOAO. Prior to the merger, Shuhua Liu and her spouse dirctly and indirectly obtained the total 49.65% controlled of AOAO, and 50% indirectly controlled of Zhongyun BVI by Zhongyun Global International Group Limited. Shuhua Liu is the sole director of AOAO and Zhongyun BVI. Following the Merger, Shuhua Liu and her spouse directly and indirectly obtained the total 49.77% controlled of AOAO. As AOAO and Zhongyun BV were under common control at the time of the share exchange, the transaction is accounted for as a combination of entities under common control in a manner similar to the pooling-of-interests method of accounting. Immediately after completion of such share exchange, the Company has a total of 76,809,533 issued and outstanding shares of common stock, with authorized share capital for common shares of 450,000,000.

On November 16, 2023, the former director and CEO Zhuo Wang transferred 19,890,000 shares to Sun Horn Limited, 4,239,742 shares to Shuhua Liu and 1,370,258 shares Xinli Chen for free.

For the year ended March 31, 2023 and 2024, the Company purchased engineering services from the related party “Shenzhen Zhongyun Information Technology Co., Ltd” in the amounts of $607,148 and nil respectively. For the six months ended September 30, 2023 and 2024, the Company purchased engineering services from the related party “Shenzhen Zhongyun Information Technology Co., Ltd” in the amounts of nil and $227,864 respectively.

For the year ended March 31, 2023 and 2024, the Company purchased engineering services from the related parties “Shenzhen Zhongyun Electronic Intelligent Technology Co., Ltd” and “Shenzhen Nanshan District Zhongyun Computer Development Center” in the amounts of $1,984 and $575 respectively. For the six months ended September 30, 2023 and 2024, the Company purchased the engineering services from the related parties “Shenzhen Zhongyun Electronic Intelligent Technology Co., Ltd” and “Shenzhen Nanshan District Zhongyun Computer Development Center” in the amounts of $575 and nil respectively.

Review, Approval and Ratification of Related Party Transactions

Given our small size and limited financial resources, we have not adopted formal policies and procedures for the review, approval or ratification of transactions, such as those described above, with our executive officer(s), Director(s) and significant stockholders. We intend to establish formal policies and procedures in the future, once we have sufficient resources and have appointed additional Directors, so that such transactions will be subject to the review, approval or ratification of our Board of Directors, or an appropriate committee thereof. On a moving forward basis, our Directors will continue to approve any related party transaction.

Director Independence

None of our directors qualified as an “independent director” under the rules of NASDAQ, Marketplace Rule 4200(a).

Nominating Committee

We do not presently have a nominating committee. Our Board of Directors currently acts as our nominating committee.

Audit Committee

We do not presently have an audit committee. Our Board of Directors currently acts as our nominating committee.

EXPENSES OF ISSUANCE AND DISTRIBUTION

The following table sets forth the costs and expenses payable by us in connection with the sale of common stock being registered. All amounts are estimates except for the SEC filing fee.

SEC filing fee	$	3,089
Legal fees and expenses	$	25,000
Accounting fees and expenses	$	210,000
Total	$	238,089

SELLING SHAREHOLDERS

Name of Selling Shareholders*	Beneficial Ownership Before the Offering		Shares of Common Stock Included in Prospectus		Beneficial of Ownership After the Offering		Percentage Ownership After the Offering
Sun Horn Limited⁽¹⁾		19,890,000		2,493,514		17,396,486		19.39	%

Lin Jianhui⁽²⁾		2,558,200		2,558,200		-		0	%

Yu Xiaocai		2,227,337		2,227,337		-		0	%

Zhang Jinlin		406,706		406,706		-		0	%

Cao Yong		874,081		874,081		-		0	%

Lin Jiayao		1,440,162		1,440,162		-		0	%

(1)

The 19,890,000 shares of common stock that were issued to Sun Horn Limited sold from Zhuo Wang.

	(2)	The 2,558,200 shares of common stock that were issued to Lin Jianhui sold from Zhongyun Global International Group Limited.

	(3)	The 2,227,337 shares of common stock that were issued to Yu Xiaocai sold from Zhongyun Global International Group Limited.

	(4)	The 406,706 shares of common stock that were issued to Zhang Jinlin sold from Zhongyun Global International Group Limited.

	(5)	The 874,081 shares of common stock that were issued to Cao Yong sold from Zhongyun Global International Group Limited.

	(6)	The 1,440,162 shares of common stock that were issued to Lin Jiayao sold from Zhongyun Global International Group Limited.

We may require the selling shareholders to suspend the sales of the securities offered by this prospectus upon the occurrence of any event that makes any statement in this prospectus, or the related registration statement, untrue in any material respect, or that requires the changing of statements in these documents in order to make statements in those documents not misleading. We will file a post-effective amendment to this registration statement to reflect any material changes to this prospectus.

Effect of Sales on Our Shareholders

All shares of common stock that are covered by this prospectus are expected to be freely tradable. The sale by the selling shareholders of a significant amount of shares registered in this offering at any given time could cause the market price of our common stock to decline and to be highly volatile.

PLAN OF DISTRIBUTION

The Selling Shareholders and any of its pledgees, assignees and successors-in-interest may, from time to time, sell any or all of the shares of our common stock covered by this prospectus on the over-the-counter market or any other stock exchange, market or trading facility on which the shares are traded or in private transactions. The Selling Shareholder may sell all or a portion of their respective shares of common stock covered by this prospectus from time to time at the fixed price of $1.00. A Selling Shareholder may use any one or more of the following methods when selling securities:

	●	on any national securities exchange or quotation service on which the Shares may be listed or quoted at the time of sale;
	●	in the over-the-counter market;
	●	in the transactions otherwise than on these exchanges or systems or in the over-the-counter market;
	●	ordinary brokerage transactions and transactions in which the broker-dealer solicits purchasers;
	●	block trades in which the broker-dealer will attempt to sell the shares as agent, but may position and resell a portion of the block as principal to facilitate the transaction;
	●	purchases by a broker-dealer as principal and resale by the broker-dealer for its account;
	●	an exchange distribution in accordance with the rules of the applicable exchange; privately transactions;
	●	short sales;
	●	through the listing or settlement of options or other hedging transactions, whether such options are listed on an options exchange or otherwise;
	●	broker-dealers may agree with the selling shareholders to sell a specified number of such Shares at a stipulated price;
	●	a combination of any such methods of sale; and
	●	any other method permitted pursuant to applicable law.

Brokers, dealers, underwriters, or agents participating in the distribution of the shares as agents may receive compensation in the form of commissions, discounts, or concessions from the selling shareholders and/or purchasers of the common stock for whom the broker-dealers may act as agent. The compensation paid to a particular broker-dealer may be less than or in excess of customary commissions.

The selling shareholders and any underwriters, broker-dealers or agents that participate in the sale of the common stock may be “underwriters” within the meaning of Section 2(11) of the Securities Act. Any discounts, commissions, concessions or profit they earn on any resale of the shares may be underwriting discounts and commissions under the Securities Act. Selling shareholders who are “underwriters” within the meaning of Section 2(11) of the Securities Act will be subject to the prospectus delivery requirements of the Securities Act.

In connection with the sale of our common stock, the selling shareholders may enter into hedging transactions with broker-dealers or other financial institutions, which may in turn engage in short sales of the common stock in the course of hedging the positions they assume. The selling shareholders may also sell shares of our common stock short and deliver shares to close out their short positions, or loan or pledge the common stock to broker-dealers that in turn may sell such shares.

Neither we nor the selling shareholders can presently estimate the amount of compensation that any agent will receive. We know of no existing arrangements between the selling shareholders, any other shareholder, broker, dealer, underwriter, or agent relating to the sale or distribution of the shares offered by this prospectus. At the time a particular offer of shares is made, a prospectus supplement, if required, will be distributed that will set forth the names of any agents, underwriters, or dealers and any compensation from the selling shareholder, and any other required information.

We will pay all of the expenses incident to the registration, offering, and sale of the shares to the public other than commissions or discounts of underwriters, broker-dealers, or agents. Any commissions, discounts or other fees payable to brokers-dealers in connection with any sale of the shares of common stock will be borne by the selling shareholders, the purchasers participating in such transaction, or both.

We have agreed to indemnify those selling shareholders against liabilities, including liabilities under the Securities Act and state securities laws, relating to the registration of the shares offered by this prospectus up to an amount not to exceed the net proceeds of the Offering.

Insofar as indemnification for liabilities arising under the Securities Act may be permitted to our directors, officers, and controlling persons, we have been advised that in the opinion of the SEC this indemnification is against public policy as expressed in the Securities Act and is therefore, unenforceable.

We have advised the selling shareholders that the anti-manipulation rules of Regulation M under the Exchange Act may apply to sales of shares in the market and to the activities of the selling shareholders and their affiliates. In addition, we will make copies of this prospectus (as it may be supplemented or amended from time to time) available to the selling shareholders for the purpose of satisfying the prospectus delivery requirements of the Securities Act. The selling shareholders may indemnify any broker-dealer that participates in transactions involving the sale of the shares against certain liabilities, including liabilities arising under the Securities Act.

We and the selling shareholders will be subject to applicable provisions of the Exchange Act and the rules and regulations under it, including, without limitation, Rule 10b-5.

This offering will terminate on the date that all shares offered by this prospectus have been sold by the selling shareholders.

Under the securities laws of some states, the shares may be sold in such states only through registered or licensed brokers or dealers. In addition, in some states the shares may not be sold unless such shares have been registered or qualified for sale in such state or an exemption from registration or qualification is available and is complied with.

Penny Stock Rules

Our shares of common stock are subject to the “penny stock” rules of the Exchange Act. In general terms, “penny stock” is defined as any equity security that has a market price less than $5.00 per share, subject to certain exceptions. The rules provide that any equity security is considered to be a penny stock unless that security is registered and traded on a national securities exchange meeting specified criteria set by the SEC, authorized for quotation from the NASDAQ stock market, issued by a registered investment company, and excluded from the definition on the basis of price (at least $5.00 per share), or based on the issuer’s net tangible assets or revenues. In the last case, the issuer’s net tangible assets must exceed $3,000,000 if in continuous operation for at least three years or $5,000,000 if in operation for less than three years, or the issuer’s average revenues for each of the past three years must exceed $6,000,000.

Trading in shares of penny stock is subject to additional sales practice requirements for broker-dealers who sell penny stocks to persons other than established customers and accredited investors. Accredited investors, in general, include individuals with assets in excess of $1,000,000 or annual income exceeding $200,000 (or $300,000 together with their spouse), and certain institutional investors. For transactions covered by these rules, broker-dealers must make a special suitability determination for the purchase of the security and must have received the purchaser’s written consent to the transaction prior to the purchase. Additionally, for any transaction involving a penny stock, the rules require the delivery, prior to the first transaction, of a risk disclosure document relating to the penny stock. A broker-dealer also must disclose the commissions payable to both the broker-dealer and the registered representative, and current quotations for the security. Finally, monthly statements must be sent disclosing recent price information for the penny stocks. These rules may restrict the ability of broker-dealers to trade or maintain a market in our common stock, to the extent it is penny stock, and may affect the ability of stockholders to sell their shares.

DESCRIPTION OF SECURITIES

The following description of our capital stock is only a summary and is qualified in its entirety by the provisions of our certificate of incorporation and bylaws, each as amended and restated, which have been filed as exhibits to the registration statement of which this prospectus forms a part.

We are authorized to issue 450,000,000 shares of Common Stock, par value $0.001. As of the date of this Report, there were 76,809,533 shares of Common Stock issued and outstanding. We are authorized to issue 500,000 shares of Preferred Stock, par value $0.001, As of the date of this Report, there were 500,000 shares of Preferred Stock issued and nil shares outstanding.

Voting Rights

Except as otherwise required by law or as may be provided by the resolutions of the Board of Directors authorizing the issuance of common stock, all rights to vote and all voting power shall be vested in the holders of common stock. Each share of common stock shall entitle the holder thereof to one vote. Except as may be provided by the resolutions of the Board of Directors authorizing the issuance of common stock, cumulative voting by any shareholder is expressly denied.

Rights upon Liquidation, Dissolution or Winding-Up of the Company

Upon any liquidation, dissolution or winding-up of the corporation, whether voluntary or involuntary, the remaining net assets of the Company shall be distributed pro rata to the holders of the common stock.

The holders of our Common Stock have equal ratable rights to dividends from funds legally available therefore, when, as and if declared by our board of directors. Holders of Common Stock are also entitled to share ratably in all of our assets available for distribution to holders of Common Stock upon liquidation, dissolution or winding up of the affairs.

Transfer Agent

The transfer agent for our capital stock is Vstock Transfer LLC, with an address of 18 Lafayette Place, Woodmere, NY 11598 and telephone number is 212-828-8436.

2023 Wyoming Statutes
Title 17 - Corporations, Partnerships and Associations
Chapter 18 - Wyoming Management Stability Act
Article 1 - General Provisions
Section 17-18-105 - Option; Shareholder Takeover Protection Provisions.

17-18-105. Option; shareholder takeover protection provisions.

(a) Any qualified corporation is subject to the shareholder takeover protection provisions listed in W.S. 17-18-105 through 17-18-111 unless the corporation elects not to be subject to the restrictions. A corporation which is not a qualified corporation may elect not to be subject to the shareholder takeover provisions in the event it becomes a qualified corporation. The election shall be made either:

(i) Through a specific provision in the articles of incorporation;

(ii) Through a statement in the bylaws that the corporation elects not to be subject to the restrictions in W.S. 17-18-105 through 17-18-111. This election shall be effective immediately upon adoption of the bylaws, unless the articles of incorporation provide otherwise; or

(iii) By filing a statement making the election with the secretary of state. This election shall be authorized by the corporation’s board of directors and shall be effective from the date of filing with the secretary of state.

(b) If a takeover offer is outstanding and in progress at the time the election becomes effective, all further acquisition of stock by the offeror shall cease until the offer is in compliance with the stockholder takeover protection provision of W.S. 17-18-105 through 17-18-111. The offeror may take any steps necessary to comply with these provisions before the election becomes effective.

(c) The election not to be subject to the shareholder takeover provisions of W.S. 17-18-105 through 17-18-111 may be revoked by the same method employed under subsection (a) of this section for making the election.

INTEREST OF NAMED EXPERTS AND COUNSEL

No expert or counsel named in this prospectus as having prepared or certified any part of this prospectus or having given an opinion upon the validity of the securities being registered or upon other legal matters in connection with the registration or offering of the common stock was employed on a contingency basis or had, or is to receive, in connection with the offering, a substantial interest, directly or indirectly, in the registrant or any of its parents or subsidiaries. Nor was any such person connected with the registrant or any of its affiliates as a promoter, managing or principal underwriter, voting trustee, director, officer or employee.

ADDITIONAL INFORMATION

We have filed with the SEC this registration statement on Form S-1 under the Securities Act with respect to the shares of common stock being offered by this prospectus. This prospectus, which constitutes a part of this registration statement, does not contain all of the information in this registration statement and its exhibits. For further information with respect to us and the common stock offered by this prospectus, you should refer to this registration statement and the exhibits filed as part of that document. Statements contained in this prospectus as to the contents of any contract or any other document referred to are not necessarily complete, and in each instance, we refer you to the copy of the contract or other document filed as an exhibit to this registration statement. Each of these statements is qualified in all respects by this reference.

We are subject to the informational requirements of the Exchange Act and file annual, quarterly and current reports, proxy statements and other information with the SEC. You can read our SEC filings, including this registration statement, over the Internet at the SEC’s website at http://www.sec.gov. You may also read and copy any document we file with the SEC at its public reference facilities at 100 F Street, N.E., Washington, D.C. 20549. You may also obtain copies of these documents at prescribed rates by writing to the Public Reference Section of the SEC at 100 F Street, N.E., Washington, D.C. 20549. Please call the SEC at 1-800-SEC-0330 for further information on the operation of the public reference facilities. You may also request a copy of these filings, at no cost, by writing or telephoning us at: Blue Star Foods Corp., 3000 NW 109th Avenue, Miami, Florida 33172 or (305) 836-68 AOAO. In addition, all documents subsequently filed by us pursuant to Sections 13(a), 13(c), 14 or 15(d) of the Exchange Act, prior to the termination of the offering (excluding any information furnished rather than filed) shall be deemed to be incorporated by reference into this prospectus.

LEGAL MATTERS

Rockville Law Company LLC will opine on the validity of the shares being offered hereby.

EXPERTS

The consolidated financial statements included in this prospectus and in the registration statement for the fiscal years ended March 31, 2024 and 2023 have been audited by Bush & Associates, CPA LLC, an independent registered public accounting firm and are included in reliance upon such report given upon the authority of said firm as experts in auditing and accounting.

INDEX TO CONSOLIDATED FINANCIAL STATEMENTS

Contents		Page

Report of Independent Registered Public Accounting Firm (PCAOB ID 6797)		F-2

Consolidated Balance Sheets as of March 31, 2024 and 2023		F-3

Consolidated Statements of Operations and Comprehensive Income (Loss) for the Years Ended March 31, 2024 and 2023		F-4

Consolidated Statements of Stockholders’ Equity for the Years Ended March 31, 2024 and 2023		F-5

Consolidated Statements of Cash Flows for the Years Ended March 31, 2024 and 2023		F-6

Notes to Consolidated Financial Statements for the Years Ended March 31, 2024 and 2023		F-7 to F-19

Condensed Consolidated Balance Sheets as of September 30, 2024 (Unaudited) and March 31, 2024		F-20

Condensed Consolidated Statements of Operations and Comprehensive Income (Loss) for the Three and Six Months Ended September 30, 2024 and 2023 (Unaudited)		F-21

Condensed Consolidated Statements of Changes in Stockholders’ Equity for the Three and Six Months Ended September 30, 2024 and 2023 (Unaudited)		F-22

Condensed Consolidated Statements of Cash Flows for the Six Months Ended September 30, 2024 and 2023 (Unaudited)		F-23

Notes to Condensed Consolidated Financial Statements for the Three and Six Months Ended September 30, 2024 and 2023 (Unaudited)		F-24 to F-35

F-1

REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM

To the Shareholders and the Board of Directors of

Alpha One, Inc.

OPINION ON THE FINANCIAL STATEMENTS

We have audited the accompanying consolidated balance sheet of Alpha One, Inc. (the “Company”) as of March 31, 2024 and 2023, and the related consolidated statements of operations, changes in stockholders’ equity, and cash flows for the years then ended, and the related notes (collectively referred to as the “financial statements”). In our opinion, the consolidated financial statements present fairly, in all material respects, the financial position of Alpha One, Inc as of March 31, 2024 and 2023 and the results of its operations and cash flows for the years then ended in conformity with accounting principles generally accepted in the United States.

SUBSTANTIAL DOUBT ABOUT THE COMPANY’S ABILITY TO CONTINUE AS A GOING CONCERN

The accompanying financial statements have been prepared assuming that the Company will continue as a going concern. As discussed in Note 2 to the financial statements, the Company’s operating losses raise substantial doubt about its ability to continue as a going concern. The financial statements do not include any adjustments that might result from the outcome of this uncertainty.

BASIS FOR OPINION

These financial statements are the responsibility of the Company’s management. Our responsibility is to express an opinion on these financial statements based on our audit. We are a public accounting firm registered with the Public Company Accounting Oversight Board (United States) (“PCAOB”) and are required to be independent with respect to the Company in accordance with the U.S. federal securities laws and the applicable rules and regulations of the Securities and Exchange Commission and the PCAOB.

We conducted our audit in accordance with the standards of the PCAOB. Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements are free of material misstatement, whether due to error or fraud. The Company is not required to have, nor were we engaged to perform, an audit of its internal control over financial reporting. As part of our audits, we are required to obtain an understanding of internal control over financial reporting but not for the purpose of expressing an opinion on the effectiveness of the Company’s internal control over financial reporting. Accordingly, we express no such opinion.

Our audit included performing procedures to assess the risks of material misstatement of the financial statements, whether due to error or fraud, and performing procedures that respond to those risks. Such procedures included examining, on a test basis, evidence regarding the amounts and disclosures in the financial statements. Our audits also included evaluating the accounting principles used and significant estimates made by management, as well as evaluating the overall presentation of the financial statements. We believe that our audit provides a reasonable basis for our opinion.

CRITICAL AUDIT MATTERS

Critical audit matters are matters arising from the current period audit of the financial statements that were communicated or required to be communicated to the audit committee and that (1) relate to accounts or disclosures that are material to the financial statements and (2) involved our especially challenging, subjective, or complex judgements. We determined that there are no critical audit matters.

/s/ Bush & Associates CPA LLC

We have served as the Company’s auditor since 2024.

Henderson, Nevada

October 31, 2024

PCAOB ID Number 6797

F-2

Alpha One Inc. and Subsidiaries

Consolidated Balance Sheets

As of March 31, 2024 and 2023

	As of March 31,
	2024			2023
Assets
Current assets
Cash and cash equivalents	$	383,682		$	329,994
Accounts receivable, net		9,746,035			5,715,660
Prepayments and other current assets, net		1,149,225			159,673
Due from related party		310,010			145,611
Total current assets		11,588,952			6,350,938

Non-current assets
Property and equipment, net		136,263			139,512
Operating lease right-of-use assets		8,542			24,375
Deferred tax assets		49,907			6,606
Intangible assets, net		289,151			342,401
Total Assets	$	12,072,815		$	6,863,832

Liabilities and Stockholders’ Equity
Current liabilities
Accounts payable	$	1,513,854		$	1,590,179
Accrued expenses and other payable		4,153,740			1,214,610
Bank and other borrowings, current		1,351,345			534,531
Contract liabilities		8,112			339,796
Income tax payable		653,168			115,696
Deferred tax liability		2,767			7,550
Operating lease liabilities, current		11,066			18,567
Due to related parties		1,376,439			1,543,043
Total current liabilities		9,070,491			5,363,972

Non-current liabilities
Operating lease liabilities, non-current		-			11,634
Bank and other borrowings, non-current		138,498			109,070
Total Liabilities		9,208,989			5,484,676

Stockholders’ Equity
Preferred stock (500,000 preferred stock authorized, 500,000 preferred stock issued and nil outstanding as of March 31, 2024 and 2023)		-			-
Common stock (450,000,000 common stock authorized, 76,809,533 common stock issued and outstanding as of March 31, 2024 and 2023)		76,809			76,809
Additional paid-in capital		1,520,893			1,203,973
Statutory reserves		163,711			34,602
Retained earning		1,204,232			87,791
Accumulated other comprehensive loss		(101,819	)		(24,019	)
Total Stockholders’ Equity		2,863,826			1,379,156

Total Liabilities and Stockholders’ Equity	$	12,072,815		$	6,863,832

See accompanying notes to the consolidated financial statements

F-3

Alpha One Inc. and Subsidiaries

Consolidated Statements of Operations and Comprehensive Income (Loss)

For the Years ended March 31, 2024 and 2023

	For the years ended March 31,
	2024			2023

Net revenues	$	23,549,144		$	6,494,640
Cost of revenues (including $575 and $609,132 from related parties for the years ended March 31, 2024 and 2023, respectively)		(20,411,893	)		(5,191,960	)
Gross profit		3,137,251			1,302,680

Operating expenses:
General and administrative expenses		695,672			351,447
Finance cost		5,039			80,129
Research and development expenses		182,574			169,123
Other operating expenses		190,544			2,052
		1,073,829			602,751

Operating income		2,063,422			699,929

Other income (expense):
Other expense		(892	)		(8,006	)
Other income		6,658			23,296
Interest income		91			108
Interest expense		(323,528	)		(267,925	)
Other (expense), net		(317,671	)		(252,527	)

Income before income tax		1,745,751			447,402

Income tax expense		(500,201	)		(117,884	)

Net income	$	1,245,550		$	329,518

Other comprehensive loss:
Foreign currency translation		(77,349	)		(23,356	)
Total comprehensive income	$	1,322,899		$	343,603

Earnings per share
Basic and diluted earnings per share	$	0.02		$	0.01
Basic and diluted weighted average shares outstanding		76,809,533			76,809,533

See accompanying notes to the consolidated financial statements

F-4

Alpha One Inc. and Subsidiaries

Consolidated Statements of Stockholders’ Equity

For the Years ended March 31, 2024 and 2023

	No. of		Common		Additional Paid-in		Statutory		Retained earnings (accumulated			Accumulated Other Comprehensive			Total Stockholders’
	Shares		Stock		Capital		Reserves		Deficits)			Income (Loss)			Equity
Balance as of March 31, 2022		76,809,533	$	76,809	$	246,548	$	-	$	(207,125	)	$	(641	)	$	115,591
Foreign currency translation adjustment		-		-		-		-					(23,378	)		(23,378	)
Additional paid in capital		-		-		957,425		-					-			957,425
Net income		-		-		-		34,602		294,916			-			329,518
Balance as of March 31, 2023		76,809,533	$	76,809	$	1,203,973	$	34,602	$	87,791		$	(24,019	)	$	1,379,156
Foreign currency translation adjustment		-		-		-		-					(77,800	)		(77,800	)
Additional paid in capital		-		-		316,920		-		-			-			316,920
Net income		-		-		-		129,109		1,116,441			-			1,245,550
Balance as of March 31, 2024		76,809,533	$	76,809	$	1,520,893	$	163,711	$	1,204,232		$	(101,819	)	$	2,863,826

See accompanying notes to the consolidated financial statements

F-5

Alpha One Inc. and Subsidiaries

Consolidated Statements of Cash Flows

For the Years ended March 31, 2024 and 2023

	For the years ended March 31,
	2024			2023
Cash flows from operating activities
Net income	$	1,245,550		$	329,518
Adjustments to reconcile net income (loss) to net cash provided by (used in) operating activities:
Depreciation and amortization expense		63,118			50,808
Noncash lease expense		15,833			18,709
Allowance for doubtful accounts		189,140			2,047
Deferred tax		(43,301	)		4,165
Changes in operating assets and liabilities
Accounts receivable		(4,217,024	)		(5,710,723	)
Prepayments and other receivables		(992,043	)		(56,973	)
Accounts payable		(76,325	)		1,590,179
Contract liabilities		(331,684	)		339,796
Accrued expenses and other payables		2,934,347			1,201,844
Income tax payable		537,472			115,696
Operating lease obligations		(19,135	)		(13,445	)
Cash (used in) operating activities		(694,052	)		(2,128,379	)

Cash flows from investing activities
Purchase of property and equipment		(30,162	)		(151,920	)
Net cash (used in) investing activities		(30,162	)		(151,920	)

Cash flows from financing activities
Borrowings from bank loans		846,242			643,601
Borrow from related parties		-			849,068
Repayments to related parties		(331,003	)		-
Capital injection		316,920			957,425
Net cash provided by financing activities		832,159			2,450,094

Effect of exchange rate changes on cash and cash equivalents		(54,257	)		8,357
Net changes in cash and cash equivalents		53,688			178,152
Cash and cash equivalents–beginning of the year		329,994			151,842

Cash and cash equivalents–end of the year	$	383,682		$	329,994

Supplementary cash flow information:
Interest paid	$	323,528		$	267,925
Income taxes paid	$	717		$	1,101

Non-cash investing and financing activities
Expenses paid by related parties on behalf of the Company	$	354,550		$	-
Operating lease right-of-use assets obtained in exchange for operating lease obligations	$	(11,066	)	$	(30,201	)

See accompanying notes to the consolidated financial statements

F-6

Alpha One Inc. and Subsidiaries

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

FOR THE YEARS ENDED MARCH 31, 2024 AND 2023

NOTE 1 - ORGANIZATION AND DESCRIPTION OF BUSINESS

On February 8, 2021, the previously issued 100,000,000 shares of common stock were canceled in connection with changes in the Company’s strategic direction.

On September 10, 2021, the Company effectuated a 100-for-1 reverse stock split, which resulted in a new total of 1,359,447 shares of common stock.

On February 8, 2022, the Company convert 500,000 of its Series A Preferred Stock into common stock with a ratio of 100 for 1.

Upon completion of the merger, all of the outstanding shares of Zhongyun BVI’s common stock were exchanged for 25,450,086 shares of common stock of AOAO. Prior to the merger, Shuhua Liu and her spouse directly and indirectly obtained the total 49.65% controlled of AOAO, and 50% indirectly controlled of Zhongyun BVI by Zhongyun Global International Group Limited. Shuhua Liu is the sole director of AOAO and Zhongyun BVI. Following the Merger, Shuhua Liu and her spouse directly and indirectly obtained the total 49.77% controlled of AOAO. As AOAO and Zhongyun BV were under common control at the time of the share exchange, the transaction is accounted for as a combination of entities under common control in a manner similar to the pooling-of-interests method of accounting. Immediately after completion of such share exchange, the Company has a total of 76,809,533 issued and outstanding shares of common stock, with authorized share capital for common shares of 450,000,000.

On November 16, 2023, the former director and CEO Zhuo Wang transferred 19,890,000 shares to Sun Horn Limited, 4,239,742 shares to Shuhua Liu and 1,370,258 shares Xinli Chen for free.

F-7

Zhongyun (BVI) Limited (“Zhongyun BVI”) was incorporated in the British Virgin Islands on December 6, 2022 with limited liability.

NOTE 2 - SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES

Going concern

The accompanying consolidated financial statements have been prepared assuming that the Company will continue as a going concern, which contemplates the realization of assets and the discharge of liabilities in the normal course of business for the foreseeable future. For the years ended on March 31, 2024 and 2023, the net cash used cash in operating activities was $694,052 and $2,128,379 respectively. These factors raise substantial doubt about the Company’s ability to continue as a going concern within one year after the date the financial statements are issued. The Company’s financial statements do not include any adjustments that might result from the outcome of this uncertainty should we be unable to continue as a going concern.

Management estimates that the current funds on hand (means cash at bank and on hand) will be sufficient to continue operations through the next 12 months. The continuation of the Company as a going concern is dependent upon (1) there was $3.52 million overdue one year (aging over 360 days) as of March 31, 2024, the Company will accelerate the collection of accounts receivable, $2.5 million will be received as of June 30, 2025 and $2.79 million to be collected in the next 12 months that based on the agreed extra payment term on the ongoing contracts. From October 2024 to January 2025, the Company has collected $1.15 million out of the $2.5 million, and regards of well-known reputation of customers, we assume that we will be able to successfully collect such amounts within the extra payment term; (2) the continued financial support from its stockholders or its ability to obtain external financing, the company has only obtained verbal funding commitments from stockholders, which are non-binding and may not be fulfilled; (3) further to make the cost controlling; and (4) implement management’s business plan to extend its operations and generate sufficient revenues to meet its obligations. While the Company believes in the viability of its strategy to increase sales volume and in its ability to raise additional funds, there can be neither any assurances to that effect, nor any assurance that the Company will be successful in securing sufficient funds to sustain the operations. In long-term, the continuation of the Company as a going concern is dependent upon (i) further implement management’s business plan to extend its operations and generate sufficient revenues to meet its obligations; (ii) Shorten customer payment terms and extend supplier payment terms; and (iii) maintain to obtain the revolving credit lines and loans with lower interest from the bank.

Management believes that the actions presently being taken to obtain additional funding and implement its strategic plan provides the opportunity for the Company to continue as a going concern.

Basis of presentation

These consolidated financial statements, accompanying notes, and related disclosures have been prepared pursuant to the rules and regulations of the U.S. Securities and Exchange Commission (“SEC”). These financial statements have been prepared using the accrual basis of accounting in accordance with the generally accepted accounting principles in the United States (“U.S. GAAP”). The Company’s fiscal year end is March 31. The Company’s financial statements are presented in U.S. dollars.

Basis of consolidation

The consolidated financial statements include the accounts of the Company and its subsidiaries. All intercompany accounts and transactions have been eliminated. The results of subsidiaries acquired during the respective periods are included in the consolidated statements of operations from the effective date of acquisition or up to the effective date of disposal, as appropriate. The portion of the income or loss applicable to noncontrolling interests in subsidiaries is reflected in the consolidated statements of operations.

As of March 31, 2024, details of the Company’s major subsidiaries were as follows:

Entity Name	Date of Incorporation	Parent Entity	Nature of Operation	Place of Incorporation
Zhongyun (BVI) Ltd	December 6, 2022	AOAO	Investment holding	British Virgin Islands
Zhongyun Investment Hong Kong Ltd	December 23, 2022	Zhongyun BVI	Investment holding	Hong Kong
Shenzhen zhongyun communication technology Co. Ltd	August 25, 2020	Zhongyun HK	Communiciation engineer project service and intelligent products’ trading	Shenzhen, China

F-8

Use of estimates

The preparation of financial statements in conformity with U.S. GAAP requires management to make estimates and assumptions relating to the reporting of assets and liabilities and the disclosure of contingent liabilities at the date of the financial statements, and the reported amounts of revenues and expenses during the reporting period. Significant accounting estimates include certain assumptions related to going concern, allowance of doubtful accounts, allowance of deferred tax asset and uncertain tax position, implicit interest rate of operating leases, useful lives and impairment of long-lived assets, and impairment of goodwill. Actual results may differ from these estimates.

Foreign currency translation and re-measurement

The Company’s reporting currency is the United States Dollars (“US$”) and the accompanying consolidated financial statements have been expressed in US$. In addition, the Company’s operating subsidiary maintains its books and records in their respective local currency, which consists of the Renminbi (“RMB”). The determination of the respective functional currency is based on the criteria set out by ASC 830, Foreign Currency Mattters, (“ASC 830”).

Transactions denominated in currencies other than in the functional currency are translated into the functional currency using the exchange rates prevailing at the transaction dates. Monetary assets and liabilities denominated in foreign currencies are translated into functional currency using the applicable exchange rates at the balance sheet date. Non-monetary items that are measured in term of historical cost in foreign currency are re-measured using the exchange rates at the dates of the initial transactions. Exchange gains or losses arising from foreign currency transactions are included in the consolidated statements of comprehensive income (loss).

The financial statements of the Company’s entities of which the functional currency is not US$ are translated from their respective functional currency into US$. Assets and liabilities denominated in foreign currencies are translated into US$ at the exchange rates at the balance sheet date. Equity accounts other than earning generated in current period are translated into US$ at the appropriate historical rates. Income and expense items are translated into US$ using the periodic average exchange rates. The resulting foreign currency translation adjustments are recorded in other comprehensive income in the consolidated statements of comprehensive income (loss), and the accumulated foreign currency translation adjustments are presented as a component of accumulated other comprehensive income in the consolidated statements of shareholders’ equity if any.

Translation of amounts from the local currencies of the Company into US$ has been made at the following exchange rates for the respective periods:

	As of and for the years ended March 31,
	2024		2023
Period-end RMB:US$1 exchange rate		0.138498		0.145611
Period-average RMB:US$1 exchange rate		0.139526		0.145951

F-9

The RMB is not freely convertible into foreign currency and all foreign exchange transactions must take place through authorized institutions. No representation is made that the RMB amounts could have been, or could be, converted into U.S. dollars at the rates used in translation.

Cash and cash equivalents

Cash and cash equivalents consist of cash on hand, demand deposits placed with banks or other financial institutions and have original maturities of less than three months. The Company’s primary bank deposits are located in the PRC.

Accounts receivable and allowance for credit losses

Accounts receivable represents the amounts that the Company has an unconditional right to consideration and is recorded net of allowance for credit losses. The Company estimated allowance for credit losses to reserve for potentially uncollectible receivable amounts periodically, considering factors in assessing the collectability of its accounts receivable, such as historical distribution of the age of the amount due, payment history, creditworthiness, forward-looking factor, historical collections data of. The credit term for the customers of telecommunication engineering services was 90 working days after the quality acceptance checked and the customers of sales of intelligent products was 10 days payment after the contract takes effect (signed and chopped by both parties). The customers, to assess the credit risk characteristics. If there is strong evidence indicating that the accounts receivable is likely to be unrecoverable, the Company also makes specific allowance in the period in which a loss is determined to be probable. Accounts receivable are considered impaired and written-off when it is probable that all contractual payments due will not be collected after all collection efforts have been exhausted.

Property and equipment, net

Property and equipment are carried at cost less accumulated depreciation. Depreciation is provided over their estimated useful lives, using the straight-line method. Estimated useful lives of the property and equipment are as follows:

Categories		Estimated useful life
Office equipment		3-5 years
Office furniture		5 years
Leasehold improvement		10 years
Communication equipment		3 years

The cost of maintenance and repairs is charged to expenses as incurred, whereas significant renewals and betterments are capitalized.

Intangible assets, net

Indefinite-lived intangible assets are tested for impairment at least annually and are reviewed for impairment whenever events or changes in circumstances indicate that the carrying amount of an asset may not be recoverable. Indefinite-lived intangible assets are impaired if their estimated fair values are less than their carrying values.

Finite-lived intangible assets are carried at cost less accumulated amortization and impairment if any. The finite-lived intangible assets are amortized over their estimated useful lives, which are the period over which the assets are expected to contribute directly or indirectly to the future cash flows of the Company. These intangible assets are tested for impairment at the time of a triggering event, if one were to occur. Finite-lived intangible assets may be impaired when the estimated undiscounted future cash flows generated from the assets are less than their carrying amounts.

The Company may rely on a qualitative assessment when performing impairment test for its intangible asset. Otherwise, the impairment evaluation is performed at the lowest level of identifiable cash flows independent of other assets.

The Company’s intangible assets mainly represented project management system purchased by the Company. The project management system is classified as finite-lived intangible assets and amortized over its useful life of 10 years.

Operating leases

The Company adopted Accounting Standards Update (“ASU”) 2016-02, Lease (FASB ASC Topic 842) to account its lease on March 1, 2022.

At inception of a contract, the Company assesses whether a contract is, or contains, a lease. A contract is or contains a lease if it conveys the right to control the use of an identified asset for a period of time in exchange of a consideration. To assess whether a contract is or contains a lease, the Company assess whether the contract involves the use of an identified asset, whether it has the right to obtain substantially all the economic benefits from the use of the asset and whether it has the right to control the use of the asset.

The Company classifies a lease as a financing lease at lease commencement when the lease meets any one of the criteria:

a.	The lease transfers ownership of the underlying asset to the lessee by the end of the lease term.
b.	The lease grants the lessee an option to purchase the underlying asset that the lessee is reasonably certain to exercise.
c.	The lease term is for a major part of the remaining economic life of the underlying asset.
d.	The present value of the sum of the lease payments and any residual value guaranteed by the lessee that is not already reflected in the lease payments equals or exceeds substantially all of the fair value of the underlying asset.
e.	The underlying asset is of such a specialized nature that it is expected to have no alternative use to the Company at the end of the lease term.

When none of the criteria are met, the Company classifies a lease as an operating lease.

F-10

The right-of-use assets and related lease liabilities are recognized at the lease commencement date. The Company recognizes operating lease expenses on a straight-line basis over the lease term.

Leases with an initial term of 12 months or less are short-term lease and not recognized as right-of-use assets and operating lease liabilities on the consolidated balance sheet. The Company recognizes lease expense for short-term leases on a straight-line basis over the lease term.

The right-of-use of asset is initially measured at cost, which comprises the initial amount of the lease liability adjusted for any lease payments made at or before the commencement date, plus any initial direct costs incurred and less any lease incentive received.

Operating lease liabilities are recognized based on the present value of the lease payments not yet paid, discounted using the average borrowing rate of the Company’s outstanding loans.

Lease term includes rent holidays and options to extend or terminate the lease when the Company is reasonably certain that the Company will exercise that option. The lease assets for operating leases consist of the amount of the measurement of the lease liabilities and any prepaid lease payments. Operating lease expense is recognized on a straight-line basis over the lease term by adding interest expense determined using the effective interest method to the amortization of the right-of-use assets. Interest expense is determined using the effective interest method. The Company’s lease agreements do not contain any material residual value guarantees or material restrictive covenants.

The Company reviews the impairment of its right-of-use assets consistent with the approach applied for its other long-lived assets. The Company reviews the recoverability of its long-lived assets when events or changes in circumstances occur that indicate that the carrying value of the asset may not be recoverable. The assessment of possible impairment is based on its ability to recover the carrying value of the asset from the expected undiscounted future pre-tax cash flows of the related operations. The Company has elected to include the carrying amount of operating lease liabilities in any tested asset Company and include the associated operating lease payments in the undiscounted future pre-tax cash flows.

Revenue recognition

The Company follows the guidance of ASC 606, revenue from contracts with customers is recognized using the following five steps:

	1.	Identify the contract(s) with a customer;
	2.	Identify the performance obligations in the contract;
	3.	Determine the transaction price;
	4.	Allocate the transaction price to the performance obligations in the contract; and
	5.	Recognize revenue when (or as) the entity satisfies a performance obligation.

Under Topic 606, revenues are recognized when the promised products have been confirmed of delivery or services have been transferred to the customers in amounts that reflect the consideration the customer expects to be entitled to in exchange for those services. The Company presents value added taxes (“VAT”) as reductions of revenues. The Company recognizes revenues net of value added taxes (“VAT”) and relevant charges.

Telecommunication Construction Services

The Company recognizes revenue from provision of Telecommunication Construction Services over time because the Company’s construction activities create or enhance assets controlled by the customers. The Company adopts the input method to measure performance progress and revenue is recognized based on the proportion of the actual costs incurred relative to the estimated total costs. Where the performance progress cannot be determined reasonably, revenue is recognized based on the amount of cost that is expected to be compensated based on the cost already incurred, until the performance progress can be reasonably determined.

Intelligent products

The Company recognizes the net product revenues from the product sales model on a gross basis as the Company is acting as a principal in these transactions and is responsible for fulfilling the promise to provide the specified goods. The Company generates revenue primarily from the sales of intelligent products directly to the customers, with majority of sales transactions were conducted offline. The Company recognizes product revenue at a point in time when the control of the products has been transferred to customers. The transfer of control is considered complete when products have been picked up by or delivered to our customers. The Company accounts for shipping and handling fees as a fulfillment cost.

F-11

The following table provides information about disaggregated revenue based on revenue by product types:

	For the years ended March 31,
	2024		2023
Telecommunication engineering services	$	5,968,562	$	6,494,640
Intelligent products		17,580,582		-
Total	$	23,549,144	$	6,494,640

Contract liabilities

A contract liability is recognized when the customer pays consideration before the Company recognizes the related revenue. A contract liability would also be recognized if the Company has an unconditional right to receive consideration before the Company recognizes the related revenue. In such cases, a corresponding receivable would also be recognized. As of March 31, 2024 and 2023, the Company had contract liabilities of $8,112 and $339,796, respectively.

Cost of revenues

Amounts recorded as cost of revenues relate to direct expenses incurred in order to generate revenue. Cost of revenues consists primarily of (i) purchase of goods, (ii) costs of telecommunication construction services and (iii) taxes and surcharges.

General and administrative expenses

General and administrative expenses consist primarily of salary and welfare for general and administrative personnel, rental expenses, entertainment expenses, freight, general office expenses and professional service fees.

Research and development expenses

Research and development expenses consist primarily of payroll and related expenses for research and development employees involved in designing, developing and maintaining telecommunication information system, and technology infrastructure costs. The Company expects the research and development expenses to increase in absolute amounts in the foreseeable future as the Company continues to invest in technology and innovation to expand the technology capabilities.

Value-added taxes

Revenue is recognized net of value-added taxes (“VAT”). The VAT is based on gross sales price and VAT rates applicable to the Company is 13%. Entities that are VAT general taxpayers are allowed to offset qualified input VAT paid to suppliers against their output VAT liabilities. Net VAT balance between input VAT and output VAT is recorded as VAT payable if output VAT is larger than input VAT and is recorded as VAT recoverable if input VAT is larger than output VAT. For entities that are qualified for VAT small taxpayers, entities are allowed to enjoy preferential tax rate from 3% to 1% for the period from January 1, 2022 to March 31, 2022 and preferential tax rate from 3% to 0% for the period from April 1, 2022 to December 31, 2022. All of the VAT returns filed by the Company’s subsidiaries in the PRC, have been and remain subject to examination by the PRC tax authorities for five years from the date of filing. VAT payables are included in accrued liabilities.

Income taxes

The Company followed the liability method of accounting for income taxes in accordance with ASC 740, Income Taxes, or ASC 740. Under this method, deferred tax assets and liabilities are determined based on the difference between the financial reporting and tax bases of assets and liabilities using enacted tax rates that will be in effect in the period in which the differences are expected to reverse. The Company recorded a valuation allowance to offset deferred tax assets if based on the weight of available evidence, it is more-likely-than-not that some portion, or all, of the deferred tax assets will not be realized. The effect on deferred taxes of a change in tax rate is recognized in tax expense in the period that includes the enactment date of the change in tax rate.

The Company accounted for uncertainties in income taxes in accordance with ASC 740. Interest and penalties related to unrecognizable tax benefit recognized in accordance with ASC 740 are classified in the consolidated statements of comprehensive income as income tax expense.

Statutory reserves

Statutory reserves are referring to the amount appropriated from the net income in accordance with laws or regulations, which can be used to recover losses and increase capital, as approved, and are to be used to expand production or operations. PRC laws prescribe that an enterprise operating at a profit must appropriate and reserve, on an annual basis, an amount equal to 10% of its profit. Such an appropriation is necessary until the reserve reaches a maximum that is equal to 50% of the enterprise’s PRC registered capital. The Company had $162,784 and $33,675 to statutory reserves as of March 31, 2024 and 2023, respectively, which were included in retained earnings and statutory reserves in the Company’s consolidated balance sheets.

Earnings (loss) per share

The Company computes earnings (loss) per share (“EPS”) in accordance with ASC Topic 260, “Earnings per share”. Basic EPS is measured as the income or loss available to common shareholders divided by the weighted average common shares outstanding for the period. Diluted EPS is similar to basic EPS but presents the dilutive effect on a per share basis of potential common shares (e.g., convertible securities, options, and warrants) as if they had been converted at the beginning of the periods presented, or issuance date, if later. Potential common shares that have an anti-dilutive effect (i.e. those that increase income per share or decrease loss per share) are excluded from the calculation of diluted EPS.

Financial instruments

The Company accounts for financial instruments in accordance to ASC Topic 820, “Fair Value Measurements and Disclosures,” which requires disclosure of the fair value of financial instruments held by the Company and ASC Topic 825, “Financial Instruments,” which defines fair value, and establishes a three-level valuation hierarchy for disclosures of fair value measurement that enhances disclosure requirements for fair value measures. The carrying amounts reported in the consolidated balance sheets for financial assets and liabilities, which primarily consist of cash and cash equivalents, accounts receivable, inventories, prepayments and other current assets, accounts payable, accrued liabilities, income tax payable, customer advances, are a reasonable estimate of their fair values because of the short period of time between the origination of such instruments and their expected realization and their current market rate of interest. The three levels of valuation hierarchy are defined as follows:

● Level 1 inputs to the valuation methodology are quoted prices for identical assets or liabilities in active markets.

● Level 2 inputs to the valuation methodology include quoted prices for similar assets and liabilities in active markets, and inputs that are observable for the asset or liability, either directly or indirectly, for substantially the full term of the financial instrument.

● Level 3 inputs to the valuation methodology are unobservable and significant to the fair value measurement.

F-12

Commitments and contingencies

Liabilities for loss contingencies arising from claims, assessments, litigation, fines and penalties and other sources are recorded when it is probable that a liability has been incurred and the amount of the assessment can be reasonably estimated.

Comprehensive income (loss)

Comprehensive income (loss) is defined to include all changes in equity except those resulting from investments by owners and distributions to owners. Among other disclosures, all items that are required to be recognized under current accounting standards as components of comprehensive income (loss) are required to be reported in a financial statement that is presented with the same prominence as other financial statements. The Company’s current component of other comprehensive income (loss) includes the foreign currency translation adjustment.

Segment reporting

The Company reports each material operating segment in accordance with ASC 280, “Segment Reporting”. Operating segments are defined as components of an enterprise about which separate financial information is available that is evaluated regularly by the chief operating decision maker in deciding how to allocate resources and in assessing performance. The Company’s chief operating decision maker is the chief executive officer. The Company has determined that it has only one operating segment.

Significant risk

Currency risk

Except for the expenses US$45,539 and US$16,503 for the year ended March 31, 2024 and 2023 respectively are in US$, other expenses derived from PRC subsidiary, and the expense transactions are denominated in RMB and US$97,535 liabilities and US$97,535 equity as of March 31, 2024 and US$51,996 liabilities and US$51,996 equity as of March 31, 2023 are in US$, other assets, liabilities and equity transactions are denominated in RMB. RMB is not freely convertible into foreign currencies. In the PRC, certain foreign exchange transactions are required by law to be transacted only by authorized financial institutions at exchange rates set by the People’s Bank of China (“PBOC”). Remittances in currencies other than RMB by the Company in the PRC must be processed through the PBOC or other Company foreign exchange regulatory bodies which require certain supporting documentation in order to affect the remittance.

The Company maintains certain bank accounts in the PRC. On May 1, 2015, the PRC’s new Deposit Insurance Regulation came into effect, pursuant to which banking financial institutions, such as commercial banks, established in the PRC are required to purchase deposit insurance for deposits in RMB and in foreign currency placed with them. Such Deposit Insurance Regulation would not be effective in providing complete protection for the Company’s accounts, as its aggregate deposits are much higher than the compensation limit, which is RMB500,000 for one bank. However, the Company believes that the risk of failure of any of these Chinese banks is remote. Bank failure is uncommon in the PRC and the Company believes that those Chinese banks that hold the Company’s cash and cash equivalents are financially sound based on public available information.

Other than the deposit insurance mechanism in the PRC mentioned above, the Company’s bank accounts are not insured by Federal Deposit Insurance Corporation insurance or other insurance.

Concentration and credit risk

Financial instruments that potentially subject the Company to the concentration of credit risks consist of cash and short-term investments. The maximum exposures of such assets to credit risk are their carrying amounts as of the balance sheet dates. The Company deposits its cash and cash equivalents with financial institutions located in jurisdictions where the subsidiaries are located. The Company believes that no significant credit risk exists as these financial institutions have high credit quality.

The Company also exposures to credit risk associated with its trading and other activities is measured on an individual counterparty basis, as well as by Company of counterparties that share similar attributes. Concentrations of credit risk can be affected by changes in political, industry, or economic factors. To reduce the potential for risk concentration, the Company generally requires payment after delivery of the services within 90 to 120 days and advanced payment acquired before delivery of goods. Credit limits are established and exposure is monitored in light of changing counterparty and market conditions. For the year ended March 31, 2024, three customers accounted for more than 10% of the Company’s total revenues which totaled of 68% revenues and 31% accounts receivable. For the year March 31, 2023, four customers accounted for more than 10% of the Company’s total revenues which totaled of 88% revenues and 89% accounts receivable. For the year ended March 31, 2024, the Company had one supplier that accounted for more than 10% of the Company’s total cost of revenues which totaled of 81% and nil% accounts payable. For the year ended March 31, 2023, the Company had three suppliers that accounted for more than 10% of the Company’s total cost of revenues which totaled of 41% cost of revenues and 59% accounts payable.

Interest rate risk

Fluctuations in market interest rates may negatively affect our financial condition and results of operations. The Company is exposed to floating interest rate risk on cash deposit and floating rate borrowings, and the risks due to changes in interest rates is not material. The Company has not used any derivative financial instruments to manage our interest risk exposure.

Related party transaction

A related party is generally defined as (i) any person that holds 10% or more of the Company’s securities and their immediate families, (ii) the Company’s management, (iii) someone that directly or indirectly controls, is controlled by or is under common control with the Company, or (iv) anyone who can significantly influence the financial and operating decisions of the Company. A transaction is considered to be a related party transaction when there is a transfer of resources or obligations between related parties.

Transactions involving related parties cannot be presumed to be carried out on an arm’s-length basis, as the requisite conditions of competitive, free market dealings may not exist. Representations about transactions with related parties, if made, shall not imply that the related party transactions were consummated on terms equivalent to those that prevail in arm’s-length transactions unless such representations can be substantiated.

F-13

Recent Accounting Pronouncement

In November 2023, the FASB issued ASU No. 2023-07 (“ASU 2023-07”), Segment Reporting (Topic 280): Improvements to Reportable Segment Disclosures to improve reportable segment disclosure requirements, primarily through enhanced disclosures about significant segment expenses. ASU 2023-07 is effective for fiscal years beginning after December 15, 2023 on a retrospective basis. Early adoption is permitted. The Group is currently evaluating the impact of this accounting standard update on its consolidated financial statements and related disclosures.

In December 2023, the FASB issued ASU No. 2023-09 (“ASU 2023-09”), Income Taxes (Topic 740): Improvement to Income Tax Disclosures to enhance the transparency and decision usefulness of income tax disclosures. ASU 2023-09 is effective for annual periods beginning after December 15, 2024 on a prospective basis. Early adoption is permitted. The Group is currently evaluating the impact of this accounting standard update on its consolidated financial statements and related disclosures.

NOTE 3 – PREPAYMENTS AND OTHER CURRENT ASSETS, NET

Prepayments and other current assets consisted of the following as of March 31, 2024 and 2023:

	As of March 31,
	2024			2023
Prepaid to suppliers	$	25,833		$	57,345
Deposits of rental and project		323,320			61,837
Advances to employees		37,954			39,184
Other prepaid operating expenses		766,556			3,354
Total prepayments and other current assets		1,153,663			161,720
Less: Allowance for doubtful accounts		(4,438	)		(2,047	)
Prepayments and other current assets, net	$	1,149,225		$	159,673

Allowance for doubtful accounts movement is as follows:

	As of March 31,
	2024			2023
Beginning balance	$	(2,047	)	$	-
Additions to allowance		(2,491	)		(2,047	)
Foreign currency translation adjustment		100			-
Ending balance	$	(4,438	)	$	(2,047	)

NOTE 4 – ACCOUNTS RECEIVABLE, NET

Accounts receivable consisted of the following as of March 31, 2024 and 2023:

	As of March 31,
	2024			2023
Accounts receivable	$	9,932,684		$	5,715,660
Less: Allowance for doubtful accounts		(186,649	)		-
Account receivable, net	$	9,746,035		$	5,715,660

Allowance for doubtful accounts movement is as follows:

	As of March 31,
	2024			2023
Beginning balance	$	-		$	-
Additions to allowance		(186,649	)		-
Foreign currency translation adjustment		-			-
Ending balance	$	(186,649	)	$	-

NOTE 5 – PROPERTY AND EQUIPMENT, NET

Property and equipment consisted of the following as of March 31, 2024 and 2023:

	As of March 31,
	2024			2023
Office equipment	$	9,322		$	5,124
Furniture equipment		16,695			16,018
Communication equipment		39,582			14,295
Leasehold improvement		116,483			116,483
Total property and equipment		182,082			151,920
Less: Accumulated depreciation		(38,397	)		(12,408	)
Foreign currency translation adjustment		(7,422	)		-
Property and equipment, net	$	136,263		$	139,512

Depreciation expense, which was included in cost of revenues and general and administrative expenses, for the years ended March 31, 2024 and 2023 was $26,594 and $12,408, respectively.

F-14

NOTE 6 – INTANGIBLE ASSETS

Intangible assets and related accumulated amortization were as follows:

	As of March 31,
	2024			2023
Management Information System	$	416,003		$	416,003
Less: Accumulated amortization		(76,092	)		(41,600	)
Foreign currency translation adjustment		(50,760	)		(32,002	)
Total	$	289,151		$	342,401

Amortization expense for the years ended March 31, 2024 and 2023 was $36,524 and $38,400, respectively, included in cost of revenues and general and administrative expenses. During the years ended March 31, 2024 and 2023, the Company recognized impairment loss of nil and nil, respectively.

As of March 31, 2024, the future estimated amortization costs for intangible assets are as follows:

2025	$	34,320
2026		34,320
2027		34,320
2028		34,320
2029		34,320
Thereafter		117,551
Total	$	289,151

NOTE 7 – ACCRUED EXPENSES AND OTHER PAYABLE

Accrued expenses and other payable consisted of the following:

	As of March 31,
	2024		2023
Staff salaries and welfare payables	$	145,512	$	82,467
Engineering labor costs payable		2,131,664		528,763
VAT and other tax payables		713,510		224,440
Others		1,163,054		378,940
	$	4,153,740	$	1,214,610

As of March 31, 2024 and 2023, the engineering labor costs accrued according to the progress of the project. Unpaid costs mainly due to the project not completed and accepted. Others represent loan from individuals and expenses paid on behalf of staffs.

NOTE 8 – CONTRACT LIABILITIES

	As of March 31,
	2024		2023
Billings in advance of performance	$	8,112	$	339,796

As of March 31, 2024 and 2023, billings in advance of performance are expected to be recognized as income within one year.

NOTE 9 - INCOME TAXES

United States of America

The Company is registered in the State of Wyoming and is subject to United States of America tax law. The U.S. federal income tax rate is 21%.

British Virgin Islands

The Company’s subsidiary incorporated in the British Virgin Islands is not subject to income or capital gains tax under the current laws of the British Virgin Islands. The British Virgin Islands does not impose withholding tax on dividend payments.

Hong Kong

Under the current Hong Kong Inland Revenue Ordinance, our subsidiaries incorporated in Hong Kong are subject to a two-tiered profits tax rates regime. Under the two-tiered profits tax rates regime, the first HK$2.0 million of profits of the qualifying Company entity will be taxed at 8.25%, and profits above HK$2.0 million will be taxed at 16.5%. We do not have operations in our Hong Kong subsidiaries and we will not be subject to profits tax. In addition, dividend payments to us are not subject to Hong Kong withholding tax.

The PRC

Generally, the Company’s WFOE, which are considered PRC resident enterprises under PRC tax law, are subject to enterprise income tax on their worldwide taxable income as determined under PRC tax laws and accounting standards at a rate of 25%.

In January 2019, the State Administration of Taxation announced that from January 1, 2019 to December 31, 2021, small and low-profit enterprises can enjoy a 20% corporate income tax rate on 25% of their taxable income amount for the proportion of taxable income not exceeding RMB1 million; and a 20% corporate income tax on 50% of their taxable income amount of more than RMB1 million but not exceeding RMB3 million. The State Administration of Taxation further announced that from January 1, 2021 to December 31, 2022, for the portion of taxable income not exceeding RMB1 million, the amount of taxable income can be halved from 25% to 12.5%, and the corporate income tax will be levied at 20%, for small and low-profit enterprises, and from January 1, 2022 to December 31, 2024, small and low-profit enterprises can enjoy a 20% corporate income tax rate on 25% of the taxable income amount for the portion of taxable income more than RMB1 million but not exceeding RMB3 million.

F-15

The components of the income tax provision are as follows:

	As of March 31
	2024		2023
Current:
– United States of America	$	-	$
– BVI		-
– Hong Kong		-
– The PRC		453,325		118,828

Deferred
– United States of America		-		-
– BVI		-		-
– Hong Kong		-		-
– The PRC		46,876		(944	)
Total	$	500,201	$	117,884

A summary of United States and foreign income (loss) before income taxes was composed of the following:

	As of March 31
	2024			2023
Income attributed to PRC operations	$	1,700,212		$	463,905
Loss attributed to BVI and Hong Kong		-			-
Loss attributed to U.S.		(45,539	)		(16,503	)
Income (loss) before tax	$	1,745,751		$	447,402

As of March 31, 2024 and 2023, the significant components of the deferred tax assets are summarized below:

	As of March 31
	2024			2023
Balance at the beginning of the year	$	6,606		$	10,771
Exchange difference		(323	)		(829	)
Allowance for doubtful accounts		43,624			(3,336	)
Total deferred tax assets, net	$	49,907		$	6,606

As of March 31, 2024 and 2023, the significant components of the deferred tax liabilities are summarized below:

	As of March 31
	2024			2023
Balance at the beginning of the year	$	7,550		$	10,911
Exchange difference		(368	)		(839	)
Less: valuation allowance		(4,415	)		(2,522	)
Total deferred tax assets, net	$	2,767		$	7,550

F-16

NOTE 10 - RELATED PARTY TRANSACTIONS

Related Parties

Name of related parties		Relationship with the Company
Shenzhen Zhongyun Electronic intelligent Technology Co., Ltd		Xiaocai Yu is the Legal representative and Director of Shenzhen Zhongyun Electronic intelligent Technology Co., Ltd
Shenzhen Zhongyun Holding Investment Company Co., Ltd		Xiaocai Yu is the Legal representative and Director of Shenzhen Zhongyun Holding Investment Company Co., Ltd
Xiaocai Yu		General Manager, Director and Legal representative of PRC Subsidiary
Shenzhen Zhongyun Project Management Software Co., Ltd		Xiaocai Yu is the Legal representative and Director of Shenzhen Zhongyun Holding Investment Company Co., Ltd
Shenzhen Zhongyun Information Technology Co., Ltd		Xiaocai Yu is the Legal representative and Director of Shenzhen Zhongyun Information Technology Co., Ltd
ShuHua Liu		Chief Executive Officer, Director of the Company
Shenzhen Baiyuwang E-commerce Co., Ltd		Significant influenced by the Company
Alpha Cultural Education Consulting (Shenzhen) Co., Ltd		Significant influenced by the Company
Shenzhen Nanshan District Zhongyun Computer Development Center		Xiaocai Yu is the operator of the Center

Amounts due from related parties as of March 31, 2024 and 2023 are as follows:

	As of March 31
	2024		2023
Shenzhen Zhongyun Electronic intelligent Technology Co., Ltd	$	132,958	$	145,611
Shenzhen Zhongyun Holding Investment Company Co., Ltd		44,319		-
Xiaocai Yu		132,733		-
	$	310,010	$	145,611

Amounts due to related parties as of March 31, 2024 and 2023 are as follows:

	As of March 31
	2024		2023
Shenzhen Zhongyun Project Management Software Co., Ltd	$	354,549	$	550,404
Shenzhen Zhongyun Information Technology Co., Ltd		215,245		480,286
Xiaocai Yu		-		35,173
ShuHua Liu		488,099		331,568
Shenzhen Baiyuwang E-commerce Co., Ltd		6,925		72,806
Alpha Cultural Education Consulting (Shenzhen) Co., Ltd		276,996		72,806
Shenzhen Zhongyun Holding Investment Company Co., Ltd		34,625		-
	$	1,376,439	$	1,543,043

F-17

Cost of revenues from related parties during the years ended March 31, 2024 and 2023 is as follows:

	For the years ended March 31,
	2024		2023
Shenzhen Zhongyun Information Technology Co., Ltd	$	-	$	607,148
Shenzhen Zhongyun Electronic Intelligent Technology Co., Ltd		-		1,984
Shenzhen Nanshan District Zhongyun Computer Development Center		575		-
	$	575	$	609,132

Due from related party mainly consists of funds advanced to related parties as borrowings or funds advanced to pay off the Company’s expenses. The balances are unsecured, non-interest bearing.

Due to related parties mainly consists of borrowings for working capital purpose, the balances are unsecured, non-interest bearing and due on demand.

In addition, during the years ended March 31, 2024 and 2023, these related parties paid expenses on the Company’s behalf in an amount of $354,550 and nil, respectively.

NOTE 11 – OPERATING LEASES

As of March 1, 2022, the Company has one operating lease agreements for office spaces in PRC with a non-related party.

As of March 31, 2024, the Company recognized operating lease liabilities, including current and noncurrent, in the amount of $11,066.

	As of March 31,
	2024		2023

Right-of-use assets-operating lease	$	8,542	$	24,375

Operating lease liabilities – current	$	11,066	$	18,567
Operating lease liabilities – non-current		-		11,634
Total lease liabilities	$	11,066	$	30,201

The components of lease expense and supplemental cash flow information related to leases for the years ended March 31, 2024 and 2023 are as follows:

Other information for the years ended	2024			2023
Weighted average remaining lease term (in month)		7			19
Weighted average discount rate		5	%		5	%

Lease expenses were $30,506 and $16,678 for the years ended March 31, 2024 and 2023, respectively.

F-18

NOTE 12 – BANK AND OTHER BORROWINGS

In February 2023, the Company obtained a loan in the principal amount of RMB1,430,000 (approximately $208,224 when borrowed) from WeBank, which bears interest at 15.05%. The loan is guaranteed by Xiaocai Yu, a related party. The maturity date is on February 20, 2025. The loan was fully repaid in February 2024.

In March 2023, the Company obtained a loan in the principal amount of RMB2,990,000 (approximately $435,377 when borrowed) from Bank of China, which bears interest at 3.85%. The loan is guaranteed by Xiaocai Yu, a related party. The maturity date is on March 27, 2024. The loan was fully repaid in March 2024.

In August 2023, the Company obtained a loan in the principal amount of RMB3,000,000 (approximately $415,494 when borrowed) from Bank of Communications, which bears interest at 5.00%. The loan is guaranteed by Xiaocai Yu, a related party, and pledged by her property. The maturity date is on July 27, 2024. The loan was fully repaid in August 2024.

In February 2024, the Company obtained a loan in the principal amount of RMB1,000,000 (approximately $138,498 when borrowed) from WeBank, which bears interest at 16.70%. The loan is guaranteed by Xiaocai Yu, a related party. The maturity date is on January 20, 2026.

In February 2024, the Company obtained a loan in the principal amount of RMB817,142.84 (approximately $114,013 when borrowed) from WeBank, which bears interest at 15.05%. The loan is guaranteed by Xiaocai Yu, a related party. The maturity date is on February 20, 2026.

In March 2024, the Company obtained a loan in the principal amount of RMB2,990,000 (approximately $414,109 when borrowed) from Bank of China, which bears interest at 3.00%. The loan is guaranteed by Xiaocai Yu, a related party. The maturity date is on March 27, 2025.

In March 2024, the Company obtained a loan in the principal amount of RMB3,000,000 (approximately $415,494 when borrowed) from SPD Bank, which bears interest at 4.45%. The loan is guaranteed by Xiaocai Yu, a related party. The maturity date is on March 29, 2025.

The balance of the loans borrowed as of March 31, 2024 and 2023 was as follows:

	As of March 31,
	2024		2023
Bank loan from the Bank of China	$	414,109	$	435,377
Bank of Communications		270,071		-
SPD Bank		415,494		-
WeBank		390,169		208,224
Aggregate outstanding principal balances		1,489,843		643,601
Less: current portion		1,351,345		534,531
Non-current portion	$	138,498	$	109,070

The total interest expense was $57,767 and nil for the years ended March 31, 2024 and 2023, respectively.

Future minimum loan payments as of March 31, 2024 are as follows:

Year ending March 31,
2025	$	1,417,296
2026		72,547
Thereafter		-
Total	$	1,489,843

NOTE 13 – CONCENTRATIONS OF RISK

(a) Major customers

For the year ended March 31, 2024, the customers who accounted for more than 10% of the Company’s revenues and the accounts receivable balances at period-end are presented as follows:

	For the year ended March 31, 2024					As of March 31, 2024
	Revenues		Percentage of revenues			Accounts receivable
Customer A	$	9,444,182		40	%	$	-
Customer B		3,662,397		16	%		-
Customer C		2,875,678		12	%		3,098,332
Total	$	15,982,257		68	%	$	3,098,332

For the year ended March 31, 2023, the customers who accounted for more than 10% of the Company’s revenues and the accounts receivable balances at period-end are presented as follows:

	For the year ended March 31, 2023					As of March 31, 2023
	Revenues		Percentage of revenues			Accounts receivable
Customer D	$	2,182,128		34	%	$	2,213,176
Customer E		1,501,579		23	%		1,324,444
Customer F		1,060,195		16	%		635,063
Customer G		954,089		15	%		888,949
Total	$	5,697,991		88	%	$	5,061,632

(b) Major vendors

For the year ended March 31, 2024, the vendors who accounted for 10% or more of the Company’s cost of revenues and its accounts payable balance at period-end are presented as follows:

	For the year ended March 31, 2024					As of March 31, 2024
	Purchases		Percentage of purchases			Accounts payable
Vendor A	$	16,463,377		81	%	$	-
Total	$	16,463,377		81	%	$	-

For the year ended March 31, 2023, the vendors who accounted for 10% or more of the Company’s cost of revenues and its accounts payable balance at period-end are presented as follows:

	For the year ended March 31, 2023					As of March 31, 2023
	Purchases		Percentage of purchases			Accounts payable (Due to related parties)
Vendor B	$	970,743		19	%	$	664,875
Vendor C, a related party		607,148		12	%		215,245
Vendor D		517,152		10	%		274,469
Total	$	2,095,043		41	%		1,154,586

Financial instruments that are potentially subject to credit risk consist principally of accounts receivable. The Company does not generally require collateral from customers. The Company evaluates the need for an allowance for doubtful accounts based upon factors surrounding the credit risk of specific customers, historical trends and other information.

The related party transactions are generally transacted in an arm-length basis at the current market value in the normal course of business.

NOTE 14 – EARNINGS PER SHARE

The following table sets forth the basic and diluted net income per common share computation and provides a reconciliation of the numerator and denominator for the years presented:

	For the years ended March 31,
	2024		2023
Numberator:
Net income	$	1,245,550	$	329,518
Net income attributable to Alpha One Inc.’s shareholders - basic		1,245,550		329,518
Net income attributable to Alpha One Inc.’s shareholders - diluted		1,245,550		329,518
Denominator
Weighted average common shares outstanding-basic		76,809,533		76,809,533
Weighted average common shares outstanding-diluted		76,809,533		76,809,533

Net income/(loss) per common share
- Basic	$	0.02	$	0.01
- Diluted	$	0.02	$	0.01

NOTE 15 - SUBSEQUENT EVENTS

F-19

Alpha One Inc. and Subsidiaries

CONDENSED CONSOLIDATED BALANCE SHEETS

AS OF SEPTEMBER 30, 2024 AND MARCH 31, 2024

	September 30, 2024			March 31, 2024
	(Unaudited)
Assets
Current assets
Cash and cash equivalents	$	3,225		$	383,682
Accounts receivable, net		9,632,028			9,746,035
Prepayments and other receivables, net		1,706,841			1,149,225
Due from related party		150,708			310,010
Total current assets		11,492,802			11,588,952

Non-current assets
Operating lease right-of-use assets		1,255			8,542
Property and equipment, net		125,658			136,263
Deferred tax assets		94,036			49,907
Intangible assets, net		278,692			289,151
Total Assets	$	11,992,443		$	12,072,815

Liabilities and Stockholders’ Equity
Accounts payable		1,208,325			1,513,854
Accrued expenses and other payables		4,426,149			4,153,740
Bank and other borrowings, current		1,433,657			1,351,345
Contract liabilities		8,345			8,112
Deferred tax liability		412			2,767
Due to related parties		2,084,224			1,376,439
Income tax payable		671,523			653,168
Operating lease liabilities, current		1,647			11,066
Total current liabilities		9,834,282			9,070,491

Non-current liabilities
Bank and other borrowings, non-current		88,788			138,498
Total Liabilities		9,923,070			9,208,989

Stockholders’ Equity
Preferred stock (500,000 preferred stock authorized, 500,000 preferred stock issued and nil outstanding as of September 30, 2024 and March 31, 2024)		-			-
Common stock (450,000,000 shares authorized, 76,809,533 shares issued and outstanding as of September 30, 2024 and March 31, 2024)		76,809			76,809
Additional paid-in capital		1,520,893			1,520,893
Statutory reserves		163,711			163,711
Retained earning		343,922			1,204,232
Accumulated other comprehensive loss		(35,962	)		(101,819	)
Total Stockholders’ Equity		2,069,373			2,863,826

Total Liabilities and Stockholders’ Equity	$	11,992,443		$	12,072,815

See accompanying notes to the unaudited condensed consolidated financial statements.

F-20

Alpha One Inc. and Subsidiaries

CONDENSED CONSOLIDATED STATEMENTS OF OPERATIONS

AND COMPREHENSIVE INCOME(LOSS)

FOR THE THREE AND SIX MONTHS ENDED SEPTEMBER 30, 2024 AND 2023

(Unaudited)

	Three months ended September 30,						Six months ended September 30,
	2024			2023			2024			2023
Net revenues	$	153,297		$	1,873,136		$	472,142		$	3,399,276
Cost of revenues (including nil and nil from related parties for the three months ended September 30, 2024, respectively; $227,864 and $575 from related parties for the six months ended September 30, 2024, respectively)		(258,656	)		(1,314,050	)		(575,089	)		(1,960,401	)
Gross (loss) profit		(105,359	)		559,086			(102,947	)		1,438,875

Operating expenses:
General and administrative expenses		273,397			236,645			413,326			347,767
Research and development		27,259			44,128			55,695			95,343
Finance cost		543			875			822			1,080
Other operating expenses		87,219			69,649			173,756			82,717
		(388,418	)		(351,297	)		(643,599	)		(526,907	)

Operating (loss) income		(493,777	)		207,789			(746,546	)		911,968

Other income (expense):
Other income		1			(9,077	)		162			422
Other expense		(327	)		(744	)		(390	)		(898	)
Interest income		5			20			42			65
Interest expense		(120,086	)		(221,716	)		(158,194	)		(248,578	)
Other expense, net		(120,407	)		(231,517	)		(158,380	)		(248,989	)

(Loss) income before income tax		(614,184	)		(23,728	)		(904,926	)		662,979

Income tax expense		23,715			26,613			44,616			(150,113	)

Net (loss) income	$	(590,469	)	$	2,885		$	(860,310	)	$	512,866

Other comprehensive income (loss):
Foreign currency translation		84,047			5,274			65,857			(97,851	)
Total comprehensive (loss) income		(506,422	)		8,159			(794,453	)		415,015

(Loss) earnings per share
Basic and diluted (loss) earnings per share	$	(0.01	)	$	0.00		$	(0.01	)	$	0.01
Basic and diluted weighted average shares outstanding		76,809,533			76,809,533			76,809,533			76,809,533

See accompanying notes to the unaudited condensed consolidated financial statements.

F-21

Alpha One Inc. and Subsidiaries

CONDENSED CONSOLIDATED STATEMENTS OF CHANGES IN STOCKHOLDERS’ EQUITY

FOR THE THREE AND SIX MONTHS ENDED SEPTEMBER 30, 2024 AND 2023

(Unaudited)

	No. of		Common		Additional Paid-in		Statutory		Retained earnings (accumulated			Accumulated Other Comprehensive			Total Stockholders’
	Shares		Stock		Capital		Reserves		Deficits)			Income (Loss)			Equity
Balance as of March 31, 2024		76,809,533	$	76,809	$	1,520,893	$	163,711	$	1,204,232		$	(101,819	)	$	2,863,826
Foreign currency translation adjustment		-		-		-		-		-			(18,190	)		(18,190	)
Net loss for the period		-		-		-		-		(269,841	)		-			(269,841	)
Balance as of June 30, 2024		76,809,533	$	76,809	$	1,520,893	$	163,711	$	934,391		$	(120,009	)	$	2,575,795
Foreign currency translation adjustment		-		-		-		-		-			84,047			84,047
Net loss for the period		-		-		-		-		(590,469	)		-			(590,469	)
Balance as of September 30, 2024		76,809,533	$	76,809	$	1,520,893	$	163,711	$	343,922		$	(35,962	)	$	(2,069,373	)

	No. of		Common		Additional Paid-in		Statutory		Retained earnings (accumulated		Accumulated Other Comprehensive			Total Stockholders’
	Shares		Stock		Capital		Reserves		Deficits)		Income (Loss)			Equity
Balance as of March 31, 2023		76,809,533	$	76,809	$	1,203,973	$	34,602	$	87,791	$	(24,019	)	$	1,379,156
Foreign currency translation adjustment		-		-		-		-		-		(103,125	)		(103,125	)
Net income for the period		-		-		-		52,562		457,419		-			509,981
Balance as of June 30, 2023		76,809,533	$	76,809	$	1,203,973	$	87,164	$	545,420	$	(127,144	)	$	1,786,012
Additional paid in capital		-		-		116,035		-		-		-			116,035
Foreign currency translation adjustment		-		-		-		-		-		5,274			5,274
Net income for the period		-		-		-		451		2,434		-			2,885
Balance as of September 30, 2023		76,809,533	$	76,809	$	1,320,008	$	87,615	$	547,644	$	(121,870	)	$	1,910,206

See accompanying notes to the unaudited condensed consolidated financial statements.

F-22

Alpha One Inc. and Subsidiaries

CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS

FOR THE SIX MONTHS ENDED SEPTEMBER 30, 2024 AND 2023

(Unaudited)

	Six months ended September 30,
	2024			2023
Cash flows from operating activities
Net income (loss)	$	(860,310	)	$	512,866
Adjustments to reconcile net income (loss) to net cash provided by (used in) operating activities:
Depreciation and amortization expense		32,472			31,244
Noncash lease expense		7,287			8,632
Allowance for doubtful accounts		178,201			80,940
Deferred tax		(42,691	)		(18,412	)
Changes in operating assets and liabilities
Accounts receivable		(60,534	)		(1,985,078	)
Prepayments and other receivables		(561,276	)		(91,631	)
Accounts payable		(305,529	)		(271,255	)
Accrued liabilities		269,974			1,403,511
Contract liabilities		233			(339,796	)
Income tax payable		18,355			160,552
Operating lease obligations		(9,419	)		(8,551	)
Net cash (used in) operating activities		(1,333,237	)		(516,978	)

Cash flows from investing activity
Purchase of property and equipment		-			(28,959	)
Net cash (used in) investing activity		-			(28,959	)

Cash flows from financing activities
Borrowings from (Repayments to) bank loans		(10,319	)		354,286
Borrowings from (Repayments to) related parties		867,087			(109,482	)
Capital injection		-			116,035
Net cash provided by financing activities		856,768			360,839

Effect of exchange rate changes on cash and cash equivalents		96,012			(107,020	)
Net changes in cash and cash equivalents		(380,457	)		(292,118	)
Cash and cash equivalents–beginning of the period		383,682			329,994

Cash and cash equivalents–end of the period	$	3,225		$	37,876

Supplementary cash flow information:
Interest paid	$	158,194		$	248,578
Income taxes paid	$	278		$	1,389

See accompanying notes to the unaudited condensed consolidated financial statements.

F-23

Alpha One Inc. and Subsidiaries

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

FOR THE THREE AND SIX MONTHS ENDED SEPTEMBER 30, 2024 AND 2023

NOTE 1 - ORGANIZATION AND DESCRIPTION OF BUSINESS

On February 8, 2021, the previously issued 100,000,000 shares of common stock were canceled in connection with changes in the Company’s strategic direction.

On September 10, 2021, the Company effectuated a 100-for-1 reverse stock split, which resulted in a new total of 1,359,447 shares of common stock.

On February 8, 2022, the Company convert 500,000 of its Series A Preferred Stock into common stock with a ratio of 100 for 1.

Upon completion of the merger, all of the outstanding shares of Zhongyun BVI’s common stock were exchanged for 25,450,086 shares of common stock of AOAO. Prior to the merger, Shuhua Liu and her spouse directly and indirectly obtained the total 49.65% controlled of AOAO, and 50% indirectly controlled of Zhongyun BVI by Zhongyun Global International Group Limited. Shuhua Liu is the sole director of AOAO and Zhongyun BVI. Following the Merger, Shuhua Liu and her spouse directly and indirectly obtained the total 49.77% controlled of AOAO. As AOAO and Zhongyun BV were under common control at the time of the share exchange, the transaction is accounted for as a combination of entities under common control in a manner similar to the pooling-of-interests method of accounting. Immediately after completion of such share exchange, the Company has a total of 76,809,533 issued and outstanding shares of common stock, with authorized share capital for common shares of 450,000,000.

On November 16, 2023, the former director and CEO Zhuo Wang transferred 19,890,000 shares to Sun Horn Limited, 4,239,742 shares to Shuhua Liu and 1,370,258 shares Xinli Chen for free.

Zhongyun (BVI) Limited (“Zhongyun BVI”) was incorporated in the British Virgin Islands on December 6, 2022 with limited liability.

NOTE 2 - SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES

Going concern

The accompanying consolidated financial statements have been prepared assuming that the Company will continue as a going concern, which contemplates the realization of assets and the discharge of liabilities in the normal course of business for the foreseeable future. For the six months ended September 30, 2024, the Company incurred a net loss of $860,310 and used cash in operating activities of $1,337,237. For the three months ended September 30, 2024, the Company had incurred a net loss of $590,469. These factors raise substantial doubt about the Company’s ability to continue as a going concern within one year after the date the financial statements are issued. The Company’s financial statements do not include any adjustments that might result from the outcome of this uncertainty should we be unable to continue as a going concern.

Management estimates that the current funds on hand will be sufficient to continue operations through the next 12 months. The continuation of the Company as a going concern is dependent upon (1) there was $6.25 million overdue one year (aging over 360 days) as of September 30, 2024, the Company will accelerate the collection of accounts receivable, $2.5 million will be received as of June 30, 2025, and $2.79 million to be collected in the next 12 months that based on the agreed extra payment term on the ongoing contracts. From October 2024 to January 2025, the Company has collected $1.15 million out of the $2.5 million, and regards of well-known reputation of customers, we assume that we will be able to successfully collect such amounts within the extra payment term; (2) the continued financial support from its stockholders or its ability to obtain external financing; (3) further to make the cost controlling; and (4) implement management’s business plan to extend its operations and generate sufficient revenues to meet its obligations. While the Company believes in the viability of its strategy to increase sales volume and in its ability to raise additional funds, there can be neither any assurances to that effect, nor any assurance that the Company will be successful in securing sufficient funds to sustain the operations. In long-term, the continuation of the Company as a going concern is dependent upon (i) further implement management’s business plan to extend its operations and generate sufficient revenues to meet its obligations; (ii) Shorten customer payment terms and extend supplier payment terms; and (iii) maintain to obtain the revolving credit lines and loans with lower interest from the bank.

Management believes that the actions presently being taken to obtain additional funding and implement its strategic plan provides the opportunity for the Company to continue as a going concern.

Basis of presentation

F-24

Basis of consolidation

As of September 30, 2024, details of the Company’s major subsidiaries were as follows:

Entity Name	Date of Incorporation	Parent Entity	Nature of Operation	Place of Incorporation
Zhongyun (BVI) Ltd	December 6, 2022	AOAO	Investment holding	British Virgin Islands
Zhongyun Investment Hong Kong Ltd	December 23, 2022	Zhongyun BVI	Investment holding	Hong Kong
Shenzhen zhongyun communication technology Co. Ltd	August 25, 2020	Zhongyun HK	Communiciation engineer project service and intelligent products’ trading	Shenzhen, China

Use of estimates

Foreign currency translation and re-measurement

Translation of amounts from the local currencies of the Company into US$ has been made at the following exchange rates for the respective periods:

	As of and for the six months ended September 30,
	2024		2023
Period-end RMB:US$1 exchange rate		0.142488		0.137447
Period-average RMB:US$1 exchange rate		0.138859		0.140513

F-25

Cash and cash equivalents

Accounts receivable and allowance for credit losses

Property and equipment, net

Categories		Estimated useful life
Office equipment		3-5 years
Office furniture		5 years
Leasehold improvement		10 years
Communication equipment		3 years

The cost of maintenance and repairs is charged to expenses as incurred, whereas significant renewals and betterments are capitalized.

Intangible assets, net

Operating leases

The Company adopted Accounting Standards Update (“ASU”) 2016-02, Lease (FASB ASC Topic 842) to account its lease on March 1, 2022.

The Company classifies a lease as a financing lease at lease commencement when the lease meets any one of the criteria:

f.	The lease transfers ownership of the underlying asset to the lessee by the end of the lease term.
g.	The lease grants the lessee an option to purchase the underlying asset that the lessee is reasonably certain to exercise.
h.	The lease term is for a major part of the remaining economic life of the underlying asset.
i.	The present value of the sum of the lease payments and any residual value guaranteed by the lessee that is not already reflected in the lease payments equals or exceeds substantially all of the fair value of the underlying asset.
j.	The underlying asset is of such a specialized nature that it is expected to have no alternative use to the Company at the end of the lease term.

When none of the criteria are met, the Company classifies a lease as an operating lease.

F-26

The right-of-use assets and related lease liabilities are recognized at the lease commencement date. The Company recognizes operating lease expenses on a straight-line basis over the lease term.

Operating lease liabilities are recognized based on the present value of the lease payments not yet paid, discounted using the average borrowing rate of the Company’s outstanding loans.

Revenue recognition

The Company follows the guidance of ASC 606, revenue from contracts with customers is recognized using the following five steps:

	1.	Identify the contract(s) with a customer;
	2.	Identify the performance obligations in the contract;
	3.	Determine the transaction price;
	4.	Allocate the transaction price to the performance obligations in the contract; and
	5.	Recognize revenue when (or as) the entity satisfies a performance obligation.

Under Topic 606, revenues are recognized when the promised products have been confirmed of delivery or services have been transferred to the consumers in amounts that reflect the consideration the customer expects to be entitled to in exchange for those services. The Company presents value added taxes (“VAT”) as reductions of revenues. The Company recognizes revenues net of value added taxes (“VAT”) and relevant charges.

Telecommunication Construction Services

Intelligent products

We recognize the net product revenues from the product sales model on a gross basis as the Company is acting as a principal in these transactions and is responsible for fulfilling the promise to provide the specified goods. We generate revenue primarily from the sales of intelligent products directly to the customers, with majority of sales transactions were conducted offline. We recognize product revenue at a point in time when the control of the products has been transferred to customers. The transfer of control is considered complete when products have been picked up by or delivered to our customers. We account for shipping and handling fees as a fulfillment cost.

The following table provides information about disaggregated revenue based on revenue by product types:

	Three months ended September 30,				Six months ended September 30,
	2024		2023		2024		2023
Telecommunication engineering services	$	153,297	$	1,873,136	$	472,142	$	3,399,276
Intelligent products		-		-		-		-
Total	$	153,297	$	1,873,136	$	472,142	$	3,399,276

F-27

Contract liabilities

Contract liabilities consist mainly of customer advances. On certain occasions, the Company may receive prepayments from downstream retailers or wholesales customers for wines, water and other products prior to them taking possession of the Company’s products. The Company records these receipts as customer advances until the control of the products has been transferred the customers. As of September 30, 2024 and March 31, 2024, the Company had contract liabilities of $8,345 and $8,112, respectively.

Cost of revenues

General and administrative expenses

Research and development expenses

Value-added taxes

Income taxes

Statutory reserves

Statutory reserves are referring to the amount appropriated from the net income in accordance with laws or regulations, which can be used to recover losses and increase capital, as approved, and are to be used to expand production or operations. PRC laws prescribe that an enterprise operating at a profit must appropriate and reserve, on an annual basis, an amount equal to 10% of its profit. Such an appropriation is necessary until the reserve reaches a maximum that is equal to 50% of the enterprise’s PRC registered capital. The Company had $162,784 and $87,615 to statutory reserves as of September 30, 2024 and 2023, respectively, which were included in accumulated deficit and statutory reserves in the Company’s consolidated balance sheets.

Earnings (loss) per share

F-28

Financial instruments

The Company accounts for financial instruments in accordance to ASC Topic 820, “Fair Value Measurements and Disclosures,” which requires disclosure of the fair value of financial instruments held by the Company and ASC Topic 825, “Financial Instruments,” which defines fair value, and establishes a three-level valuation hierarchy for disclosures of fair value measurement that enhances disclosure requirements for fair value measures. The carrying amounts reported in the consolidated balance sheets for financial assets and liabilities, which primarily consist of cash and cash equivalents, accounts receivable, inventories, prepayments and other receivables, accounts payable, accrued liabilities, income tax payable, customer advances, are a reasonable estimate of their fair values because of the short period of time between the origination of such instruments and their expected realization and their current market rate of interest. The three levels of valuation hierarchy are defined as follows:

● Level 1 inputs to the valuation methodology are quoted prices for identical assets or liabilities in active markets.

● Level 3 inputs to the valuation methodology are unobservable and significant to the fair value measurement.

Commitments and contingencies

Comprehensive income (loss)

Segment reporting

Significant risk

Currency risk

Except for the expenses US$115,800 and US$15,641 for the quarterly ended September 30, 2024 and 2023 respectively, are in US$, other expenses derived from PRC subsidiary, and the expense transactions are denominated in RMB and US$213,335 liabilities and US$213,335 equity as of September 30, 2024 and US$67,637 liabilities and US$67,637 equity as of September 30, 2023 are in US$, other assets, liabilities and equity transactions are denominated in RMB. RMB is not freely convertible into foreign currencies. In the PRC, certain foreign exchange transactions are required by law to be transacted only by authorized financial institutions at exchange rates set by the People’s Bank of China (“PBOC”). Remittances in currencies other than RMB by the Company in the PRC must be processed through the PBOC or other Company foreign exchange regulatory bodies which require certain supporting documentation in order to affect the remittance.

Other than the deposit insurance mechanism in the PRC mentioned above, the Company’s bank accounts are not insured by Federal Deposit Insurance Corporation insurance or other insurance.

F-29

Concentration and credit risk

The Company also exposures to credit risk associated with its trading and other activities is measured on an individual counterparty basis, as well as by Company of counterparties that share similar attributes. Concentrations of credit risk can be affected by changes in political, industry, or economic factors. To reduce the potential for risk concentration, the Company generally requires payment after delivery of the goods within 90 to 120 days. Credit limits are established and exposure is monitored in light of changing counterparty and market conditions. For the quarterly ended September 30, 2024, two customers accounted for more than 10% of the Company’s total revenues which totaled of 92% revenues and 55% accounts receivable. For the quarterly ended September 30, 2023, three customers accounted for more than 10% of the Company’s total revenues which totaled of 77% revenues and 38% accounts receivable. For the quarterly ended September 30, 2024, the Company had one supplier (a related party) that accounted for more than 10% of the Company’s total cost of revenues, which totaled of 40% cost of revenue and 4% due to related parties. For the quarterly ended September 30, 2023, the Company had three suppliers that accounted for more than 10% of the Company’s total cost of revenues which totaled of 54% cost of revenue and 53% accounts payable.

Interest rate risk

Related party transaction

Recent Accounting Pronouncement

F-30

NOTE 3 – PREPAYMENTS AND OTHER RECEIVABLES, NET

Prepayments and other receivables consisted of the following as of September 30, 2024 and March 31, 2024:

	September 30, 2024			March 31, 2024
Prepaid to suppliers	$	504,341		$	25,833
Deposit of rental and project		261,391			323,320
Advances to employees		66,624			37,954
Other prepaid operating expenses		882,807			766,556
Total prepayments and other current assets		1,715,163			1,153,663
Less: Allowance for doubtful accounts		(8,322	)		(4,438	)
Prepayments and other current assets, net	$	1,706,841		$	1,149,225

Allowance for doubtful accounts movement is as follows:

	September 30, 2024			March 31, 2024
Beginning balance	$	(4,438	)	$	(2,047	)
Additions to allowance		(3,660	)		(2,491	)
Foreign currency translation adjustment		(224	)		100
Ending balance	$	(8,322	)	$	(4,438	)

NOTE 4 – ACCOUNTS RECEIVABLE, NET

Accounts receivable consisted of the following as of September 30, 2024 and March 31, 2024:

	September 30, 2024			March 31, 2024
Accounts receivable	$	9,998,596		$	9,932,684
Less: Allowance for doubtful accounts		(366,568	)		(186,649	)
Accounts receivable, net	$	9,632,028		$	9,746,035

Allowance for doubtful accounts movement is as follows:

	September 30, 2024			March 31, 2024
Beginning balance	$	(186,649	)	$	-
Additions to allowance		(174,541	)		(186,649	)
Foreign currency translation adjustment		(5,378	)		-
Ending balance	$	(366,568	)	$	(186,649	)

NOTE 5 – PROPERTY AND EQUIPMENT, NET

Property and equipment consisted of the following as of September 30, 2024 and March 31, 2024:

	September 30, 2024			March 31, 2024
Office equipment	$	9,322		$	9,322
Furniture equipment		16,695			16,695
Leasehold improvement		116,483			116,483
Communication equipment		39,582			39,582
Total Property and equipment		182,082			182,082
Less: Accumulated depreciation		(54,047	)		(38,397	)
Foreign currency translation adjustment		(2,377	)		(7,422	)
Property and equipment, net	$	125,658		$	136,263

Depreciation expense, which was included in cost of revenues and general and administrative expenses, for the six months ended September 30, 2024 and 2023 was $14,162 and $12,716 respectively.

F-31

NOTE 6 – INTANGIBLE ASSETS, NET

Intangible assets and related accumulated amortization were as follows:

	September 30, 2024			March 31, 2024
Management Information System	$	416,003		$	416,003
Less: Accumulated amortization		(97,073	)		(76,092	)
Foreign currency translation adjustment		(40,238	)		(50,760	)
Total	$	278,692		$	289,151

Amortization expense for the six months ended September 30, 2024 and 2023 was $18,310 and $18,528, respectively, included in cost of revenues and general and administrative expenses.

As of September 30, 2024, the future estimated amortization costs for intangible assets are as follows:

2025 (remaining)	$	18,788
2026		37,576
2027		37,576
2028		37,576
2029		37,576
Thereafter		109,600
Total	$	278,692

NOTE 7 – ACCRUED EXPENSES AND OTHER PAYABLES

As of September 30, 2024 and March 31, 2024, accrued expenses and other payables consisted of the following:

	September 30, 2024		March 31, 2024

Staff salaries and welfare payables	$	164,758	$	145,512
Engineering labor cost payables		2,405,019		2,131,664
VAT and other tax payables		690,364		713,510
Others		1,166,008		1,163,054
	$	4,426,149	$	4,153,740

As of September 30, 2024 and March 31, 2024, the engineering labor cost was accrued according to the progress of project. Others represent loan from individuals and expenses paid on behalf of staffs.

NOTE 8 – CONTRACT LIABILITIES

	September 30, 2024		March 31, 2024

Billings in advance of performance	$	8,345	$	8,112

As of September 30, 2024 and March 31, 2024, billings in advance of performance are expected to be recognised as income within one year.

F-32

NOTE 9 - INCOME TAXES

United States of America

The Company is registered in the State of Wyoming and is subject to United States of America tax law. The U.S. federal income tax rate is 21%.

British Virgin Islands

Our subsidiary incorporated in the British Virgin Islands is not subject to income or capital gains tax under the current laws of the British Virgin Islands. The British Virgin Islands does not impose withholding tax on dividend payments.

Hong Kong

The PRC

The components of the income tax provision are as follows:

	Six months ended September 30,
	2024			2023
Current tax expense:
– United States of America	$	-		$	-
– BVI		-			-
– Hong Kong		-			-
– The PRC		-			169,655

Deferred income tax expenses (benefits)
– United States of America		-			-
– BVI		-			-
– Hong Kong		-			-
– The PRC		(44,616	)		(19,542	)
Total	$	(44,616	)	$	150,113

A summary of United States and foreign income (loss) before income taxes was composed of the following:

	Six months ended September 30,
	2024			2023
(Loss) income attributed to PRC operations	$	(789,126	)	$	678,620
Loss attributed to BVI and Hong Kong		-			-
Loss attributed to U.S.		(177,842	)		(132,303	)
(Loss) income before tax	$	966,968		$	546,317

As of September 30, 2024 and March 31, 2024, the significant components of the deferred tax assets are summarized below:

	September 30, 2024		March 31, 2024
Balance at the beginning of the year	$	49,907	$	6,606
Exchange difference		1,438		(323	)
Allowance for doubtful accounts		42,691		43,624
Total deferred tax assets, net	$	94,036	$	49,907

As of September 30, 2024 and March 31, 2024, the significant components of the deferred tax liabilities are summarized below:

	September 30, 2024			March 31, 2024
Balance at the beginning of the year	$	2,767		$	7,550
Exchange difference		80			(368	)
Less: valuation allowance		(2,435	)		(4,415	)
Total deferred tax assets, net	$	412		$	2,767

F-33

NOTE 10 - RELATED PARTY TRANSACTIONS

Related Parties

Name of related parties		Relationship with the Company
Shenzhen Zhongyun Electronic intelligent Technology Co., Ltd		Xiaocai Yu is the Legal representative and Director of Shenzhen Zhongyun Electronic intelligent Technology Co., Ltd
Shenzhen Zhongyun Holding Investment Company Co., Ltd		Xiaocai Yu is the Legal representative and Director of Shenzhen Zhongyun Holding Investment Company Co., Ltd
Xiaocai Yu		General Manager, Director and Legal representative of PRC Subsidiary
Shenzhen Zhongyun Project Management Software Co., Ltd		Xiaocai Yu is the Legal representative and Director of Shenzhen Zhongyun Holding Investment Company Co., Ltd
Shenzhen Zhongyun Information Technology Co., Ltd		Xiaocai Yu is the Legal representative and Director of Shenzhen Zhongyun Information Technology Co., Ltd
ShuHua Liu		Chief Executive Officer, Director of the Company
Shenzhen Baiyuwang E-commerce Co., Ltd		Significant influenced by the Company
Alpha Cultural Education Consulting (Shenzhen) Co., Ltd		Significant influenced by the Company
Shenzhen Nanshan District Zhongyun Computer Development Center		Xiaocai Yu is the operator of the Center

Amounts due from related parties as of September 30, 2024 and March 31, 2024 are as follows:

	September 30, 2024		March 31, 2024
Shenzhen Zhongyun Electronic Intelligent Technology Co., Ltd	$	-	$	132,958
Shenzhen Zhongyun Holding Investment Company Co., Ltd		-		44,319
Xiaocai Yu		150,708		132,733
	$	150,708	$	310,010

Amounts due to related parties as of September 30, 2024 and March 31, 2024 are as follows:

	September 30, 2024		March 31, 2024
Shenzhen Zhongyun Project Management Software Co., Ltd	$	366,189	$	354,549
Shenzhen Zhongyun Information Technology Co., Ltd		83,757		215,245
ShuHua Liu		639,271		488,099
Shenzhen Baiyuwang E-commerce Co., Ltd		-		6,925
Alpha Cultural Education Consulting (Shenzhen) Co., Ltd		303,663		276,996
Shenzhen Zhongyun Holding Investment Company Co., Ltd		691,344		34,625
	$	2,084,224	$	1,376,439

Cost of revenues from related parties for the six months ended September 30, 2024 and 2023 is as follows:

	Six months ended September 30,
	2024		2023
Shenzhen Zhongyun Information Technology Co., Ltd	$	227,864	$	-
Shenzhen Nanshan District Zhongyun Computer Development Center		-		575
	$	227,864	$	575

Due from related parties mainly consists of funds advanced to related parties as borrowings or funds advanced to pay off the Company’s expenses. The balances are unsecured, non-interest bearing.

Due to related parties mainly consists of borrowings for working capital purpose, the balances are unsecured, non-interest bearing and due on demand.

NOTE 11 – OPERATING LEASES

As of September 30, 2024, the Company has one operating lease agreements for office spaces in PRC (non-related party) with remaining lease terms of 1 month.

As of September 30, 2024, the Company recognized operating lease liabilities, including current and noncurrent, in the amount of $1,647.

	September 30, 2024		March 31, 2024

Right-of-use assets-operating lease	$	1,255	$	8,542

Operating lease liabilities – current	$	1,647	$	11,066
Operating lease liabilities – non-current		-		-
Total lease liabilities	$	1,647	$	11,066

The components of lease expense and supplemental cash flow information related to leases for the six months ended September 30, 2024 and 2023 are as follows:

Other information for the months ended	2024			2023
Weighted average remaining lease term (in month)		1			13
Weighted average discount rate		5	%		5	%

Lease expenses were $9,669 and $9,274 for the six months ended September 30, 2024 and 2023, respectively.

F-34

NOTE 12 – BANK AND OTHER BORROWINGS

In August 2024, the Company obtained a loan in the principal amount of RMB3,000,000 (approximately $427,464 when borrowed) from Industrial and Commercial Bank of China, which bears interest at 3.65%. The loan is guaranteed by Xiaocai Yu, a related party. The maturity date is on August 25, 2025.

The balance of the loans borrowed as of September 30, 2024 and March 31, 2024 was as follows:

	September 30, 2024		March 31, 2024
Bank of China	$	349,352	$	414,109
Bank of Communications		-		270,071
Industrial and Commercial Bank of China		427,464		-
SPD Bank		427,464		415,494
WeBank		318,165		390,169
Aggregate outstanding principal balances		1,522,445		1,489,843
Less: current portion		1,433,657		1,351,345
Non-current portion	$	88,788	$	138,498

The total interest expenses were $50,384 and $25,079 for the six months ended September 30, 2024 and 2023, respectively.

Future minimum loan payments as of September 30, 2024 are as follows:

Year ending March 31,
2025 (remaining)	$	891,504
2026		630,941
Thereafter		-
Total	$	1,522,445

NOTE 13 – CONCENTRATIONS OF RISK

(a) Major customers

For the six months ended September 30, 2024, the customers who accounted for more than 10% of the Company’s revenues and the accounts receivable balances at period-end are presented as follows:

	For the six months ended September 30, 2024					As of September 30, 2024
	Revenues		Percentage of revenues			Accounts receivable
Customer G	$	224,779		48	%	$	2,176,421
Customer C		207,895		44	%		3,372,387
Total	$	432,674		92	%	$	5,548,808

For the six months ended September 30, 2023, the customers who accounted for more than 10% of the Company’s revenues and the accounts receivable balances at period-end are presented as follows:

	For the six months ended September 30, 2023					As of September 30, 2023
	Revenues		Percentage of revenues			Accounts receivable
Customer C	$	1,143,598		34	%	$	1,305,995
Customer G		1,107,384		33	%		1,673,899
Customer H		379,595		11	%		328,778
Total	$	2,630,577		77	%	$	3,308,672

(b) Major vendors

For the six months ended September 30, 2024, the vendors who accounted for 10% or more of the Company’s cost of revenues and its accounts payable balance at period-end are presented as follows:

	For the six months ended September 30, 2024					As of September 30, 2024
	Purchases/Cost of revenue		Percentage of purchases			Due to related parties
Vendor C, a related party	$	227,864		40	%	$	83,757
Total	$	227,864		40	%	$	83,757

Vendor C provides the engineering services that related to the telecommunication engineering.

For the six months ended September 30, 2023, the vendors who accounted for 10% or more of the Company’s cost of revenues and its accounts payable balance at period-end are presented as follows:

	For the six months ended September 30, 2023					As of September 30, 2023
	Purchases/Cost of revenue		Percentage of purchases			Accounts payable
Vendor B	$	386,527		20	%	$	-
Vendor E		373,044		19	%		515,914
Vendor F		290,096		15	%		196,762
Total	$	1,049,667		54	%		712,676

Vendor B, Vendor E and Vendor F provide the engineering services to the company

The related party transactions are generally transacted in an arm-length basis at the current market value in the normal course of business.

NOTE 14 - SUBSEQUENT EVENTS

In November 2024, the Company obtained a loan in the principal amount of RMB2,450,000 (approximately $349,096 when borrowed) from Bank of China, which bears interest at 3.00%. The loan is guaranteed by Xiaocai Yu, a related party. The maturity date is on November 7, 2025.

On December 3, 2024, the Company’s stockholders (over 97%) approved and announced that the Company is going to apply a seven-for-one reverse split of common stock as the general meeting of stockholders. The reverse split is still in process, effective date is to be determined.

F-35

PART II

INFORMATION NOT REQUIRED IN PROSPECTUS

Item 13. Other Expenses of Issuance and Distribution

The following table sets forth the costs and expenses payable by us in connection with the sale of common stock being registered. All amounts are estimates except for the SEC filing fee.

SEC filing fee	$	3,089
Legal fees and expenses	$	25,000
Accounting fees and expenses	$	210,000
Total	$	238,089

Item 14. Indemnification of Directors and Officers

(a)	The Company shall indemnify and hold harmless, to the fullest extent permitted by applicable law as it presently exists or may hereafter be amended, any person who was or is made or is threatened to be made a party or is otherwise involved in any claim, action, suit, or proceeding, whether civil, criminal, administrative or investigative (a “proceeding”) by reason of the fact that the person, or a person for whom he or she is the legal representative, is or was a Director or officer of the Company or is or was serving at the request of the Company as a director, officer or fiduciary of another corporation or of a partnership, joint venture, trust, non-profit entity, or other enterprise, including service with respect to employee benefit plans, against all expense, liability and loss (including attorneys’ fees, judgments, fines, ERISA excise taxes or penalties and amounts paid or to be paid in settlement) reasonably incurred or suffered by such person. The right to indemnification conferred in this Bylaw shall be a contract right. Except as provided in paragraph (c) of this Bylaw with respect to proceedings seeking to enforce rights to indemnification, the Company shall indemnify a person in connection with a proceeding initiated by such person or a claim made by such person against the Company only if such proceeding or claim was authorized in the specific case by the Board of Directors of the Company.
(b)	Subject to applicable law, the Company shall pay the expenses incurred in defending any proceeding in advance of its final disposition, provided, however, that if and to the extent required by law the payment of expenses incurred by any person covered hereunder in advance of the final disposition of the proceeding shall be made only upon receipt of an undertaking by or on behalf of the affected person to repay all amounts advanced if it should ultimately be determined that such person is not entitled to be indemnified under this Bylaw or otherwise.
(c)	If a claim for indemnification (following the final disposition of such proceeding) or advancement of expenses under this Bylaw is not paid in full within thirty days, or such other period as might be provided pursuant to contract, after a written claim therefor has been received by the Company, the claimant may file suit to recover the unpaid amount of such claim or may seek whatever other remedy might be provided pursuant to contract. In any such action the Company shall have the burden of proving that the claimant was not entitled to the requested indemnification or advancement of expenses under applicable law. If successful in whole or in part, claimant shall be entitled to be paid the expense of prosecuting such claim to the fullest extent permitted by law. Neither the failure of the Company (including its Directors, independent legal counsel or shareowners) to have made a determination prior to the commencement of such action that indemnification of the claimant is proper in the circumstances because the claimant has met the applicable standard of conduct set forth in the General Corporation Law of Wyoming, nor an actual determination by the Company (including its Directors, independent legal counsel or shareowners) that the claimant has not met such applicable standard of conduct, shall be a defense to the action or create a presumption that the claimant has not met the applicable standard of conduct.
(d)	Any determination regarding whether indemnification of any person is proper in the circumstances because such person has met the applicable standard of conduct set forth in the General Corporation Law of Wyoming shall be made in accordance with the applicable provisions of Wyoming law.

II-1

(e)	The Company may, but shall not be required to, indemnify and hold harmless, to the fullest extent permitted by applicable law as it presently exists or may hereafter be amended, any person who was or is made or is threatened to be made a party or is otherwise involved in any claim, action, suit, or proceeding, whether civil, criminal, administrative or investigative (a “proceeding”) by reason of the fact that the person, or a person for whom he or she is the legal representative, is or was an employee or agent of the Company or is or was serving at the request of the Company as an employee or agent of another corporation or of a partnership, joint venture, trust, non-profit entity, or other enterprise, including service with respect to employee benefit plans, against all expense, liability and loss (including attorneys’ fees, judgments, fines, ERISA excise taxes or penalties and amounts paid or to be paid in settlement) reasonably incurred or suffered by such person.
(f)	The rights conferred on any person by this Bylaw shall not be exclusive of any other rights which such person may have or hereafter acquire under any statute, provision of the Certificate of Incorporation, these Bylaws, agreement, vote of shareowners or disinterested Directors or otherwise.
(g)	Any repeal or modification of the foregoing provisions of this Bylaw shall not adversely affect any right or protection hereunder of any person with respect to any act or omission occurring prior to or at the time of such repeal or modification for which indemnification or advancement of expenses is sought.
(h)	The Company’s obligation, if any, to indemnify or to advance expenses to any person who was or is serving at its request as a director, officer, employee or agent of another corporation, partnership, joint venture, trust, enterprise or nonprofit entity shall be reduced by any amount such person may collect as indemnification or advancement of expenses from such other corporation, partnership, joint venture, trust, enterprise or non-profit enterprise.

We currently maintain and intend to maintain for the foreseeable future director and officer liability insurance on behalf of our directors and officers.

Item 15. Recent Sales of Unregistered Securities

During the past three years, we sold the following securities which were not registered under the Securities Act, all of which were offered and sold in reliance upon exemptions from registration under Section 4(a)(2) of the Securities Act.

On March 20, 2023, we consummated the transactions contemplated by the Share Exchange Agreement among the Company, Zhongyun (BVI) Limited, a British Virgin Islands Corporation (“Zhongyun BVI”) and the shareholder of Zhongyun BVI, pursuant to which we acquired all the ordinary shares of Zhongyun BVI in exchange for the issuance to the shareholder of Zhongyun BVI of an aggregate of 25,450,086 shares of the Company. The shareholders are the selling security holders in this prospectus and are all affiliates. As a result of the transactions contemplated by the Share Exchange, Zhongyun BVI became a wholly-owned subsidiary of the Company. This was a non-public offering under Section 4(a)(2) of the Securities Act.

Item 16. Exhibits

Exhibit Number		Description of Document

2.1		Share Exchange Agreement, dated as of March 23, 2023
3.1		Articles of Amendment (name change), filed on September 7, 2021
3.2		Articles of Amendment and Certificate of Designation for Preferred Series A Stock, file on June 17, 2021
3.3		Bylaws of the Company
5.1		Opinion of Rockville Law Company LLC
10.1		English translation of the Purchase Contract between Shenzhen Zhongyun Communication Technology Co., Ltd. and Shenzhen JingMeiJing Technology Co., Ltd.
10.2		English translation of the Purchase Contract between Shenzhen Zhongyun Communication Technology Co., Ltd. and Shenzhen JingMeiJing Technology Co., Ltd.
10.3		English translation of the Contract between Shenzhen Zhongyun Communication Technology Co., Ltd. and Shenzhen Zhongyun Information Technology Co., Ltd.
23.1		Consent of Bush & Associates, CPA LLC
107		Filing Fee

II-2

Item 17. Undertakings

The Company hereby undertakes:

(a)(1)

To file, during any period in which offers or sales are being made, a post-effective amendment to this registration statement:

	i.	To include any prospectus required by section 10(a)(3) of the Securities Act of 1933;

	ii.	To reflect in the prospectus any facts or events arising after the effective date of the registration statement (or the most recent post-effective amendment thereof) which, individually or in the aggregate, represent a fundamental change in the information set forth in the registration statement. Notwithstanding the foregoing, any increase or decrease in volume of securities offered (if the total dollar value of securities offered would not exceed that which was registered) and any deviation from the low or high end of the estimated maximum offering range may be reflected in the form of prospectus filed with the Commission pursuant to Rule 424(b) if, in the aggregate, the changes in volume and price represent no more than 20% change in the maximum aggregate offering price set forth in the “Calculation of Registration Fee” table in the effective registration statement.

	iii.	To include any material information with respect to the plan of distribution not previously disclosed in the registration statement or any material change to such information in the registration statement;

(2)	That, for the purpose of determining any liability under the Securities Act of 1933, each such post-effective amendment shall be deemed to be a new registration statement relating to the securities offered therein, and the offering of such securities at that time shall be deemed to be the initial bona fide offering thereof.

(3)	To remove from registration by means of a post-effective amendment any of the securities being registered which remain unsold at the termination of the offering.

(4)	That, for the purpose of determining liability of the Company under the Securities Act of 1933 to any purchaser in the initial distribution of the securities: The undersigned Company undertakes that in a primary offering of securities of the undersigned Company pursuant to this registration statement, regardless of the underwriting method used to sell the securities to the purchaser, if the securities are offered or sold to such purchaser by means of any of the following communications, the undersigned Company will be a seller to the purchaser and will be considered to offer or sell such securities to such purchaser:

	(i)	Any preliminary prospectus or prospectus of the undersigned Company relating to the offering required to be filed pursuant to Rule 424;

	(ii)	Any free writing prospectus relating to the offering prepared by or on behalf of the undersigned Company or used or referred to by the undersigned Company;

	(iii)	The portion of any other free writing prospectus relating to the offering containing material information about the undersigned Company or its securities provided by or on behalf of the undersigned Company; and

	(iv)	Any other communication that is an offer in the offering made by the undersigned Company to the purchaser.

(5)

That, for the purpose of determining liability under the Securities Act of 1933 to any purchaser, if the Company is subject to Rule 430C, each prospectus filed pursuant to Rule 424(b) as part of a registration statement relating to an offering, other than registration statements relying on Rule 430B or other than prospectuses filed in reliance on Rule 430A, shall be deemed to be part of and included in the registration statement as of the date it is first used after effectiveness. Provided, however, that no statement made in a registration statement or prospectus that is part of the registration statement or made in a document incorporated or deemed incorporated by reference into the registration statement or prospectus that is part of the registration statement will, as to a purchaser with a time of contract of sale prior to such first use, supersede or modify any statement that was made in the registration statement or prospectus that was part of the registration statement or made in any such document immediately prior to such date of first use.

Insofar as indemnification for liabilities arising under the Securities Act of 1933 (the “Act”) may be permitted to our directors, officers and controlling persons pursuant to the provisions above, or otherwise, we have been advised that in the opinion of the SEC such indemnification is against public policy as expressed in the Securities Act, and is, therefore, unenforceable. In the event that a claim for indemnification against such liabilities, other than the payment by us of expenses incurred or paid by one of our directors, officers, or controlling persons in the successful defense of any action, suit or proceeding, is asserted by one of our directors, officers, or controlling persons in connection with the securities being registered, we will, unless in the opinion of our counsel the matter has been settled by controlling precedent, submit to a court of appropriate jurisdiction the question whether such indemnification is against public policy as expressed in the Securities Act, and we will be governed by the final adjudication of such issue.

II-3

SIGNATURES

Pursuant to the requirements of the Securities Act of 1933, the registrant has duly caused this registration statement to be signed on its behalf by the undersigned, thereunto duly authorized, in the city of Shenzhen Guangdong China, on February 24, 2025.

	Alpha One Inc..

February 24, 2025	By:	/s/ Shuhua Liu
		Shuhua Liu
		Chairman and Chief Executive Officer and Director
		(Principal Executive Officer)

Pursuant to the requirements of the Securities Act, this registration statement has been signed by the following persons in the capacities and on the dates indicated.

February 24, 2025	By:	/s/ Shuhua Liu
		Shuhua Liu
		Chairman and Chief Executive Officer and Director
		(Principal Executive Officer)

February 24, 2025	By:	/s/ Hongyan Li
		Hongyan Li
		Chief Financial Officer
		(Principal Financial and Accounting Officer)

II-4

Exhibit 2.1

Exhibit 3.1

Exhibit 3.2

Exhibit 3.3

Exhibit 5.1

Rockville Law Group

Re: Legal opinion on Alpha One Inc, Symbol: AOAO

Ladies and Gentlemen,

Please be advised that I am securities counsel to Alpha One Inc.,a Wyoming corporation f/k/a World Mobile Holdings, Inc.(the “Issuer”). I have been requested, as securities counsel to the Issuer, to render an opinion (this “Opinion”) for the purpose of registering 10,000,000 shares of common stock under the Securities Act in connection with the filing by the Issuer on November 01, 2024 of its registration statement Form S-1 for the year ended ended March 31, 2024 including audited financial statements and all documents previously filed on the OTC Markets (collectively the”Historical Information”). (The audited financial statements and the Historical Information are sometimes hereinafter referred to collectively as the “Filed Documents”).

For the reasons set forth herein, it is my opinion that the Filed Documents,taken together:

1.	constitutes adequate current public information concerning the shares of common stock of the Issuer (the “Securities”)and the Issuer and is available within the meaning of Rule 144(c)(2) under the Securities Act;

2.	includes all of the information that a broker-dealer would be required to obtain from the Issuer to publish a quotation for the shares of common stock of the Corporation (the “Securities”), under Rule 15c2-11 of the Exchange Act;

3.	I have reviewed WRITTEN CONSENT TO ACTION WITHOUT MEETING OF THE DIRECTORS OF Alpha One Inc, dated on March 23, 2023, Authorization of Issuance of Common Stock and Acceptance of Subscription Agreements

●	RESOLVED THAT the Corporation, having acquired Zhongyun (BVI) Limited under share exchange agreement from the selling shareholders.

●	FURTHER RESOLVED THAT the Corporation direct its transfer agent to issue share certificates in the name of the selling shareholders set forth herein with the appropriate restrictive legend.

4.	I have reviewed SHARE EXCHANGE AGREEMENT, and relevant documents, where 25,450,086 common shares were validly issued, fully paid and non-assessable.

5.	I have reviewed Supplemental Disclosure for Change of Control Events, where the purchase of 100,000,000 common shares of stock took place, these common stocks are validly issued, fully paid and non-assessable.

6.	Alpha One Inc is registering 10,000,000 shares of common stock in this S-1, all of them are existing shares, which were validly issued, fully paid and non-assessable. Alpha One Inc is not selling any shares of its common stock mentioned in its SEC Form S-1 and will not receive any proceeds from any sale or disposition by the selling shareholders of the shares of our common stock covered by SEC Form S-1.

In rendering the Opinion, I have reviewed such corporate records and other documents as I have deemed necessary regarding the filing of the Filed Documents. I have conducted two video calls which included Shuhua Liu, the CEO and sole director of the Issuer, where we could see and hear each other and we discussed the Company,in terms of both its history and its plans and prospects. In addition, I have made such investigations and have considered such questions of law as I deemed necessary and appropriate for the purposes of rendering this Opinion. In all such examinations, I have assumed the genuineness of all signatures, the authenticity of all documents submitted to me as originals, the conformity to original documents of all documents submitted to me as copies and the authenticity of all originals of such documents submitted as copies. Further, in all such examinations, I may have relied on information obtained from public officials, officers of the Issuer and other sources and represents that all such sources are reasonably believed to be reliable.

The person responsible for the preparation of the audited financial statements and notes thereto contained in the 2023-2024 Annual was Shuhua Liu, CEO of the company who was assisted by Bush & Associates CPA LLC, which has served as the Company’s auditor since 2024.

Henderson, Nevada, an accounting consultant to the Issuer as required, whose PCAOB ID Number is 6797.

Ms. Liu, in her capacity as an officer of the Issuer has certified that the financial statements to present fairly, in all material respects, the financial position, results of operations and cash flows for the periods presented, in conformity with accounting principles generally accepted in the United States of America, consistently applied. In the opinion of management,all adjustments considered necessary for fair presentation have been included in the financial statements.

The Issuer’s transfer agent (the “Transfer Agent”) is Vstock Transfer, LLC, 18 Lafayette Place, Woodmere, NY 11598, (tel) 212.828.8436. The Transfer Agent is registered with the Securities and Exchange Commission. I have communicated with the Transfer Agent and viewed a recent shareholder list to confirmed the number of shares outstanding and the identity of principal shareholders.

The documents containing the information concerning the Issuer and the Securities that are publicly available as of the date of this letter are the Filed Documents as defined above.

I have personally reviewed the Filed Documents together with all exhibits and it is my legal opinion that such information and that to the best of my knowledge those documents taken together are accurate, up to date, and contain the most current information available on the Issuer, and that an interested investor would find current information therein which could help him objectively determine corporate and financially relevant information better enabling him to make an informed and educated and intelligent decision. I have discussed with management and received management’s approval of this Opinion and all filings hereunder. Moreover. To the best of my knowledge,after inquiry of management of the Issuer, neither the Issuer nor its Board of Directors nor any 5% or greater shareholder is currently under investigation by any Federal or state regulatory authority for any violation of federal or state securities laws. Furthermore, after reasonable inquiry, I confirm the ownership information with respect to the Issuer’s officers and directors and 5% beneficial owners set forth in the Filed Documents.

I am admitted to practice law in the State of New York. I have been retained by Issuer as its general securities counsel which includes being retained for the purpose of rendering this Opinion and related matters. My relationship as counsel to the Issuer is solely as a lawyer serving as securities counsel and in connection therewith I have been retained for the purpose of reviewing the current information provided by the Issuer. I have never been prohibited from practicing before the Securities and Exchange Commission. I do not own any securities of the Issuer. To my knowledge, I am not currently under investigation by any federal or state or foreign regulatory authority and I have never been the subject of any proceeding by the SEC, the US Commodity Futures Trading Commission (CFTC), the Financial Industry Regulatory Authority (FINRA), or any other federal, state, or foreign regulatory agency. I am not now and have never been suspended or barred from practicing in any state or jurisdiction, and have never been charged in a civil or criminal case or been the subject of any investigation related thereto I own no securities of the Issuer. This opinion is as to the laws of the States of Wyoming, and the laws of the USA.

Regards,

Li Weng, Attorney at Law

Rockville Law Group LLC

3635 Old Court Road, Suite 208

Baltimore MD 21208

Wenglidk@foxmail.com

001 (410) 243 5500

Date: 01/10/2025

Exhibit 10.1

Sales Contract

Contract number:

Supplier:

Address:

Contact person:

Tel:

Buyer:

Address:

Contact person:

Tel:

1.	Product Details Currency: RMB

Product Name	Model number	Unit	Quantity	Unit price (RMB)	Total amount (RMB)

Total amount	Meta uppercase: integer

2.	Delivery Location: (shipping and insurance costs to be borne by the supplier)

3.	Delivery Time: Delivery shall be made within 45 days after the contract becomes effective.

4.	Goods Inspection: If there are quality issues, the buyer must submit a written claim within 30 working days after receiving the goods (the goods can be returned or replaced). If no claim is made within this period, the goods will be deemed accepted and of satisfactory quality.

5.	Payment Terms and Methods: 30% prepayment, inclusive of a 13% VAT invoice.

6.	Packaging and Labeling: Packaging must be intact, with labels including the product name, origin, manufacturer’s name, and quantity

7.	Breach of Contract: Either party must notify the other party in advance and obtain consent for any change in contract quantity or delivery time. The supplier shall not bear any liability for late delivery or non-performance caused by force majeure. If the buyer fails to make payment on time, a penalty of 3% of the total contract amount per day of delay shall be paid to the supplier. Other liabilities for breach of contract shall be governed by the “Economic Contract Law of the People’s Republic of China”.

8.	Dispute Resolution: Any dispute arising from the execution of this Contract shall be settled through friendly negotiation. If no negotiation can be reached between the parties, either party may file a lawsuit with the people’s court in the place where the Supplier is located.

9.	Effective Date: This contract shall become effective upon the signatures of authorized representatives of both parties and the affixing of their official seals. The contract is made in two copies, with each party holding one copy. Fax copies are considered valid documents.

Supplier:	Buyer:
Bank Account:	Bank Account:
Account number:	Account number:
Tax Number:	Tax Number:
Representative:	Representative:
Date:	Date:	(YY/MM/DD)

Contract Signing Location: Shenzhen

Exhibit 10.2

Sales Contract

Contract No:

Supplier: Shenzhen JingMeiJing Technology Co., Ltd

Address:

Contact Person:

Tel:

Buyer: Shenzhen Zhongyun Communication Technology Co., Ltd

Address:

Contact Person:

Tel:

Due to business needs, the Buyer intends to purchase related electronic products from the Supplier. The Supplier agrees to sell electronic products to the Buyer (a detailed product list is attached). Based on the Contract Law of the People’s Republic of China and relevant laws and regulations, and in accordance with the principles of equality and mutual benefit, both parties have reached an agreement and hereby sign this contract to define their rights and obligations, which both parties shall abide by.

1. Product

No.

Product Name

Model

Quantity (Units)

Unit Price

Amount

Tax Amount

The total price tax is in RMB

During the validity period of this agreement, if there is an increase or decrease in the market price of the above products, both parties agree to settle payments based on the price stated in the signed and effective order.

Specifications

Size
Packaging Weight
Processor
RAM
Storage
Camera

1 / 7

2. Quality Standards

2.1 The Supplier guarantees that the provided goods are brand new, unused, and manufactured using advanced production technology and the best materials. The Supplier shall provide products and services as per its promotional materials or the contract agreement.

2.2 The Supplier guarantees that the quality, specifications, performance, and technical parameters of the provided materials fully meet national standards and comply with national regulations. If there are design drawings, the products must conform to the drawings recognized by the Buyer;

2.3 The Supplier guarantees that the color, color number, and appearance of the materials provided are consistent with the sample confirmed on-site;

2.4 The Supplier guarantees that the materials provided are environmentally friendly and will provide a full set of inspection reports and environmental certification. The Supplier shall bear all costs related to product re-testing and inspections. For imported products, the Supplier must also provide a certificate of origin, customs declaration, and quarantine certificate;

2.5 The Supplier guarantees that the products provided have complete independent intellectual property rights or are legally authorized, and the Supplier shall bear full legal responsibility for any infringement of third-party intellectual property rights.

3. Packaging Standards, Supply, and Recycling

3.1 The product packaging must meet national or industry standards to ensure safe transportation and handling. If no national standards exist, industry standards shall apply; if neither exists, the Supplier shall follow the factory packaging standards. The Supplier’s packaging should display the Supplier’s name (or logo). Protective measures against moisture, rain, rust, shock, and corrosion must be taken to ensure that the quality, quantity, and performance of the goods are maintained.

3.2 Factory Standard Packaging: the packaging must include installation accessories, a certificate of conformity, a packing list, a user manual, technical parameters, and an original product quality certification or valid documents. If the product is imported, the Supplier must provide the certificate of origin, original factory quality certificate, customs declaration, tax invoice (original for Buyer’s verification, and a copy for Buyer’s records), inspection certificate issued by the commodity inspection bureau, complete original manufacturer documentation, Chinese installation instructions, installation diagrams, and other agreed supplementary materials.

2 / 7

3.3 The Supplier shall provide the packaging materials. For packaging materials that may cause environmental pollution, the Supplier shall organize recycling and bear related costs.

3.4 The packaging costs are included in the contract price

4. Delivery Time, Location, Method, and Risk Allocation

4.1 Delivery Time: Within 45 days from the signing date of this contract;

4.2 The Supplier shall deliver the goods to the delivery place designated by the Buyer, and the Supplier shall be responsible for the storage, transportation, unloading, warehousing and other related expenses.

4.3 Before the Buyer officially receives the goods (i.e., all the goods are checked and accepted by the Buyer), including in transit or during unloading, any risks such as personal injury, damage or loss of goods shall be borne by the Supplier.

4.4 If the Supplier delivers the goods in advance, it shall be agreed by the Buyer. Otherwise, all risks of damage or loss of the products before the delivery date and all related storage and maintenance costs shall be borne by the Supplier.

5. Acceptance Standards, Methods, Location, and Deadlines

5.1 Acceptance Standards: As specified in Section 4.

5.2 Acceptance Method: The Buyer shall first sign and confirm the quantity and specification of the products, and confirm the quality of the products. The final acceptance shall be made by both parties;

5.3 The Supplier shall deliver the products to the designated location by the time specified in this contract or as required by the Buyers supply notice, and notify the Buyer to prepare for receipt 8 hours before the goods arrive; upon arrival at the delivery location, the Buyer should inspect and accept the goods within a reasonable time interval (4 hours during working hours, 8 hours during non-working hours); the Supplier is responsible for the delivery, acceptance, and settlement of the goods, while the Buyer conducts an initial inspection based on the packaging standards agreed upon in this contract, checking the appearance, quantity, model, and brand of the products, and signs to confirm receipt.

5.4 In case of disputes arising from acceptance, the inspection shall be conducted by a third-party product technical quality supervision and inspection agency, and the relevant expenses shall be borne by the responsible party.

3 / 7

5.5 After receiving the product, if the Buyer finds that the model, specifications, quantity, and quality of the product do not comply with the terms of this contract, the Buyer may retain custody of the product (the costs incurred from retaining the goods shall be borne by the Supplier) and submit a written objection to the Supplier within the period specified in Article 5.6. The Buyer also has the right to refuse payment for any non-conforming products under this contract.

5.6 Acceptance Deadline: The quantity of products shall be confirmed on the day of delivery, and the Buyer shall confirm the quality within 3 days from the date of delivery. If there is no objection, it shall be deemed as no objection. If the quality does not meet the requirements of the contract, the Supplier shall replace the machine with a new one within 7 working days.

6. Quality Assurance and Liability

6.1 If a product is found to be non-compliant with quality requirements during or after use, the Supplier must replace it unconditionally.

6.2 The Buyer shall have the right to inspect the raw materials of the goods and send representatives to conduct random inspections at any time during the production process of the goods; if the quality and specifications of the products do not conform to the requirements and descriptions stipulated in the contract, or if the materials used do not meet the requirements, the representative of the Buyer shall have the right to request the supplier to make improvements until the termination of the contract;

6.3 The Buyer’s on-site acceptance shall be considered as a preliminary confirmation only. If, during usage or after the use of the products, quality issues arise due to the products failing to meet contract standards, the Supplier shall bear full liability for compensation. Additionally, the Supplier shall also be responsible for any claims made by the Buyer’s clients or end-users resulting from such quality defects;

6.4 The Supplier shall provide a quality assurance period in accordance with national regulations. If national regulations specify a lifetime warranty or lifetime maintenance, the Supplier must comply with such provisions. If there is no national regulation, the quality assurance period shall be two years from the date of final project acceptance. If the issue is determined to be the Supplier’s responsibility, the Supplier must repair or replace the defective products unconditionally, covering all costs, including materials, labor, and transportation.

4 / 7

7. Payment Terms

7.1 The Buyer shall pay 100% of the contract amount within 10 days after the contract becomes effective.

7.2 The Supplier shall issue a valid VAT invoice within 30 days after the Buyer accepts the products.

The invoice information is as follows:

Company Name:

Unified Social Credit Code:

Bank

Account Number:

Address:

7.3 If there is any change to the Supplier’s bank name, account name, or account number, the Supplier must notify the Buyer in writing at least 10 days in advance of the relevant payment deadline specified in the contract. If the Supplier fails to notify on time or provides incorrect information that affects the settlement process, the Buyer’s payment obligation shall be postponed accordingly.

7.4 If the Supplier provides false invoices or non-compliant invoices, the Supplier shall bear all losses and tax penalties incurred by the Buyer, regardless of when the issue is discovered. Additionally, the Supplier must replace the false or non-compliant invoice within the specified time limit.

8. Breach of Contract

8.1 If the Supplier fails to deliver the goods on the date stipulated in the contract or on the date specified by the Buyer, the Supplier shall bear liability for delayed delivery. For each day of delay, the Supplier shall pay the Buyer 0.5% of the total contract amount as a penalty. If the penalty is insufficient to cover the Buyer’s actual losses, the Supplier shall compensate for the actual loss, including direct and indirect losses caused by the delay, such as delays in the Buyer’s project schedule (including claims from project owners).

8.2 If the Supplier delays delivery for more than 10 days, in addition to paying the penalty stipulated above, the Buyer has the right to terminate the contract;

5 / 7

8.3 If the Supplier fails to deliver products that meet the agreed quality standards on the stipulated date, causing delays in the Buyer’s project schedule, the Supplier shall compensate the Buyer for direct and indirect losses, including claims from project owners. If the Supplier delivers non-compliant products and the Buyer agrees to use them, both parties shall negotiate a revised payment. If the Buyer refuses to accept them, the Supplier shall replace the products and bear all penalties for late delivery. Additionally, the Buyer has the right to terminate the contract. If the Supplier’s product quality issues cause any financial loss to the Buyer, the Supplier shall be fully liable for compensation, and the Buyer retains the right to terminate the contract.

8.4 During bulk deliveries, if the Supplier is found to have delivered substandard products or products that do not meet the agreed standards, in addition to the breach of contract liability under Article 8.3, the Buyer has the right to directly deduct 10% of the total contract amount as liquidated damages per order.

8.5 If the contract is terminated due to the Supplier’s breach, the Supplier shall fully refund any advance payments or purchase amounts received from the Buyer within 2 days. If the Buyer has paid a deposit, the Buyer has the right to demand double the deposit amount within 2 days, without imposing any additional penalty on the Supplier.

8.6 If the Supplier breaches the contract, but the Buyer requires the Supplier to continue fulfilling the contract, the Supplier must do so after fulfilling all breach-related liabilities.

8.7 If the Buyer fails to pay the purchase price on time, the Buyer shall pay the Supplier a penalty of 0.5% per day for the unpaid amount, but the total penalty shall not exceed 20% of the total unpaid amount.

8.8 When performing the contract at a Buyer’s designated site, the Supplier must comply with all site management regulations set by the Buyer. If the Supplier causes any loss to the Buyer or a third party, the Supplier shall bear full liability for compensation, and the Buyer may directly deduct the compensation from the payment due to the Supplier.

8.9 If the Buyer terminates the contract under this agreement, all Supplier personnel and products must be removed within 2 working days from the date the Buyer issues a written termination notice. The Buyer has no obligation or responsibility to store or take care of the Supplier’s products after contract termination.

8.10 If either party violates the anti-corruption agreement, the violating party shall pay the other party a penalty of 5% of the total contract amount and compensate for any economic losses incurred. Additionally, the non-breaching party has the right to terminate the contract accordingly.

6 / 7

9. Contract Termination Conditions

9.1 The contract may be terminated upon mutual agreement between both parties;

9.2 The contract may be terminated if force majeure prevents its execution.

9.3 The contract may be terminated when other contractually agreed-upon termination conditions are met.

10. Dispute Resolution

In the event of a dispute arising during the execution of this contract, both parties shall attempt to resolve it through negotiation. If negotiation fails, either party may file a lawsuit in the People’s Court in the Buyer’s location in accordance with the law.

11. Other

11.1 The annexes to this contract are an integral part of the contract. If there are any unresolved matters, both parties may negotiate and sign a supplementary agreement, which, upon signing and stamping, shall have the same legal effect as this contract.

11.2 Before, during, and after the execution of this contract, neither party may disclose any materials or information provided by the other party, including but not limited to trade secrets, technical data, drawings, figures, customer information, and other business-related information, without prior written consent from the other party. This confidentiality clause remains valid even if the contract is terminated or revoked.

11.3 If either party violates the confidentiality clause, the responsible party shall pay the other party a penalty equal to 5% of the total contract amount. If this penalty does not fully compensate for the damages suffered by the other party, the responsible party shall compensate for the actual losses incurred.

11.4 If any changes occur to the parties’ contact information, account details, or other contractual information, the affected party must notify the other party in writing. If no such notice is given, it will be assumed no changes have been made.

11.4 This contract is made in two original copies, with each party holding one copy. The contract shall take effect upon signature by the authorized representatives of both parties and upon affixing the official company seals or contract-specific stamps.

Supplier:		Buyer:
Bank:		Bank:
Account Number:		Account Number:
Tax Number:		Tax Number:
Representative:		Representative:
Date:		Date:

7 / 7

Exhibit 10.3

2021-2022 Guangdong Unicom Pipeline and

Customer Engineering (Shenzhen Area)

Transmission Pipeline Distribution Engineering

Labor Service Contract

Client: Shenzhen Zhongyun Communication Technology Co., Ltd.

The Contractor: Shenzhen Zhongyun Information Technology Co., Ltd.

The Contractor (Party A): Shenzhen Zhongyun Communication Technology Co., Ltd

The Contractor (Party B):Shenzhen Zhongyun Information Technology Co., Ltd

Party A entrusts Party B to implement the construction of the 2021-2022 Guangdong Unicom Pipeline and Customer Project (Shenzhen Area) Transmission Pipeline Distribution Engineering Contract. Both parties, in accordance with the Civil Code of the Peoples Republic of China and other relevant laws and administrative regulations, adhere to the principles of equality, voluntariness, fairness, and good faith, enter into this contract.

1.	Project overview

1.	Project Name: 2021-2022 Guangdong Unicom Pipeline and Customer Engineering (Shenzhen Area) Transmission Pipeline Distribution Project.

2.	Project Location: Shenzhen

3.	Project Scope: This is an annual framework contract, with the final settlement amount based on the actual completed work volume.

4.	The contract follows a fixed-unit-price, lump-sum model, covering labor, quality, construction, progress, safety, site maintenance, finished/semi-finished product protection, and acceptance coordination. Party B guarantees project completion with quality and within the agreed schedule, except for Party A-approved design changes.

5.	The contract quotation includes all work specified in the drawings, such as construction and installation fees, commissioning and activation fees, material handling costs, water and electricity for construction, special tool service fees, profits, and taxes

6.	Party B confirms that the design drawings provided by Party A fully meet the construction needs. If Party B proposes further modification and supplement, Party B shall be responsible for and bear the relevant costs. If Party A proposes further modification and supplement, Party A shall be responsible for and bear the relevant costs.

7.	Pricing and Work Volume Basis: Contract pricing and project quantities shall be based on Party A’s bidding documents, special design drawings, and the accepted bid submitted by Party B.

8.	If Party A requests design or material changes, the additional costs will be adjusted through a change order If pricing exists in the original bid, adjustments will follow contract and bidding criteria; otherwise, both parties shall negotiate a new price.

9.	Party B has independently inspected the construction site and verified the dimensions before submitting the bid. Any misinterpretations or miscalculations shall be at Party B’s expense. If site conditions change after Party B’s inspection, Party A shall bear any resulting costs.

2.	Scope of engineering contract

For details on specific systems and engineering items, refer to Attachment 1: Labor Unit Price Quotation Sheet.

3.	Contract duration

1.	The official start date shall be subject to the written notice of Party B after Party A has met the conditions for commencement.

2.	Within three (3) days of receiving the notice, Party B must begin construction.

3.	Party B must comply with Party A’s reasonable urgent work requests.

4.	If the project is delayed due to the reasons of Party A, Party A shall be responsible and the project timeline shall be extended accordingly.

5.	The completion date is based on acceptance and approval by both parties.

6.	If Party A issues a commencement notice, but Party B unreasonably delays and fails to start construction on time, causing losses, Party B shall pay a penalty of 0.05% of the total contract amount per day of delay, with a maximum penalty of 5% of the total contract amount. If the delay exceeds ten (10) days, Party A has the right to unilaterally terminate the contract and pursue economic compensation from Party B.

4.	Quality Standard

1.	If the construction quality problems caused by Party B result in related losses and disputes, Party B shall be responsible for them and compensate for all economic losses caused thereby.

2.	Party B shall ensure the operation stability and reliability of the system project, and Party B shall bear all consequences and losses caused by the system operation failure due to the quality problems of the equipment provided by Party B.

3.	Contract project warranty period: None

5.	Contract Price and Settlement

1.	Settlement method:(Currency: RMB) After the construction team completes this project, the account settlement shall be made according to the actual project situation.

2.	Payment method: telegraphic transfer

3.	Party A shall pay the corresponding amount to the bank account designated by Party B within the time limit stipulated in this Contract, as follows:

Bank: China Merchants Bank Co., LTD. Shenzhen Shajing Branch

Bank account: 755941743310901

Account name: Shenzhen Hongfu Communication Technology Co., LTD

6.	Equipment and Material Management:

All equipment and materials shall be kept by Party B before the completion acceptance and delivery of the project. In case of loss, damage or theft, Party B shall be responsible, and Party A shall not bear any responsibility; after the completion acceptance and delivery of the project, if any loss, damage or theft occurs, Party B shall not bear any responsibility.

Design Change and Settlement

Except for the following factors, the total contract price of the project shall not be adjusted or changed for any other reasons:

1.	Design changes caused by adjustments in building structure leading to increases or decreases in work volume (based on the as-built drawings) can be adjusted according to the change order. The calculation method is as follows: if there are identical items in the contract, equipment prices and installation commissioning fees shall be executed at the unit price stipulated in the contract; if there are no identical items in the contract, the unit price of equipment and installation commissioning fees shall be approved by the client, with the fee standards and discount rates being proportional.

2.	The additional costs of design changes proposed by Party B for the convenience of construction shall not be adjusted and shall be borne by Party B.

3.	All pricing determinations and adjustments shall only take effect after Party A’s approval through a Change Order.

4.	If Party B finds any errors or unreasonable conditions in the construction drawings during implementation or proposes design changes and optimization of construction drawings for the convenience of construction, Party B shall confirm and acknowledge them by the design unit, and implement them only after the consent of the representative of the on-site supervision engineer. Party B shall not modify the design drawings without authorization.

5.	The design change order issued by the representative of the on-site supervising engineer between Party A and the design unit is also a contract document, which Party B must implement, but the costs caused by the design change shall be borne by Party A.

6.	Party B shall not transfer the drawings of the project to a third party without the consent of Party A. After the completion and acceptance of the project, all the drawings except those that Party B must keep for archiving shall be destroyed by itself.

8.	Party A’s Work and Responsibilities

1.	Pay the contract project payment to Party B in time according to the contract.

2.	Party A entrusts a designated supervisor to oversee the construction of this project. Party A grants the supervisor the following supervisory rights: the authority to sign commencement orders, suspension orders, and resumption orders; the right to inspect construction quality; the power to monitor and supervise construction progress; as well as the authority to approve if the actual completion date is advanced or exceeds the deadline specified in the construction contract; and to conduct quality inspections and acceptance according to current national standards for construction and installation evaluation.

3.	Party A shall designate an engineering project manager to be responsible for the performance of the contract, handle various external procedures before commencement, coordinate on site and negotiate with outsiders, and advance various compensation fees, and assist Party B to solve difficulties and problems encountered in construction.

4.	Organize construction drawing design briefing and be responsible for project construction management.

5.	To be responsible for handling the construction procedures approved by various government functional departments before construction; to provide the site construction underground pipeline network data to Party B; to coordinate and deal with the protection of buildings around the site construction.

6.	Organize the project acceptance according to the delivery notice issued by Party B, handle the project handover procedures and visa, and be responsible for reviewing the construction settlement and handling the payment of project funds.

9.	Party B’s Work and Responsibilities

1.	Prepare construction organization design and quality plan (must be reviewed and confirmed by the supervisor), and do a good job in all construction preparations.

2.	Provide the construction plan to the client and the supervisor respectively. Submit the commencement notice, completion notice, project accident report, project change notice and other documents to the supervisor.

3.	Comply with the management regulations of the relevant government authorities regarding traffic, construction noise, environmental protection, and production safety at the construction site. Be responsible for on-site security, cleaning, and other tasks, and protect buildings around the construction site. If underground obstacles or cultural relics are discovered, promptly report to the relevant departments and take effective protective measures. Disposal will be handled according to specific regulations, and any resulting costs will be negotiated with the client. Any delay in the project schedule will be extended accordingly.

4.	Responsible for the inventory, storage and use of equipment and materials. At the end of the project, the surplus engineering materials will be handed over to the material agent entrusted by the client.

5.	Responsible for the collection and transportation of depreciation materials at the construction site, and deliver the depreciation materials to the location designated by the project manager representative and hand over to relevant personnel.

6.	Party B warrants that the system equipment provided shall have reasonable performance and service life under correct installation, normal use and maintenance.

7.	Party B appoints Yang Yue as the Project Manager and Xu Junhao as the Technical Director.

8.	The construction shall be carried out in strict accordance with the construction design, meeting minutes, ministry regulations and construction operation requirements, and civilized construction shall be carried out. The quality and time of the project shall be ensured, and the safety of equipment and materials at the construction site shall be responsible. The regulations on site safety and civilized construction and labor protection shall be strictly observed, and the responsibility for any safety accidents shall be borne by the contractor.

9.	Cooperate with party A to participate in the completion acceptance.

10.	If Party B fails to complete all work as agreed in the contract, Party B shall bear the economic losses caused thereby and the construction period shall not be extended. During the construction process, Party B shall be responsible for and bear all expenses caused by quality accidents due to party Bs reasons.

11.	This project is included in the scope of general contracting management. Party B must abide by the site management system of the general contractor, comply with the management and supervision of Party A and the supervisor; after entering the site, Party B must sign a safety and civilized production management agreement with the general contractor; if Party B breaches the contract during its performance, it will unconditionally accept the penalty of Party A;

12.	Provide technical data for completion acceptance, submit project settlement data, participate in completion acceptance, and be responsible for completing the site clearance after work is completed, and all construction teams and construction machinery and equipment will be withdrawn within seven days after completion.

13.	Party B shall not subcontract the contracted project to others, nor shall it subdivide the contracted project and subcontract it to others in the name of sub-contracting.

14.	During the execution of the contract, living or cooking on the construction site is strictly prohibited. The contractor is responsible for arranging accommodation and meals for construction personnel. If a violation is found, a penalty of 2,000 RMB per occurrence will be imposed.

10.

Acceptance of Work

1.	The quality of the project shall meet the quality grade stipulated in the contract, and the quality evaluation standard shall be based on the national or industrial quality inspection evaluation standard. If the quality of the project fails to meet the promised quality grade due to the reasons attributable to Party B, it shall be deemed as a breach of contract by Party B, and Party A shall have the right to pursue Party Bs liability for breach of contract.

2.	If the part of the project acceptance is deemed unqualified and it is due to Party Bs reasons, Party B shall be responsible for rectification, rework or demolition and re-construction, and Party A shall reorganize the acceptance, and the costs incurred therefrom shall be borne by Party B.

3.	During the process of project acceptance, the inspection, testing, measurement and testing required by Party A shall be carried out with the cooperation of Party B or Party B shall provide relevant instruments, meters and vehicles, and the costs shall be borne by Party B.

4.	During the process of project acceptance, if Party A requires re-inspection of the concealed project, Party B shall excavate or open holes as required, and re-cover or repair after inspection, and bear all the costs incurred.

11.

Safety Construction and Penalties

1.	Party B shall comply with Party As management regulations on construction safety production, strictly organize construction according to safety standards, and at any time accept the legal supervision and inspection conducted by Party A or industry safety inspectors, taking necessary safety precautions to eliminate potential accident hazards. Party B shall be solely responsible for any liabilities and costs resulting from inadequate safety measures.

2.	Party A shall not require Party B to carry out construction in violation of the safety management regulations. Party A shall bear the corresponding responsibilities and expenses caused by the safety accidents caused by Party A.

3.	Party B shall submit safety protection measures to the supervising engineer before starting construction in power equipment, transmission lines, underground pipelines, inflammable and explosive areas and near street traffic routes, and implement them after being approved by the supervising engineer.

12.

Performance Bond & Liability for Breach of Contract

1.	If Party B fails to deliver goods or complete the construction period as stipulated in the contract, Party B shall pay a penalty of five ten-thousandths of the total contract amount per day from the day following the tenth day after the specified date for each delay. After ten days of delay, Party B shall pay a penalty of one thousandth of the total contract amount per day for each subsequent delay. The maximum amount of this penalty is five percent of the total contract amount. When the penalty reaches its upper limit, Party A has the right to terminate the execution of this contract and replace the construction team, and all losses resulting therefrom shall be borne by Party B.

2.	If Party A fails to pay the contract amount on time as stipulated in the contract, starting from the day after ten days from the latest due date, Party A shall pay Party B a penalty of five ten-thousandths of the total contract amount per day. After ten days of delay, for each day of delay, a penalty of one thousandth of the total contract amount per day shall be paid. The maximum amount of this penalty shall not exceed five percent of the total contract amount. Furthermore, in this contract, Party Bs service dates for Party A shall be extended accordingly.

3.	In the event of a breach by one party to the contract, the other party shall submit a written claim to the breaching party, specifying the liability for breach that the breaching party should bear; the breaching party must respond within ten days of receiving the notice, or otherwise compensate the other party for any further losses incurred; if the breaching party has objections to the liability for breach within ten days of receiving the notice, both parties should promptly negotiate to clarify the liability for breach.

4.	The liquidated damages, compensation, maintenance fees and various economic losses payable according to the contract shall be paid within ten days after the responsibility is clearly defined; otherwise, they shall be treated as overdue payment and the relevant provisions of the Contract Law shall apply.

5.	After one party breaches the contract, if the other party requires the breaching party to continue to perform the contract, the breaching party shall continue to perform the contract after bearing the above liability for breach of contract.

13.	Dispute

1.	This contract, the bid inquiry minutes and relevant commitments, the bidding documents, the bid documents, national or industrial technical standards, specifications and relevant technical documents, the design documents of this project and the approval documents of the design have the same legal effect. In case of any inconsistency between the above contract documents, the above order is the priority of interpretation of the contract.

2.	After this Contract comes into force, if either party proposes to modify or terminate this Contract, it shall be handled in accordance with the Contract Law of the Peoples Republic of China.

3.	Any dispute arising from or in connection with the execution of this Contract shall be settled by both parties through friendly negotiation. If no agreement can be reached after negotiation, both parties agree to submit the dispute to Shenzhen Intermediate Peoples Court for litigation.

4.	The court’s ruling shall be final and binding, and all legal costs shall be borne by the party deemed liable by the judgment.

5.	During the litigation, the other parts of the contract shall continue to be executed except for the part in litigation.

14.

Other

1.	In the event of force majeure (such as earthquake, flood disaster, etc.), Party B must inform Party A of the damage and loss as soon as possible, as well as the estimated cost of cleaning up and repairing. The costs and delay caused by force majeure shall be handled by both parties through negotiation.

2.	The engineering materials or equipment to be installed at the construction site shall be properly kept by Party B. If insurance is required, Party B shall be responsible for handling it and bear the insurance costs.

3.	Party A and Party B may terminate the contract through consultation. If the contract cannot be performed due to force majeure or breach of contract by either party (including the suspension or delay of construction due to party As reasons), Party A and Party B may terminate the contract.

4.	This contract is made in duplicate, with one copy for each party A and Party B, which shall have the same legal effect.

5.	Any matters not covered herein shall be settled by Party A and Party B through negotiation.

6.	This contract shall come into force upon being signed (sealed) by both parties and shall automatically terminate upon expiration of the warranty period of the project.

15.

The following attachments are included in this contract, as listed below:

1.	Annex 1: Labor unit price quotation form

2.	Annex 2: Confidentiality Agreement

3.	Annex 3: Safety production responsibility agreement

4.	Annex 4: Construction Engineering Safety Agreement

Time of conclusion of this contract: Year Month Day;

Place of conclusion of this contract:

Party A: Shenzhen Zhongyun Communication Technology Co., LTD

Signature/Seal:

Party B:

Signature/Seal:

Attachment 1: Labor Unit Price Quotation Form

number	project name	unit	Wages (yuan)	remarks
1	Collecting customer peripheral business is opened	moon	6000

Settlement method: payment every six months

Attachment 2: Confidentiality Agreement

Party A: Shenzhen Zhongyun Communication Technology Co., LTD

Party B:

In light of the contractual relationship between Party A and Party B, and the fact that Party B has become aware of and obtained Party As “confidential information” during the course of business activities aimed at achieving Party As contractual objectives, the disclosure of such confidential information would affect Party As normal operations, reduce Party As competitiveness, and damage Party As corporate image and interests. According to the Contract Law of the Peoples Republic of China and the Advertising Law of the Peoples Republic of China, and other relevant laws and regulations, to protect Party As “confidential information,” after full consultation, both parties hereby enter into the following confidentiality clauses for compliance and execution:

1.	Definition

The term “business activities” in this agreement refers to all economic activities conducted by Party B under the contract signed with Party A to fulfill its objectives. These activities include, but are not limited to: designing, producing, publishing, and placing advertisements for Party A; providing corporate branding, business promotion, and market research services for Party A; producing marketing materials for Party A; supplying various products and services to Party A; conducting site inspections, design, construction, supervision, and maintenance for Party A’s engineering projects; designing, developing, and maintaining software systems and other technical services for Party A; providing agency maintenance services for Party A’s projects and equipment; organizing competitions, bidding, and tendering activities for Party A in connection with contract execution.

The term “Confidential Information” in this agreement refers to any and all information that Party B obtains or becomes aware of in the course of conducting the above-mentioned business activities. Confidential Information includes but is not limited to: business records, technical data, financial records, accounting information, customer details, corporate strategies, and trade secrets. Confidential Information may be stored in various forms, including written documents, electronic files, data formats, images, audio-visual materials, and physical objects.

2.	Party B’s Obligation of Confidentiality

1.	Party B shall maintain the confidentiality of any ‘Confidential Information’ acquired from Party A during business activities, both during and after the contract term. Without prior written authorization from Party A, Party B shall not disclose, transfer, license, or otherwise share any Confidential Information with Party A’s competitors, third parties, or unauthorized individuals. Party B must not use this confidential information for any commercial activities. Exceptions apply if required by law by national judicial authorities or other competent authorities to disclose such information.

2.	The “confidential information” provided by Party A to Party B shall be owned solely by Party A. Party B may need to know such “confidential information” for work purposes, but it is only to be used for internal discussions, creation, design, and authorized publication. Unless Party A gives written authorization, Party B must not fully or partially copy or reproduce such information materials; upon completion of business activities and when these information materials and their copies are no longer needed, they should be returned in full to Party A or destroyed with Party As consent and supervision.

3.	Party B shall properly keep the “confidential information” provided by Party A and ensure that, apart from staff members who have participated in Party As business activities, no other personnel of Party Bs company may review, borrow, or obtain knowledge of its contents. Party B shall be liable for any breach of contract if its negligence results in the loss, unauthorized disclosure, or indirect leakage of Party A’s Confidential Information, including trade secrets.

4.	Party B warrants that the staff members participating in Party As business activities shall keep Party As “confidential information” and shall not disclose it to any third party in any way before or after the completion of the business activities, including during their employment with Party B or during their transfer or resignation.

3.	Breach of Contract and Liability

1.	If Party B breaches any provisions of this Agreement, Party A reserves the right to unilaterally terminate cooperation with immediate effect.

2.	If Party B violates any of the provisions mentioned above in this Agreement, Party B shall pay a penalty to Party A according to the following standard (1):

1)	20% of the amount of the main contract;

Note: If the liquidated damages agreed herein are lower than the loss of Party A calculated according to paragraph 3 of Article 3, Party A shall have the right to claim compensation from Party B for the part of the loss exceeding the agreed liquidated damages.

3.	In case of loss caused to Party A by Party Bs violation of the provisions of this Agreement, Party A shall have the right to choose one of the following methods to calculate the amount of loss compensation:

1)	The compensation amount shall be the actual loss suffered by Party A (including direct loss, indirect loss, expected income and litigation costs and legal fees incurred by Party A in pursuing Party Bs liability), which shall not exceed 5% of the amount of the main contract.

2)	The total income obtained by Party B due to breach of contract or tort shall be taken as the amount of compensation.

3)	No matter what method Party A chooses, if Party B causes the technical secret to be completely disclosed, Party B shall compensate for the entire value of the technical secret. The entire value of the technical secret may be assessed by an intangible asset evaluation institution recognized by the state.

4.	Principle of Mutual Confidentiality

In accordance with the principle of mutual confidentiality, Party A shall also be responsible for safeguarding Party B’s Confidential Information. Any violation by Party A shall result in liability under the same terms set forth in this Agreement.

5.	Other Provisions

1.	Party B shall earnestly perform this Agreement in good faith. If any dispute arises during the performance of this Agreement, both parties shall settle it through friendly negotiation; if no settlement can be reached through friendly negotiation, either party may bring a lawsuit to the Peoples Court at Party As place of residence.

2.	This Agreement shall come into force immediately upon being signed and sealed by both parties.

Party A: Shenzhen Zhongyun Communication Technology Co., LTD

Signature / Seal:

Party B:

Signature / Seal:

Attachment 3: Safety Production Responsibility Agreement

Agreement on the Safety Production Responsibility System

Party A: Shenzhen Zhongyun Communication Technology Co., LTD

Party B:

To comply with the “Law of the People’s Republic of China on Work Safety” and other relevant laws, regulations, and national/local policies, and to implement a safety production responsibility system, strengthen safety management in production (especially in construction and maintenance services), ensure the safety and health of employees, and reduce economic losses, both parties, through equal consultation, hereby enter into this Agreement.

1. This Agreement serves as an appendix to the “2021-2022 Guangdong Unicom Pipeline and Customer Engineering (Shenzhen Area) Transmission Pipeline Distribution Engineering Labor Service Contract” (hereinafter referred to as the “Base Contract”). It holds equal legal effect as the Base Contract and shall take effect upon signing by both parties.

2.	Qualification Examination and Filing

1.	Party B guarantees compliance with the Law of the People’s Republic of China on Work Safety and other relevant regulations. Party B must have a sound safety management system and operating procedures. Party B must have had no major safety accidents in the past three (3) years. Party B must provide social insurance (including pension, medical, unemployment, work-related injury, and maternity insurance) for its employees. For engineering construction, network maintenance (e.g., transmission pipelines, base station maintenance services), and outdoor advertising services, Party B must also provide commercial accident insurance for its personnel.

2.	For special operations requiring specific qualifications, Party B must submit original qualification certificates or special operation licenses for Party A’s verification, and provide certified copies for Party A’s records.

For information development and software system maintenance projects, Party B shall have regular response procedures and measures for information security, protection measures for intellectual property rights, detailed description of services that can be provided, and, if necessary, issue a qualified appraisal certificate issued by a third-party appraisal institution designated or jointly recognized by Party A as required by Party A.

3.	Organizational Structure and Responsibilities

1.	Party B shall set up a safety production management organization, establish and improve safety production rules and regulations, and the emergency response plan and handling procedures shall meet Party As requirements for the emergency response plan. The person in charge of Party Bs unit is the primary person responsible for safety production under the basic contract, responsible for the safety education of Party Bs personnel, and responsible for safety production and security work during the project implementation period.

2.	For the implementation of specific projects, Party B must designate a project leader to facilitate coordination and contact during the construction process; Party B must provide safety production management personnel to conduct regular inspections of the safety production status, supervise and inspect the implementation of various management systems and safety operation procedures by employees, and record the inspection and handling situation in the records.

3.	Party B shall actively cooperate with Party As safety inspection and rectify the safety risks found in accordance with the requirements. If Party B fails to rectify or fails to rectify according to Party As requirements, it shall be deemed that Party B has breached the basic contract, and Party A shall have the right to deal with Party B according to the breach terms agreed in the basic contract.

4.	Safety Training

1.	Party B must prepare a written safety operating procedure before starting a project.

2.	Before dispatching and adjusting the workforce, Party B must provide safety production education and training to the aforementioned personnel, truthfully informing them of the hazardous factors present in the workplace and job positions, preventive measures, and emergency response procedures for accidents. This ensures that all workers possess essential safety production knowledge, are familiar with relevant safety production regulations and operating procedures, and have mastered the safety operation skills required for their positions. After receiving safety training and understanding the safety procedures, the workers must sign to confirm and sign the safety responsibility agreement.

3.	Before the project commences, Party B shall submit copies of the safety operating procedures and the safety responsibility statement to Party A. If the safety operating procedures are not submitted, Party A has the right to suspend the project. If Party B fails to submit the safety responsibility statement before the personnel start work, Party A has the right to refuse their employment, and any resulting project liability or loss shall be borne by Party B.

4.	For construction projects, Party B shall provide safety protective equipment and clothing to the workers and inform them of the operating procedures for hazardous positions and the hazards of violating regulations. Special operation personnel must undergo specialized safety training in accordance with national and local regulations, obtain the corresponding special operation qualification certificates, and participate in the education and training organized by Party B. Party B must also ensure that 100% of the safety briefings conducted by the project supervisor are qualified before dispatching personnel to work.

5.	For information software system projects, all personnel from Party B must undergo pre-job training provided by Party A (including each branch company) before the project begins. The training consists of two parts: general modules and specialized training modules. General training covers foundational and common safety management systems and measures, while specialized training is arranged according to the specific type of project business. After completing the safety training, all personnel must pass a written assessment conducted by Party A (including each branch company). Only those who achieve 100% success can start work. If the assessment is not passed, Party A has the right to refuse the individual from starting work, and any resulting project liability or loss will be borne by Party B.

5.	Safety Measures & Compliance

1.	Party B must comply with national, industry, and Party As regulations on production safety management, strictly organizing project-related work according to safety standards. Party B must organize construction in strict accordance with safety protection and civilized construction regulations, taking necessary labor safety precautions to eliminate accident hazards, and be ready to accept supervision and inspection from the state, industry, Party A, and supervisory units at any time.

2.	For projects involving engineering construction:

1)	Party B shall, in the project design, construction and maintenance plan of the construction organization, prepare relevant quality, safety and civilized production guarantee measures, improve the conditions of safety protection and civilized construction, and submit to the examination and supervision of Party A and the supervising unit.

2)	Party B shall strictly abide by the safety norms of business development process (entry, site and exit) formulated by Party A, allocate the corresponding workplace according to business needs, and strictly abide by the safety rules of the workplace.

3)	Party B shall take all reasonable preventive measures to prevent the implementation of the project from being disturbed by non-safe factors (including but not limited to illegal and fighting behaviors), ensure the safety of the site, construction quality and protect the life and property safety of the site and nearby personnel.

4)	Party B shall strictly abide by Party As regulations on safety management of machine rooms and key departments; under the premise of not affecting Party As safe production operation, Party A shall provide Party B with convenient conditions and assistance services as far as possible.

5)	During the project, Party A and the supervising unit shall have the right to inspect Party Bs safety management at any time, stop all kinds of illegal operations, and order Party B to suspend work for rectification for acts violating safety regulations. At the same time, Party B shall have the responsibility to timely remind Party A and the supervising unit of the safety hazards that Party A has not taken into account.

6)	Party B shall formulate corresponding safety technical measures for the project; for projects with strong professionalism, special safety construction organization design shall be compiled and safety technical measures shall be taken.

7)	After both parties meet the conditions for commencement, the commencement order issued by Party A or the supervisor shall prevail, and both parties shall complete the handover procedures.

8)	Employees must wear construction certificates and safety protective equipment according to the requirements of different places, and special operation personnel (including but not limited to welders, electricians, etc.) must hold certificates before they can work.

9)	Party B shall establish and improve the daily work log, including construction time, location, construction content, etc.

10)	Party B shall set up safety warning signs at the construction site and send special personnel to guard and watch when necessary. Outdoor communication construction projects in urban areas shall be surrounded by barriers at the construction site. When construction is temporarily stopped at the construction site, the construction unit shall do a good job of on-site protection.

11)	The operation area shall be marked with obvious safety signs, the operation personnel shall be active in the construction area, and shall not enter the non-construction area at will; the operation personnel shall discourage non-operation personnel from entering the operation area.

12)	The site of the operation shall specify the key fire prevention parts and the use of various fire fighting equipment, do a good job in the safety management of equipment and materials, keep the site clean, and party B shall bear full responsibility for all pollution and other accidents occurring externally.

13)	Before working in the site where Party A has installed equipment, or near other power equipment, transmission lines, underground pipelines, sealed and earthquake-proof workshops, inflammable and explosive areas and streets with traffic, Party B shall apply to Party A and take safety protection measures, which can be implemented only after written approval from Party A and local safety authorities.

14)	In the event of blasting operations, construction in radioactive and toxic environments (including but not limited to storage, transportation, use, etc.) and the use of toxic and corrosive materials, Party B shall notify Party A in writing 14 days before construction and formulate corresponding safety protection measures, which can be implemented only after being written approved by Party A and local safety authorities.

3.	For projects involving information system software development and maintenance:

1)	The responsible department of Party B shall be the information security authority in charge of counterpart cooperation (including maintenance, development, testing and value-added business cooperation). Party B shall establish a sound information security monitoring and emergency process to estimate possible information security accidents, detect and deal with them in time when security incidents occur, and assist Party A to control risks.

2)	Party A is responsible for supervising the development and maintenance of internal information systems; participating in the design and development of project systems, and following up on the writing of relevant documents; supporting and supervising the subsequent requirements development, system optimization and bug modification of outsourced information systems.

3)	Party A is responsible for assigning appropriate and available permissions to Party Bs personnel and providing necessary measures for the conduct of their work. Party B must strictly adhere to the information security standards set by Party A during the business process (entry, on-site, exit), ensuring that its personnel properly manage the account permissions they obtain and prevent any information leaks or other security incidents related to information security. Otherwise, Party A has the right to terminate the project at any time and reserves the right to legal recourse.

4)	During the project, Party A and the supervising unit shall have the right to inspect Party Bs information security management at any time, stop all kinds of risky operations, and order a suspension for rectification if there is any violation of information security regulations. Meanwhile, Party B shall have the responsibility to timely remind Party A and the supervising unit of any information security risks that Party A has not taken into account.

5)	Party B is obliged to properly protect intellectual property rights (IPRs) and copyright transfers as well as co-authorship.

6)	Party B must strictly comply with the requirements and regulations of China Mobiles “Five Prohibitions” for customer service. When personnel dispatched by Party B enter production areas of China Mobile (including its subsidiaries) or log into various business systems of China Mobile (including its subsidiaries) for operations, they must strictly adhere to all safety management systems and standards of China Mobile (including its subsidiaries). They should voluntarily complete procedures such as authorization, certification, and registration of entry and exit times, and be ready to accept safety inspections from Party A and supervisory units at any time.

7)	When Party B comes into contact with all kinds of sensitive information and business secrets such as customer data and business information of Party A, it must cooperate with and abide by the provisions of Party A and ensure the confidentiality, integrity and verifiability of the information.

8)	Before the equipment of Party B is connected to the network, it must be ensured that the equipment has passed Party As safety inspection and testing and obtained authorization. When necessary, it should undergo a safety check by a professional testing company designated by Party A to prevent the system from being connected with faults. After connection, Party B should accept random inspections by Party A at any time. Party B should regularly inventory and clear out system equipment in cooperation with China Mobile, promptly removing retired system equipment. Before the project concludes, Party B should clean up all connections of the equipment, ensuring that sensitive information and commercial secrets are deleted. When necessary, it should undergo a safety check by a professional testing company designated by Party A.

9)	When Party B personnel apply for adding or changing accounts, they must adhere to the principle of dedicated accounts for specific individuals and the principle of minimal authority. Account applications must be reviewed and approved by Party A, and a written account application authorization letter must be signed to take effect. The authorization letter should specify matters such as the user, permissions, and usage period. Party A will keep records of the application approval process and conduct post-audit reviews. For Party B personnel who are long-term stationed at China Mobile, before transferring positions or leaving their posts, Party B must submit a written application for position transfer or departure to the responsible person of the affiliated project under Party A. The responsible person of the Party A project should lead the completion of account recovery, changes, and reviews for Party B personnel. Only after signing the position transfer or departure approval can Party B personnel officially transfer positions or leave their posts.

10)	Party B shall file and properly store the business systems or software programs independently developed by Party A or in collaboration with Party A. If the system or program has access to customer sensitive information, Party B must submit the system development documentation to the relevant department of Party A for archiving. The documentation should specify the distribution scope and require developers, testers, and project managers to strictly adhere to distribution control requirements. The system or program should have detailed logging capabilities for various types of system logs. During development and testing phases, test data used by Party B personnel should generally not reflect real customer information from the live network. Before significant changes are made to Party Bs system, a security assessment must be conducted and submitted for approval by the relevant department.

11)	All system information, customer information, operation logs, etc., related to Party Bs system must be properly managed. No additions, deletions, or modifications shall be made without the permission of the relevant supervisory department. Party Bs system, which has the authority to access or retain sensitive information, must, in principle, be located within the interconnection area of Party Bs partners. Sensitive information must be strictly controlled during transmission. The security configuration and protection of Party Bs system should meet China Mobiles relevant security requirements.

12)	In principle, the business system of Party Bs company shall not keep the information content of China Mobile customers communications. If it is indeed necessary for business purposes, it shall be kept only after approval by the competent department concerned.

6.	Accident Management & Compensation

Production safety accidents and cases include but are not limited to: casualties, fire, vehicle safety, crimes committed by employees, public security criminal cases, and communication network or interconnection accidents, communication power supply, information security accidents, etc.

1.	According to the engineering interface, Party B shall be responsible for safety during the operation process, including personal safety, equipment safety, and network security. Party B must conscientiously carry out preventive work to prevent production safety accidents and incidents. If Party B fails to manage strictly or implement preventive measures, resulting in production safety accidents or incidents, Party B shall bear legal responsibility corresponding to its fault. If Party A suffers losses due to production safety accidents or incidents caused by Party B, Party B shall fully compensate Party A.

2.	After the occurrence of a safety accident, Party B shall take emergency measures to organize repair and resume production in accordance with Party As emergency incident handling process, inform Party A by telephone within 15 minutes, and submit a written accident analysis report to Party A within 6 hours after the occurrence of the accident; at the same time, handle it according to the requirements of relevant government departments and actively cooperate with the investigation and handling of the accident.

3.	According to the “Measures for the Extraction and Use of Safety Production Expenses of Enterprises” (Ministry of Finance & State Administration of Work Safety [2012] No.16), construction enterprises base their safety expense extraction on the cost of building and installation projects. The safety expense extraction standards for various types of construction projects are as follows: 2.0% for housing construction projects, water conservancy and hydropower projects, power projects, railway projects, and urban rail transit projects; 1.5% for municipal public works, mechanical and electrical installation projects, highway projects, and communication projects. The safety expenses extracted by construction enterprises are included in the project cost. If there are other provisions regarding the basic construction investment estimate by the state, those provisions shall be followed.

4.	If Party B has a work safety accident during the operation of the basic contract, Party A has the right to deduct the penalty for Party Bs breach of contract and adjust the scope of services of Party B in the contract on the premise of not violating laws and regulations according to the relevant national standards for the characterization of accidents.

5.	Party B shall fulfill the obligation of confidentiality with respect to the project data, written materials and other confidential materials provided by Party A, and ensure that it does not provide or disclose them to any third party within five years after the expiration of the basic contract. Otherwise, Party B shall bear all losses and liabilities caused thereby.

6.	Party B should strengthen content management when conducting interactive services, short message services, IDC services, download services, instant messaging services, and voice services. Strict control over mass messages on the platform must be enforced to enhance content supervision and ensure content safety. For interactive services, once a non-compliant user is identified, actions such as suspension, blacklisting, account freezing, restriction of user functions, or account closure should be taken based on the severity of the violation. For short message services, if a user is found sending non-compliant messages, temporary or permanent account suspension, service suspension, port closure, or blacklisting should be implemented according to the level of violation. For IDC services, if non-compliant information is detected on a website, measures such as blocking, offlineing, or stopping access services should be taken based on the severity of the situation. For download services, if illegal content downloads or malicious user activities are discovered, actions like blocking content download channels, adding to the blacklist, or filtering sensitive words should be promptly executed. For instant messaging services, once non-compliant users or groups are identified, immediate actions such as blacklisting, freezing, restricting, or closing accounts should be taken. For voice services, severe violations should result in measures such as suspending new business additions, pausing settlements, and halting full-network cooperation.

7.	The cooperative unit shall report the overall framework of the use plan of safety expenses and the use of production safety expenses, and cooperate with the audit department and the competent authority of production safety to conduct regular review and audit of the use of production safety expenses.

7. The validity period of this Agreement shall be the same as that of the base contract, but the termination date of the equipment installation contract shall be the expiration of the warranty period after the completion and acceptance of the equipment installation project.

8. Any matters not covered herein shall be handled by both parties in accordance with the principle of friendly negotiation. If Party A and Party B have any dispute over the liability for the accident, they shall negotiate and handle it according to the responsibility determination of relevant government departments. If no agreement can be reached through negotiation, either party may bring a lawsuit to the peoples court at Party As place of residence for settlement.

9. This Agreement is made in duplicate, with each party holding one copy. It shall come into force upon signature and seal by authorized representatives of both parties.

Party A: Shenzhen Zhongyun Communication Technology Co., LTD

Signature / Seal:

Party B:

Signature/Seal:

Attachment 4: Construction Safety Agreement

This agreement is formulated to implement the policy of “Safety First, Prevention Foremost, and Comprehensive Governance”, clarify the safety responsibilities of both parties, enhance on-site safety management, ensure construction safety and quality, protect the health and safety of on-site personnel, and ensure the smooth, safe, civilized, high-quality, and efficient execution of the project while safeguarding the electrical equipment entrusted by the client. In accordance with national and local laws and regulations on safe and civilized production and following the principle of signing the contract and safety agreement before commencing work, both parties have, upon signing the construction contract, reached an agreement through mutual consultation.

1.	Party B’s Safety Responsible Person

i.	The safety responsible person of Party B, as referred to in this agreement, shall be the legal representative of Party B. The legal representative is the primary person responsible for safety production and signs this agreement on behalf of the company.

2.	Project Duration

i.	Project duration: From the commencement date to the date of final project acceptance and approval.

3.	Safety and Civilized Construction Objectives

i.	No serious personal injury or above accidents occurred. No minor personal injury accidents occurred.

ii.	No mechanical, equipment or fire accidents and traffic accidents of equal or greater responsibility will occur.

iii.	No power grid and equipment accidents or assessment events caused by engineering construction shall occur.

iv.	Meet the requirements of site safety and civilized construction put forward by Party A.

v.	No social security incidents occurred.

4.	Safety Regulations and Compliance Standards (including but not limited to)

i.	Law of the Peoples Republic of China on Work Safety

ii.	Regulations on Safety in Construction Projects of the State Council of the Peoples Republic of China

iii.	Safety Inspection Standard for Construction JGJ59-2011

iv.	Safety Technical Code for Construction Machinery Use JGJ33-2012

v.	Technical Code for Safety of Temporary Electrical Power Supply at Construction Sites JGJ46-2012

vi.	Safety Code for Power Supply and Use at Construction Sites of Building Engineering GB50194-93

vii.	Safety Technical Code for High-altitude Operations in Building Construction JGJ80-91

viii.	Relevant management regulations of Shenzhen Electric Power Company.

ix.	The relevant safety and civilization rules and regulations of Party A.

5.	Responsibilities of Party A

1.	Party A shall examine Party Bs qualification according to relevant regulations and confirm that the project constructed by Party B is in line with its qualification.

2.	Party A shall guarantee the timely payment of necessary safety production measures for this project.

3.	Party A shall supervise and inspect the implementation of relevant laws, regulations and national or industrial standards concerning work safety by Party B, and exercise the following duties:

1)	Party A shall enter Party B for inspection, review relevant materials and learn about the situation from Party B personnel;

2)	Party A shall correct or require Party B to correct the illegal acts of production safety found in the inspection on the spot; Party A may punish Party B according to the relevant safety management system of the company;

3)	Party A shall notify Party B to immediately eliminate any accident hazards discovered during the inspection; if major accident hazards cannot ensure safety before or during their elimination, Party A shall notify the withdrawal of personnel from hazardous areas and temporarily halt production, operations, or use; after major accident hazards have been eliminated, resumption of production, operations, or use can only occur upon approval following a review.

4.	Cooperate with the government, relevant functional departments and sub-district offices to carry out inspection, cleaning and rectification work. When Party A performs various inspection work, Party B shall have special personnel to cooperate.

5.	In case of an accident during construction, Party A shall immediately organize Party B to deal with the accident emergency, report to the superior unit and the administrative department according to the requirements, and assist or organize the accident investigation.

6.	Responsibilities of Party B

1.	In the process of construction, Party B shall have the relevant national laws, regulations, national standards or industrial standards and local government regulations on production safety conditions, and be responsible for the production safety of the site of the unit;

2.	Provide the enterprise qualification, safety construction status in the past three years and qualification certificates of construction personnel to Party A and the supervising unit according to the regulations, and be responsible for the authenticity of the materials provided by them.

3.	Party B must assign a full-time safety officer when the number of construction personnel exceeds 20, and a part-time safety officer must be appointed for 20 or fewer personnel. The safety officer should undergo training and assessment, holding relevant certification and qualification certificates. Party B has designated Zeng Qingyou, ID number: 431124198910134731, with contact phone: 18665821255, to serve as the safety officer responsible for ensuring safe and civilized construction of this project.

4.	The funds necessary for the production safety conditions that Party B shall have shall be guaranteed by the decision-making body, the principal person in charge or the individual investor of Party B, and Party B shall be responsible for the consequences caused by the insufficient funds necessary for production safety.

5.	Party B must participate in the work-related injury social insurance according to law and pay insurance premiums for employees.

6.	The site construction safety, technical and organizational measures and construction plan (hereinafter referred to as “three measures and one plan”) shall be compiled and implemented and submitted to the supervisor for examination and approval before the commencement of construction.

7.	When Party B enters the operation of the substation construction, it must first go through relevant procedures and strictly implement the relevant provisions of the Power Safety Work Regulations.

8.	The tools used by Party B during the construction period shall be provided by Party B. If it is necessary to borrow or rent, relevant procedures shall be handled. The tools shall meet the requirements for safe use.

9.	Party B shall conduct “three-level” safety education and training for construction personnel, pass the examination and assessment, and work with certificates to ensure that there is evidence to check, and cooperate with Party A to carry out safety education at the site.

10.	Anyone entering the substation shall wear a safety helmet correctly, which shall be qualified and within the effective use period.

11.	Party B shall strictly implement the organizational measures and technical measures to ensure safety and relevant provisions in the “Electric Power Safety Work Regulations” when working on the electrical equipment of the substation. Party B shall not work blindly, take risks or violate regulations without permission.

12.	Party B shall check the electric tools before using them in construction, so as to achieve “one machine, one switch and one protection”. When using metal shell electric tools, insulating gloves shall be worn, and the metal shell shall be grounded.

13.	The ladder shall be completed with solid load standards and anti-slip measures. When using or carrying the ladder, it shall be kept at a sufficient safe distance from the equipment. The use of metal ladder is prohibited in areas near live parts.

14.	Party B is strictly prohibited to use steel tape measure and line ruler (with metal wire) for measurement around live equipment.

15.	Party B shall compile various construction safety management systems, establish corresponding safety management accounts, construction teams shall carry out regular safety inspections and safety activities, and make written records.

16.	The construction site should meet the requirements of safety standardization, and the site must be cleared after the work is completed.

17.	In the event of a major production safety accident, Party Bs principal person in charge shall immediately organize rescue and shall not leave his post without authorization during the investigation and handling of the accident. Party B shall timely report to Party A according to the emergency management requirements of Party A. If an accident or event occurs due to Party Bs responsibility, Party B shall be liable for the accident and compensate for the loss.

18.	If Party B changes the project leader, technical leader, safety officer, etc., it shall timely report to Party A and the supervising unit for record. If Party B changes the construction plan or scope of construction, it shall also timely report to Party A in writing, which shall be implemented after being reviewed and approved by Party A.

19.	Party B shall be responsible for any personal accident or traffic accident occurring from the construction site to the unit.

20.	Party B guarantees that all kinds of reports, data and documents provided by Party A for production safety are true and reliable. Otherwise, Party B shall be punished according to the system for dereliction of duty or malfeasance, and those with serious circumstances shall be held legally liable.

7.	Breach of Contract and Penalties

1.	Party B shall organize the companys safety management in accordance with relevant national laws, regulations, standards and local government requirements during the construction process, and keep written records. If Party B violates relevant national laws, regulations, standards and local government provisions for work safety, causing property loss or personal accidents, Party B shall bear legal responsibility corresponding to its fault.

2.	Party B shall organize the companys safety management in accordance with relevant national laws, regulations, standards, and local government requirements during construction, promptly eliminating major safety hazards. If Party B fails to timely eliminate major safety hazards and does not make corrections after being notified in writing by Party A, Party A has the right to terminate the construction contract, and any actual economic losses incurred shall be borne by Party B.

3.	Party B shall bear full legal responsibility for all losses caused by unauthorized production, storage of hazardous chemicals, illegal use of electricity and illegal operation and other business activities, Party A has the right to terminate the construction contract, and all economic losses caused by Party B shall be borne by Party B.

4.	Party B must comply with Party A’s safety supervision. Non-compliance will result in penalties as per Party A’s regulations.

8.	Other

1.	This agreement is part of the project contract and has the same effect as the contract and is attached to the contract text.

2.	This agreement shall be valid upon being signed and sealed by both parties, and both parties shall abide by it. If this agreement is not signed, the project contract shall be invalid.

3.	The construction safety agreement shall come into force from the date of signature and seal, in duplicate, with each party holding one copy, both of which shall have legal effect.

Party A: Shenzhen Zhongyun Communication Technology Co., Ltd

Signature/Seal:

Party B: Shenzhen Zhongyun Information Technology Co., Ltd

Signature / Seal:

Exhibit 23.1

CONSENT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM

To Whom It May Concern:

We hereby consent to the inclusion in this Amendment No. 3 Registration Statement of Alpha One Inc. on Form S-1 of our report dated October 31, 2024, with respect to our audits of the consolidated financial statements of Alpha One Inc. and Subsidiaries for the years ended March 31, 2024 and 2023 and to each of the years in the two-year period ended March 31, 2024.

We also consent to the reference to our Firm under the heading “Experts” in the prospectus.

/s/ Bush & Associates CPA LLC (PCAOB 6797)
Henderson, Nevada
February 24, 2025

Exhibit 107

Alpha one inc.

(Exact Name of Registrant as Specified in its Charter)

CALCULATION OF REGISTRATION FEE

Title of Each Class of Securities to be Registered

Amount to

Registered

Proposed

Maximum

Offering

Price Per

Share (1)

Proposed

Maximum

Aggregate

Offering

Price

Amount of

Registration

Fee (2)

Common Stock, $0.001 par value

10,000,000

2.38

23,800,000

3,643.78

(1)

Estimated solely for purposes of calculating the registration fee in accordance with Rule 457(a) of the Securities Act of 1933 based upon

the closing sale price of our shares of common stock of 2.38 on October 29, 2024.

(2)

The fee is calculated by multiplying the aggregate offering amount by 0.0001531, pursuant to Section 6(b) of the Securities Act of 1933.

Alpha One (PK) (USOTC:AOAO)
Graphique Historique de l'Action
De Fév 2025 à Mar 2025

Plus de graphiques de la Bourse Alpha One (PK)

Alpha One (PK) (USOTC:AOAO)
Graphique Historique de l'Action
De Mar 2024 à Mar 2025

Donnée du Marché

Actualité

Outils

Donnée du Marché

Discover

Hot Features

Follow Feed

Flux des Options

Moniteur

AOAO Alpha One Inc (PK)

Actualités Alpha One Inc (PK)

Dernières Valeurs Consultées

Société

Entreprise

Popular

Obtenir l'application

Donnée du Marché

Actualité

Outils

Donnée du Marché

Discover

Hot Features

Follow Feed

Flux des Options

Moniteur

AOAO Alpha One Inc (PK)

Actualités Alpha One Inc (PK)

Dernières Valeurs Consultées

Société

Entreprise

Popular

Obtenir l'application

Supprimer les publicités